Document
Table of Contents


 
 
 
 
 
 

UNITED STATES
SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549
 
FORM 10-K
 
T
ANNUAL REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934
For the fiscal year ended January 1, 2017
OR
o
TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

For the transition period from ______________ to ______________

Commission file number 001-34166


sp2014logoa01a12.gif
SunPower Corporation
(Exact Name of Registrant as Specified in Its Charter)
Delaware
 
94-3008969
(State or Other Jurisdiction of Incorporation or Organization)
 
(I.R.S. Employer Identification No.)
77 Rio Robles, San Jose, California 95134
(Address of Principal Executive Offices and Zip Code)
(408) 240-5500
(Registrant's Telephone Number, Including Area Code)

Securities registered pursuant to Section 12(b) of the Act:
Title of each class
Name of each exchange on which registered
Common Stock $0.001 par value
Nasdaq Global Select Market
Preferred Stock Purchase Rights
Nasdaq Global Select Market
d
Securities registered pursuant to Section 12(g) of the Act: None


_________________________________________
Indicate by check mark if the registrant is a well-known seasoned issuer, as defined in Rule 405 of the Securities Act. Yes  T    No  o
Indicate by check mark if the registrant is not required to file reports pursuant to Section 13 of Section 15(d) of the Act. Yes  o    No  x
Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Sections 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. Yes  T    No  o

Indicate by check mark whether the registrant has submitted electronically and posted on its corporate Web site, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T (§232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files). Yes  T    No  o

Indicate by check mark if disclosure of delinquent filers pursuant to Item 405 of Regulation S-K (§229.405 of this chapter) is not contained herein, and will not be contained, to the best of registrant’s knowledge, in definitive proxy or information statements incorporated by reference in Part III of this Form 10-K or any amendment to this Form 10-K.  T

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting company. See the definitions of “large accelerated filer,” “accelerated filer” and “smaller reporting company” in Rule 12b-2 of the Exchange Act. (Check one):
Large accelerated filer x
Accelerated filer o
Non-accelerated filer o
Smaller reporting company o
 
 
(Do not check if a smaller reporting company)
 
Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Act).  Yes  o    No  T

The aggregate market value of the voting stock held by non-affiliates of the registrant on July 3, 2016 was $906 million. Such aggregate market value was computed by reference to the closing price of the common stock as reported on the Nasdaq Global Select Market on July 1, 2016. For purposes of determining this amount only, the registrant has defined affiliates as including Total Energies Nouvelles Activités USA, formerly known as Total Gas & Power USA, SAS and the executive officers and directors of registrant on July 1, 2016.

The total number of outstanding shares of the registrant’s common stock as of February 10, 2017 was 138,651,751.

DOCUMENTS INCORPORATED BY REFERENCE


Parts of the registrant’s definitive proxy statement for the registrant’s 2017 annual meeting of stockholders are incorporated by reference in Items 10, 11, 12, 13, and 14 of Part III of this Annual Report on Form 10-K.

 
 
 
 
 
d


1

Table of Contents


TABLE OF CONTENTS
 
 
Page
Part I.
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
Part II.
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 


2

Table of Contents


INTRODUCTORY NOTES

Trademarks

The following terms, among others, are our trademarks and may be used in this report: SunPower®, Maxeon®, Oasis®, EnergyLink™, InvisiMount®, Tenesol®, Greenbotics®, Customer Cost of Energy™ ("CCOE™"), SunPower Spectrum™, Helix™, Equinox™, Signature™, SolarBridge®, and The Power of One™. Other trademarks appearing in this report are the property of their respective owners.

Unit of Power

When referring to our solar power systems, our facilities’ manufacturing capacity, and total sales, the unit of electricity in watts for kilowatts ("KW"), megawatts ("MW"), and gigawatts ("GW") is direct current ("DC"), unless otherwise noted as alternating current ("AC").

Levelized Cost of Energy ("LCOE")

LCOE is an evaluation of the life-cycle energy cost and life-cycle energy production of an energy producing system. It allows alternative technologies to be compared to different scales of operation, investment or operating time periods. It captures capital costs and ongoing system-related costs, along with the amount of electricity produced, and converts them into a common metric. Key drivers for LCOE reduction for photovoltaic products include panel efficiency, capacity factors, reliable system performance, and the life of the system.

Customer Cost of Energy("CCOE")

Our customers are focused on reducing their overall cost of energy by intelligently integrating solar and other distributed generation, energy efficiency, energy management, and energy storage systems with their existing utility-provided energy. The CCOE™ measurement is an evaluation of a customer’s overall cost of energy, taking into account the cost impact of each individual generation source (including the utility), energy storage systems, and energy management systems.  The CCOE measurement includes capital costs and ongoing operating costs, along with the amount of electricity produced, stored, saved, or re-sold, and converts all of these variables into a common metric. The CCOE metric allows a customer to compare different portfolios of generation sources, energy storage, and energy management, and to tailor towards optimization.  

Cautionary Statement Regarding Forward-Looking Statements

This Annual Report on Form 10-K contains forward-looking statements within the meaning of the Private Securities Litigation Reform Act of 1995. Forward-looking statements are statements that do not represent historical facts and the assumptions underlying such statements. We use words such as "anticipate," "believe," "continue," "could," "estimate," "expect," "intend," "may," "plan," "predict," "project," "potential," "will," "would," "should," and similar expressions to identify forward-looking statements. Forward-looking statements in this Annual Report on Form 10-K include, but are not limited to, our plans and expectations regarding future financial results, expected operating results, business strategies, projected costs and cost reduction, development of new products and improvements to our existing products, our manufacturing capacity and manufacturing costs, the adequacy of our agreements with our suppliers, our ability to monetize utility projects, competitive positions, management's plans and objectives for future operations, the sufficiency of our cash and our liquidity, our ability to obtain financing, our ability to comply with debt covenants or cure any defaults, trends in average selling prices, the success of our joint ventures and acquisitions, expected capital expenditures, warranty matters, outcomes of litigation, our exposure to foreign exchange, interest and credit risk, general business and economic conditions in our markets, industry trends, the impact of changes in government incentives, expected restructuring charges, and the likelihood of any impairment of project assets and long-lived assets. These forward-looking statements are based on information available to us as of the date of this Annual Report on Form 10-K and current expectations, forecasts and assumptions and involve a number of risks and uncertainties that could cause actual results to differ materially from those anticipated by these forward-looking statements. Such risks and uncertainties include a variety of factors, some of which are beyond our control. Please see "Item 1A. Risk Factors" herein and our other filings with the Securities and Exchange Commission ("SEC") for additional information on risks and uncertainties that could cause actual results to differ. These forward-looking statements should not be relied upon as representing our views as of any subsequent date, and we are under no obligation to, and expressly disclaim any responsibility to, update or alter our forward-looking statements, whether as a result of new information, future events or otherwise.

The following information should be read in conjunction with the Consolidated Financial Statements and the accompanying Notes to Consolidated Financial Statements included in this Annual Report on Form 10-K. Our fiscal year ends

3

Table of Contents


on the Sunday closest to the end of the applicable calendar year. All references to fiscal periods apply to our fiscal quarter or year, which end on the Sunday closest to the calendar month end.

PART I

ITEM 1. BUSINESS

Corporate History

SunPower has been a leader in the solar industry for 30 years, originally incorporated in California in 1985 and reincorporated in Delaware during 2004 in connection with our initial public offering. In November 2011, our stockholders approved the reclassification of all outstanding former class A common stock and class B common stock into a single class of common stock listed on the Nasdaq Global Select Market under the symbol "SPWR." In fiscal 2011, we became a majority owned subsidiary of Total Energies Nouvelles Activités USA, formerly known as Total Gas & Power USA, SAS ("Total"), a subsidiary of Total S.A. ("Total S.A.").

Company Overview

We are a leading global energy company dedicated to changing the way our world is powered. We deliver complete solar solutions to residential, commercial, and power plant customers worldwide by offering:

Cutting-edge solar module technology and solar power systems that are designed to generate electricity over a system life typically exceeding 25 years;

Integrated Smart Energy software solutions that enable customers to effectively manage and optimize their CCOE measurement;

Installation, construction, and ongoing maintenance and monitoring services; and

Financing solutions that provide customers a variety of options for purchasing or leasing high efficiency solar products at competitive energy rates.

Our global reach is enhanced by Total S.A.'s long-standing presence in many countries where significant solar installation goals are being established.

Residential

Residential Systems

We offer a complete set of residential solutions that deliver value to homeowners and our dealer partners. We have developed the capability to deliver AC panels with factory-integrated microinverters. AC system architecture, as compared with DC systems, facilitates direct panel installation, eliminating the need to mount or assemble additional components on the roof or the side of a building, driving down system costs, improving overall system reliability, and providing improved, cleaner design aesthetics. As part of our complete solution approach, we offer our Equinox™ residential market product, a fully-integrated solar platform utilizing Maxeon® cells, AC panel architecture, and EnergyLink™ monitoring hardware to combine solar power production and energy management, allowing residential customers to quickly and easily complete their system installations and to ensure always-on connectivity so homeowners can easily access their data anytime, anywhere. The Equinox platform is also sold with our Smart Energy software analytics, which provides our customers with detailed information about their energy consumption and production, enabling them to further reduce their energy costs.

We offer the SunPower® InvisiMount® residential mounting system in our product portfolio. The InvisiMount® system is designed specifically for use with our panels and reduces installation time through pre-assembled parts and integrated grounding. The InvisiMount system is well-suited for residential sloped roof applications and provides design flexibility and enhanced aesthetics by delivering a unique, "floating" appearance.

We support our hardware development with investments in our proprietary set of advanced monitoring applications (the "SunPower Monitoring System") and our EnergyLink™ customer portal, which enable customers to gain visibility into their solar system production and household energy consumption. This software is available for use on the web or through the SunPower mobile application on smartphones and tablets. In fiscal 2016, we issued nine software upgrades to our EnergyLink customer portal offering and, as a result, have experienced increases in customer traffic, engagement, satisfaction, and referrals.

4

Table of Contents



Sales Channels, Residential Leasing Program and other Financing Options

We sell our residential solar energy solutions to end customers through a variety of means, including cash sales and long-term leases directly to end customers, sales to resellers, including the Company's third-party global dealer network, and sales of the Company's operations and maintenance (“O&M”) services.  

We offer financing programs that are designed to offer customers a variety of options to obtain high efficiency solar products and systems, including loans arranged through our third-party lending partners, in some cases for no money down, or by leasing high efficiency solar systems at competitive energy rates. Our residential lease program, in partnership with third-party investors, provides U.S. customers SunPower systems under 20-year lease agreements that include system maintenance and warranty coverage, including warranties on system performance. SunPower residential lease customers have the option to purchase their leased solar systems upon the sale or transfer of their home. These financing options enhance our ability to provide individually-tailored solar solutions to a broad range of residential customers.

We also have the ability to sell residential systems to 8point3 Energy Partners LP, a joint Yieldco vehicle in which we have an approximately 37% ownership stake, through transactions in which we sell portfolios of residential leases. For additional information on transactions with 8point3 Energy Partners LP, please see "Item 8. Financial Statements and Supplementary Data—Note 10. Equity Method Investments" in our Annual Report on Form 10-K for the fiscal year ended January 3, 2016.

Commercial

Commercial Roof and Ground Mounted Systems

As part of our complete solution product approach, we offer our Helix™ commercial market product. The Helix system is a pre-engineered, modular solution that combines our industry-leading solar module technology with integrated plug-and-play power stations, cable management systems, and mounting hardware that is built to last and fast to install, enabling customers to scale their solar programs quickly with minimal business disruption. The Helix platform is standardized across rooftop, carport and ground installations and designed to lower system cost while improving performance. The Helix platform is also bundled with our Smart Energy software analytics, which provides our customers with detailed information about their energy consumption and production, enabling them to further reduce their energy costs.

We also offer a variety of commercial solutions designed to address a wide range of site requirements for commercial rooftop, parking lot and open space applications, including a portfolio of solutions utilizing framed panels and a variety of internally or externally developed mounting methods for flat roof and high tilt roof applications. Our commercial flat rooftop systems are designed to be lightweight and interlock, enhancing wind resistance and providing for secure, rapid installations.

We offer parking lot structures designed specifically for SunPower panels, balance of system components, and inverters and in fiscal 2015 expanded our capability to design and install innovative solar structures and systems for carport applications. These systems are typically custom design-build projects that utilize standard templates and design best practices to create a solution tailored to unique site conditions. SunPower's highest efficiency panels are especially well suited to stand-alone structures, such as those found in parking lot applications, because our systems require less steel and other materials per unit of power or energy produced as compared with our competitors.

Sales Channels and Financing Options

We sell our commercial solar energy solutions to commercial and public entity end customers through a variety of means, including direct sales of turn-key engineering, procurement and construction ("EPC") services, sales to our third-party global dealer network and to 8point3 Energy Partners, and sales of our O&M services. We also offer some of our commercial customers alternatives to purchasing systems, such as selling energy to them under power purchase agreements ("PPAs").

Power Plants

Power Plant Systems

We offer the industry's first modular solar power block, the Oasis® system, which combines SunPower solar panels and tracker technology into a scalable 1.5 MW solar power block, which streamlines the construction process while optimizing the use of available land by conforming to the contours of the production site. The power block kits are shipped pre-assembled to

5

Table of Contents


the job site for rapid field installation. The Oasis operating system is designed to support future grid interconnection requirements for large-scale solar power plants, such as voltage ride-through and power factor control. More than 2 GW of the Oasis system is installed or under contract worldwide. The Oasis system was deployed at the 748 MW Solar Star Projects in California, formerly known as Antelope Valley Solar Projects, the world's largest solar power project to date. Our robotic solar power plant cleaning system technology has been deployed on many of the utility-scale solar power systems for which we provide O&M services. The robots may be configured for use with a variety of solar panels and mounting types, including fixed-tilt arrays and single access trackers and significantly reduce water use and improve system performance.

Our single axis tracking systems automatically pivot solar panels to track the sun's movement throughout the day. This tracking feature increases the amount of sunlight that is captured and converted into energy by up to 30% over flat or fixed-tilt systems, depending on geographic location and local climate conditions. A single motor and drive mechanism can control 10 to 20 rows, or more than 200 KW, of solar panels. This multi-row feature represents a cost advantage for our customers over dual axis tracking systems, as such systems require more motors, drives, land, and power to operate per KW of capacity.

Utility-Scale Solar Power System Construction and Development

Our global project teams have established a scalable, fully integrated, vertical approach to constructing and developing utility-scale photovoltaic power plants in a sustainable way. Our industry experienced power plant development and project finance teams evaluate sites for solar developments; obtain land rights through purchase and lease options; conduct environmental and grid transmission studies; and obtain building, construction and grid-interconnection permits, licenses, and regulatory approvals.

We enter into turnkey EPC agreements with customers under which we design, engineer, construct, commission, and deliver functioning rooftop- and ground-mounted solar power systems. This includes the development, execution, and sale of solar power plants, which generally include the sale or lease of related real estate. Under such development projects, the plants and project development rights, initially owned by us, are later sold to third parties. In the United States, commercial and electric utility customers typically choose to purchase solar electricity under a PPA with an investor or financing company that buys the system from us. In other areas, such as the Middle East, Africa, and South America, projects are typically purchased by an investor or financing company and operated as central-station solar power plants.

Sales Channels and Financing

Our power plant business refers to sales of our large-scale solar products and systems, including power plant project development and project sales, EPC services for power plant construction, power plant O&M services and component sales for power plants developed by third parties, sometimes on a multi-year, firm commitment basis.  Our utility-scale solar power systems are typically purchased by an investor or financing company and operated as central-station solar power plants. We also sell utility-scale solar power plants to 8point3 Energy Partners.

We are able to utilize various means to finance our utility-scale power plant development and construction projects, which include arranging tax equity financing structures, utilizing non-recourse project debt facilities, and executing our HoldCo strategy in conjunction with project sales to 8point3 Energy Partners.

Operations and Maintenance

Our solar power systems are designed to generate electricity over a system life typically exceeding 25 years. We offer our customers various levels of post-installation O&M services with the objective of optimizing our customers' electrical energy production over the life of the system. The terms and conditions of post-installation O&M services may provide for remote monitoring of system production and performance, including providing performance reports, preventative maintenance, including solar module cleanings, corrective maintenance, and rapid-response outage restoration, including repair or replacement of all system components covered under warranty or major maintenance agreements.

We incorporate leading information technology platforms to facilitate the management of our solar power systems operating worldwide. Real-time flow of data from our customers' sites is aggregated centrally where an engine applies advanced solar specific algorithms to detect and report potential performance issues. Our work management system routes any anomalies to the appropriate responders to help ensure timely resolution. Our performance model, PVSim, was developed over the last 20 years and has been audited by independent engineers. Solar panel performance coefficients are established through independent third-party testing. The SunPower Monitoring System also provides customers real-time performance status of their solar power system, with access to historical or daily system performance data through our customer website (www.sunpowermonitor.com). The SunPower Monitoring System is available through applications on Apple® and Android™

6

Table of Contents


devices. Some customers choose to install "digital signs" or kiosks to display system performance information from the lobby of their facility. We believe these displays enhance our brand and educate the public and prospective customers about solar power.

We typically provide a system output performance warranty, separate from our standard solar panel product warranty, to customers that have subscribed to our post-installation O&M services. The system output performance warranty expires upon termination of the post-installation O&M services related to the system. In connection with system output performance warranties, we agree to pay liquidated damages in the event the system does not perform to the stated specifications, with certain exclusions. The warranty excludes system output shortfalls attributable to force majeure events, customer curtailment, irregular weather, and other similar factors. In the event that the system output falls below the warrantied performance level during the applicable warranty period, and provided that the shortfall is not caused by a factor that is excluded from the performance warranty, the warranty provides that SunPower will pay the customer an amount based on the value of the shortfall of energy produced relative to the applicable warrantied performance level. For leased systems, we provide a system output performance warranty with similar terms and conditions as that for non-leased systems.

We calculate our expectation of system output performance based on a particular system’s design specifications, including the type of panels used, the type of inverters used, site irradiation measures derived from historical weather data, our historical experience as a manufacturer, EPC services provider, and project developer as well as other unique design considerations such as system shading. The warrantied system output performance level varies by system depending on the characteristics of the system and the negotiated agreement with the customer, and the level declines over time to account for the expected degradation of the system. Actual system output is typically measured annually for purposes of determining whether warrantied performance levels have been met.

Our primary remedy for the system output performance warranty is our ongoing O&M services which enable us to quickly identify and remediate potential issues before they have a significant impact on system performance. We also have remedies in the form of our standard product warranties and third-party original equipment manufacturer warranties that cover certain components, such as inverters, to prevent potential losses under our system output performance warranties or to minimize further losses.

Technology

We believe that we possess a technological advantage as the leading manufacturer of back-contact, back-junction cells that enables our panels to produce more electricity, last longer and resist degradation more effectively. We believe that our technology allows us to deliver:

superior performance, including the ability to generate up to 45% more power per unit area than conventional solar cells;

superior aesthetics, with our uniformly black surface design that eliminates highly visible reflective grid lines and metal interconnection ribbons;

superior reliability, as confirmed by multiple independent reports and internal reliability data;

superior energy production per rated watt of power, as confirmed by multiple independent reports; and

solar power systems that are designed to generate electricity over a system life typically exceeding 25 years.

With industry-leading conversion efficiencies, we continuously improve our Maxeon® solar cells and believe they perform better and are tested more extensively to deliver maximum return on investment when compared with the products of our competitors.

Panels

Solar panels are solar cells electrically connected together and encapsulated in a weatherproof panel. Solar cells are semiconductor devices that convert sunlight into direct current electricity. Our solar cells are designed without highly reflective metal contact grids or current collection ribbons on the front of the solar cell, which provides additional efficiency and allows our solar cells to be assembled into solar panels with a more uniform appearance. Our X-Series solar panels, made with our Maxeon Gen 3 solar cells, have demonstrated panel efficiencies exceeding 22% in high-volume production. In fiscal 2016, one of our standard production modules set a world record for aperture area efficiency as tested by National Renewable Energy Laboratory ("NREL"). We believe our X-Series solar panels are the highest efficiency solar panels available for the mass market, and we continue to focus on increasing cell efficiency even as we produce solar cells with over 25% efficiency in a lab

7

Table of Contents


setting. Because our solar cells are more efficient relative to conventional solar cells, when our solar cells are assembled into panels, the assembly cost per watt is less because more power can be incorporated into a given size panel. Higher solar panel efficiency allows installers to mount a solar power system with more power within a given roof or site area and can reduce per watt installation costs. Our suite of SunPower solar panels provides customers a variety of features to fit their needs, including the SunPower® Signature Black design which allows the panels to blend seamlessly into the rooftop. We offer panels that can be used both with inverters that require transformers as well as with the highest performing transformer-less inverters to maximize output. Both our X-Series and E-Series panels have proven performance with low levels of degradation, as validated by third-party performance tests. Additionally, in fiscal 2016, we launched a new line of solar panels under the Performance Series product name. These products utilize a proprietary manufacturing process to assemble conventional silicon solar cells into panels with increased efficiency and reliability compared with conventional panels. Designed to target a new set of customers and global markets, we expect Performance Series panels to contribute to the growth of all three of SunPower’s business segments.

Balance of System Components

"Balance of system components" are components of a solar power system other than the solar panels, and include mounting structures, charge controllers, grid interconnection equipment, and other devices, depending on the specific requirements of a particular system and project. We possess advanced module-level control electronics in our technology portfolio that enable longer series strings and significant balance of system components cost reductions in large arrays.

Inverters

Every solar power system needs an inverter to transform the direct current electricity collected from the solar panels into utility-grade AC power that is ready for use. We sell inverters manufactured by third parties, some of which are SunPower-branded. We also have integrated microinverter technology that converts DC generated by a single solar photovoltaic panel into AC directly on the panel. We are utilizing this technology to develop next generation microinverters for use with our high efficiency solar panels. Panels with these factory-integrated microinverters perform better in shaded applications compared to conventional string inverters and allow for optimization and monitoring at the solar panel level, enabling maximum energy production by the solar system.

Warranties

SunPower provides a 25-year standard solar panel product warranty for defects in materials and workmanship. The solar panel product warranty also warrants that the panel will provide 95% of the panel’s minimum peak power rating for the first five years, declining due to expected degradation by no more than 0.4% per year for the following 20 years, such that the power output at the end of year 25 will be at least 87% of the panel’s minimum peak power rating. Our warranty provides that we will repair or replace any defective solar panels during the warranty period. We also pass through long-term warranties from the original equipment manufacturers of certain system components to customers for periods ranging from five to 20 years. In addition, we generally warrant our workmanship on installed systems for periods ranging up to 25 years.

Smart Energy

We see “Smart Energy” as a way to harness our world’s energy potential by connecting the most powerful and reliable solar systems on the market with an increasingly vast array of actionable data that can help our customers make smarter decisions about their energy use. Our Smart Energy initiative is designed to add layers of intelligent control to homes, buildings and grids—all personalized through easy-to-use customer interfaces. In order to enhance the portfolio of Smart Energy solutions we offer, we continue to invest in integrated technology solutions to help customers manage and optimize their CCOE measurement.

We have an investment in Tendril Networks, Inc. and have licensed its data-driven Energy Services Management Platform. We believe that this open, cloud-based software platform provides the infrastructure, analytics and understanding required to power the development of new Smart Energy applications that will deliver personalized energy services to our residential customers.

We have also negotiated several agreements with residential and commercial energy storage providers to integrate storage technology into our residential and commercial solar solutions. By combining storage with energy management, we lower our customers' cost of energy through improvements in self-consumption, rate arbitrage, demand management, and grid and market participation. We continue to work to make combined solar and storage solutions broadly commercially available.


8

Table of Contents


We are developing next generation microinverters for use with our high efficiency solar panels in order to enhance our portfolio of Smart Energy solutions. Panels with these factory-integrated microinverters can convert direct current generated by the solar panel into alternating current, enabling optimization and monitoring at the solar panel level to ensure maximum energy production by the solar system.

Research and Development

We engage in extensive research and development efforts to improve solar cell efficiency through enhancement of our existing products, development of new techniques, and reducing manufacturing cost and complexity. Our research and development group works closely with our manufacturing facilities, our equipment suppliers and our customers to improve our solar cell design and to lower solar cell, solar panel and system product manufacturing and assembly costs. In addition, we have dedicated employees who work closely with our current and potential suppliers of crystalline silicon, a key raw material used in the manufacture of our solar cells, to develop specifications that meet our standards and ensure the high quality we require, while at the same time controlling costs. Under our Research & Collaboration Agreement with Total, our majority stockholder, we have established a joint committee to engage in long-term research and development projects with continued focus on maintaining and expanding our technology position in the crystalline silicon domain and ensuring our competitiveness. Please see "Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations - Research and Development."

Supplier Relationships, Manufacturing, and Panel Assembly

We purchase polysilicon, ingots, wafers, solar cells, balance of system components, and inverters from various manufacturers on both a contracted and a purchase order basis. We have contracted with some of our suppliers for multi-year supply agreements. Under such agreements, we have annual minimum purchase obligations and in certain cases prepayment obligations. Please see "Item 7. Management's Discussion and Analysis of Financial Condition and Results of Operations—Liquidity and Capital Resources—Contractual Obligations" for further information regarding the amount of our purchase obligations in fiscal 2017 and beyond. Under other supply agreements, we are required to make prepayments to vendors over the terms of the arrangements. As of January 1, 2017, advances to suppliers totaled $284.8 million. We may be unable to recover such prepayments if the credit conditions of these suppliers materially deteriorate or if we are otherwise unable to fulfill our obligations under these supply agreements. For further information regarding our future prepayment obligations, please see "Item 8. Financial Statements and Supplementary Data—Note 9. Commitments and Contingencies—Advances to Suppliers." We currently believe our supplier relationships and various short- and long-term contracts will afford us the volume of material and services required to meet our planned output over the next several years. For more information about risks related to our supply chain, please see "Item 1A. Risk Factors—Risks Related to Our Supply Chain."

We are working with our suppliers and partners along all steps of the value chain to reduce costs by improving manufacturing technologies and expanding economies of scale. Crystalline silicon is the principal commercial material for solar cells and is used in several forms, including single-crystalline, or monocrystalline silicon, multicrystalline, or polycrystalline silicon, ribbon and sheet silicon, and thin-layer silicon. Our solar cell value chain starts with high purity silicon called polysilicon. Polysilicon is created by refining quartz or sand.
 
Polysilicon is melted and grown into crystalline ingots and sawed into wafers by business partners specializing in those processes. The wafers are processed into solar cells in our manufacturing facilities located in the Philippines and Malaysia. During fiscal 2016, we substantially completed the construction of the solar cell manufacturing facility that we own and operate in the Philippines. Once fully operational, which is expected to occur in the first half of fiscal 2017, the facility has a planned annual capacity of 350 MW. The solar cell manufacturing facility we own and operate in Malaysia has a total rated annual capacity of over 800 MW.

We use our solar cells to manufacture our X- and E-series solar panels at our solar panel assembly facilities located in Mexico and France, while we source solar cells from third parties for use in our Performance Series solar panels at our solar panel assembly facility in Mexico. Our solar panel manufacturing facilities have a combined total rated annual capacity of close to 1.9 GW.

We source the solar panels and balance of system components based on quality, performance, and cost considerations both internally and from third-party suppliers. We typically assemble proprietary components, while we purchase generally available components from third-party suppliers. The balance of system components, along with the EPC cost to construct the project, can comprise as much as two-thirds of the cost of a solar power system. Therefore, we focus on standardizing our products with the goal of driving down installation costs, such as with our Equinox, Helix, and SunPower® Oasis® systems.

9

Table of Contents


Customers

We operate in three end-customer segments: (i) Residential Segment, (ii) Commercial Segment and (iii) Power Plant Segment. The Residential and Commercial Segments combined are referred to as Distributed Generation. Our scope and scale allow us to deliver solar solutions across all segments, ranging from consumer homeowners to the largest commercial and governmental entities in the world. Our customers typically include investors, financial institutions, project developers, electric utilities, independent power producers, commercial and governmental entities, production home builders, residential owners and small commercial building owners. We leverage a combination of direct sales as well as a broad partner ecosystem to efficiently reach our global customer base.

We work with development, construction, system integration, and financing companies to deliver our solar power products and solutions to wholesale sellers, retail sellers, and retail users of electricity. In the United States, commercial and electric utility customers typically choose to purchase solar electricity under a PPA with an investor or financing company that buys the system from us. End-user customers typically pay the investors and financing companies over an extended period of time based on energy they consume from the solar power systems, rather than paying for the full capital cost of purchasing the solar power systems. Our utility-scale solar power systems are typically purchased by an investor or financing company, such as 8point3 Energy Partners, and operated as central-station solar power plants. In addition, our third-party global dealer network and our new homes division have deployed thousands of SunPower rooftop solar power systems to residential customers. See "Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations - Revenue" for our significant customers.

Competition

The market for solar electric power technologies is competitive and continually evolving. In the last year, we faced increased competition, resulting in price reductions in the market and reduced margins, which may continue and could lead to loss of market share. Our solar power products and systems compete with many competitors in the solar power market, including, but not limited to:

Residential and Commercial: Canadian Solar Inc., Hanwha Corporation, JA Solar Holdings Co., Kyocera Corporation, LG Corporation, Mitsubishi Corporation, NRG Energy, Inc., Panasonic Corporation, Recurrent Energy, Sharp Corporation, SolarWorld AG, Sungevity, Inc., SunRun, Inc., Tesla, Inc., Trina Solar Ltd., Vivint, Inc., and Yingli Green Energy Holding Co. Ltd.

Utility and Power Plant: Abengoa Solar S.A., Acciona Energia S.A., AES Solar Energy Ltd., Chevron Energy Solutions (a subsidiary of Chevron Corporation), EDF Energy plc, First Solar Inc., NextEra Energy, Inc., NRG Energy, Inc., Sempra Energy, Silverado Power LLC., Skyline Solar, Inc., Solargen Energy, Inc., Solaria Corporation, and Tenaska, Inc.

We also face competition from resellers that have developed related offerings that compete with our product and service offerings, or have entered into strategic relationships with other existing solar power system providers. We compete for limited government funding for research and development contracts, customer tax rebates and other programs that promote the use of solar, and other renewable forms of energy with other renewable energy providers and customers.

In addition, universities, research institutions, and other companies have brought to market alternative technologies, such as thin films, which compete with our technology in certain applications. Furthermore, the solar power market in general competes with conventional fossil fuels supplied by utilities and other sources of renewable energy such as wind, hydro, biomass, solar thermal, and emerging distributed generation technologies such as micro-turbines, sterling engines and fuel cells.

In the large-scale on-grid solar power systems market, we face direct competition from a number of companies, including those that manufacture, distribute, or install solar power systems as well as construction companies that have expanded into the renewable sector. In addition, we will occasionally compete with distributed generation equipment suppliers.

We believe that the key competitive factors in the market for solar systems include:

total system price;

LCOE evaluation;

CCOE evaluation;

10

Table of Contents



power efficiency and performance;

aesthetic appearance of solar panels and systems;

speed and ease of installation through modular solutions such as Oasis and Helix systems;

strength of distribution relationships;

availability of third-party financing and investments;

established sales channels to customers such as 8point3 Energy Partners;

timeliness of new product introductions;

bankability, strength, and reputation of our company; and

warranty protection, quality, and customer service.

We believe that we can compete favorably with respect to each of these elements, although we may be at a disadvantage in comparison to larger companies with broader product lines, greater technical service and support capabilities, and financial resources. For more information on risks related to our competition, please see the risk factors set forth under the caption "Item 1A. Risk Factors" including "Risks Related to Our Sales Channels—The increase in the global supply of solar cells and panels, and increasing competition, may cause substantial downward pressure on the prices of such products and cause us to lose sales or market share, resulting in lower revenues, earnings, and cash flows."

Intellectual Property

We rely on a combination of patent, copyright, trade secret, trademark, and contractual protections to establish and protect our proprietary rights. "SunPower" and the "SunPower" logo are our registered trademarks in countries throughout the world for use with solar cells, solar panels, energy monitoring systems, inverters, and mounting systems. We also hold registered trademarks for, among others, "Maxeon," "Oasis," "EnergyLink," "Equinox," "Helix," "InvisiMount," "Pantheon," "Serengeti," "Smarter Solar," "Smart Energy," "Solar Showdown," "SolarBridge," "Solaire," "Solaire Generation," "SunTile," "SunPower Electric," "SuPo Solar," "Tenesol," "TrueAC," "Greenbotics," "PowerLight," "More Energy. For Life.," "The Planet's Most Powerful Solar," "The Power of One," "The World's Standard for Solar," and "Use More Sun" in certain countries. We are seeking and will continue to seek registration of the "SunPower" trademark and other trademarks in additional countries as we believe is appropriate. As of January 1, 2017, we held registrations for 32 trademarks in the United States, and had 17 trademark registration applications pending. We also held 152 trademark registrations and had over 45 trademark applications pending in foreign jurisdictions. We typically require our business partners to enter into confidentiality and non-disclosure agreements before we disclose any sensitive aspects of our solar cells, technology, or business plans. We typically enter into proprietary information agreements with employees, consultants, vendors, customers, and joint venture partners.

We own multiple patents and patent applications that cover aspects of the technology in the solar cells, mounting products, and electrical and electronic systems that we currently manufacture and market. We continue to file for and receive new patent rights on a regular basis. The lifetime of a utility patent typically extends for 20 years from the date of filing with the relevant government authority. We assess appropriate opportunities for patent protection of those aspects of our technology, designs, methodologies, and processes that we believe provide significant competitive advantages to us, and for licensing opportunities of new technologies relevant to our business. As of January 1, 2017, we held 404 patents in the United States, which will expire at various times through 2035, and had 385 U.S. patent applications pending. We also held 348 patents and had 778 patent applications pending in foreign jurisdictions. While patents are an important element of our intellectual property strategy, our business as a whole is not dependent on any one patent or any single pending patent application. We additionally rely on trade secret rights to protect our proprietary information and know-how. We employ proprietary processes and customized equipment in our manufacturing facilities. We therefore require employees and consultants to enter into confidentiality agreements to protect them.

When appropriate, we enforce our intellectual property rights against other parties. For more information about risks related to our intellectual property, please see the risk factors set forth under the caption "Item 1A. Risk Factors" including "Risks Related to Our Intellectual Property—We depend on our intellectual property, and we may face intellectual property infringement claims that could be time-consuming and costly to defend and could result in the loss of significant rights," "Risks Related to Our Intellectual Property—We rely substantially upon trade secret laws and contractual restrictions to protect our proprietary rights, and, if these rights are not sufficiently protected, our ability to compete and generate revenue could suffer,"

11

Table of Contents


and "Risks Related to Our Intellectual Property—We may not obtain sufficient patent protection on the technology embodied in the solar products we currently manufacture and market, which could harm our competitive position and increase our expenses."

Backlog

We believe that backlog is not a meaningful indicator of our future business prospects.  In the residential and commercial markets we often sell large volumes of solar panel, mounting systems, and other solar equipment to third parties, which are typically ordered by our third-party global dealer network and customers under standard purchase orders with relatively short delivery lead-times.  We often require project financing for development and construction of our solar power plant projects, which require significant investments before the equity is later sold to investors.  Our solar power system project backlog would therefore exclude sales contracts signed and completed in the same quarter and contracts still conditioned upon obtaining financing.  Based on these reasons, we believe backlog at any particular date is not necessarily a meaningful indicator of our future revenue for any particular period of time.

Regulations

Public Policy Considerations

Different policy mechanisms have been used by governments to accelerate the adoption of solar power. Examples of customer-focused financial mechanisms include capital cost rebates, performance-based incentives, feed-in tariffs, tax credits, and net metering. Some of these government mandates and economic incentives are scheduled to be reduced or to expire, or could be eliminated altogether. Capital cost rebates provide funds to customers based on the cost and size of a customer’s solar power system. Performance-based incentives provide funding to a customer based on the energy produced by their solar power system. Feed-in tariffs pay customers for solar power system generation based on energy produced, at a rate generally guaranteed for a period of time. Tax credits reduce a customer’s taxes at the time the taxes are due. Net metering allows customers to deliver to the electric grid any excess electricity produced by their on-site solar power systems, and to be credited for that excess electricity at or near the full retail price of electricity.

In addition to the mechanisms described above, new market development mechanisms to encourage the use of renewable energy sources continue to emerge. For example, many states in the United States have adopted renewable portfolio standards which mandate that a certain portion of electricity delivered to customers come from eligible renewable energy resources. Some states, such as California and Hawaii, have significantly expanded their renewable portfolio standards in recent years. In certain developing countries, governments are establishing initiatives to expand access to electricity, including initiatives to support off-grid rural electrification using solar power. For more information about how we avail ourselves of the benefits of public policies and the risks related to public policies, please see the risk factors set forth under the caption "Item 1A. Risk Factors" including "Risks Related to Our Sales Channels—The reduction, modification or elimination of government incentives could cause our revenue to decline and harm our financial results," and "Risks Related to Our Sales Channels—Existing regulations and policies and changes to these regulations and policies may present technical, regulatory, and economic barriers to the purchase and use of solar power products, which may significantly reduce demand for our products and services."

Environmental Regulations

We use, generate, and discharge toxic, volatile, or otherwise hazardous chemicals and wastes in our research and development, manufacturing, and construction activities. We are subject to a variety of foreign, U.S. federal and state, and local governmental laws and regulations related to the purchase, storage, use, and disposal of hazardous materials. We believe that we have all environmental permits necessary to conduct our business and expect to obtain all necessary environmental permits for future activities. We believe that we have properly handled our hazardous materials and wastes and have appropriately remediated any contamination at any of our premises. For more information about risks related to environmental regulations, please see the risk factors set forth under the caption "Item 1A. Risk Factors" including "Risks Related to Our Operations—Compliance with environmental regulations can be expensive, and noncompliance with these regulations may result in adverse publicity and potentially significant monetary damages and fines."

The Iran Threat Reduction and Syria Human Rights Act of 2012

Section 13(r) of the Securities Exchange Act of 1934, as amended (the “Exchange Act”), requires us to disclose whether Total S.A. or any of its affiliates (collectively, the “Total Group”) engaged during the 2016 calendar year in certain Iran-related activities. While the Total Group has not engaged in any activity that would be required to be disclosed pursuant to

12

Table of Contents


subparagraphs (A), (B) or (C) of Section 13(r)(1), affiliates of Total S.A. may be deemed to have engaged in certain transactions or dealings with the government of Iran that would require disclosure pursuant to Section 13(r)(1)(D), as discussed below. Unless otherwise noted, all foreign currency translations to U.S. dollars in this section are made using exchange rates as of January 1, 2017.

Upstream

Following the suspension of certain international economic sanctions against Iran on January 16, 2016, the Total Group commenced various business development activities in Iran. The Total Group entered into a memorandum of understanding (“MOU”) with the National Iranian Oil Company (“NIOC”), pursuant to which NIOC provided technical data on certain oil and gas projects so that the Total Group could assess potential developments in Iran in compliance with the remaining applicable international economic sanctions. The Total Group subsequently proposed to develop and operate the South Pars Phase 11 gas field offshore Iran in the Persian Gulf along the international border with Qatar. This resulted in the negotiation and signing, on November 8, 2016, of a heads of agreement (“HOA”) for the development and operation of the field. The parties to the HOA are NIOC, Total E&P South Pars S.A.S. (a wholly owned affiliate of Total S.A.), CNPC International Ltd. (a wholly owned affiliate of China National Petroleum Company) and Petropars Ltd. (a wholly owned affiliate of NIOC). The HOA contains the key principles and commercial terms that will be adopted in a definitive contract for the development and operation of South Pars Phase 11, should such definitive contract be finally agreed. The project is expected to have a production capacity of 370,000 boe/d and the produced gas will be fed into Iran’s gas network. The Total Group is expected to operate the project with a 50.1% interest alongside Petropars (19.9%) and CNPC (30%). The required investment is expected to be approximately $4 billion, of which The Total Group would finance 50.1%, with all equity contributions and payments in non-U.S. currency. In preparation for the South Pars Phase 11 project, The Total Group commenced engineering and reservoir studies, which were presented in part to Pars Oil & Gas Company (a NIOC affiliate) in 2016 during a technical workshop. In the event of new or reinstated international economic sanctions, if such sanctions were to prevent the Total Group from performing under the anticipated contract for South Pars Phase 11, The Total Group expects to be able to terminate the contract and recover its past costs from NIOC (unless prevented by sanctions).

Regarding other potential oil and gas projects covered by the aforementioned MOU, The Total Group held technical meetings in 2016 with representatives of NIOC and its affiliated companies and carried out a technical review of the South Azadegan oil field in Iran as well as the Iran LNG Project (a project contemplating a 10 Mt/y LNG production facility at Tombak Port on Iran’s Persian Gulf coast), the results of which were partially disclosed to NIOC and relevant affiliated companies.

In addition, in connection with anticipated activities under the aforementioned MOU and HOA, The Total Group attended meetings in 2016 with the Iranian oil and gas ministry and several Iranian companies with ties to the government of Iran.

Also in 2016, The Total Group was selected, along with other international oil and gas companies, to form an advisory group to the oil and gas ministries of Iran and Oman concerning a possible future gas pipeline between the two countries. In that regard, The Total Group entered into a confidentiality agreement and attended meetings with these companies and ministries.

In addition, The Total Group registered in 2016 a branch office of a new entity, Total Iran B.V., a wholly-owned affiliate of Total S.A., the purpose of which is to serve as the representation office for the Total Group in Iran. This entity replaces Total E&P Iran, which previously served the same purpose, but only for Exploration & Production.

Neither revenues nor profits were recognized from any of the aforementioned activities in 2016, and the Total Group expects to conduct similar business development activities in 2017.

Some payments are yet to be reimbursed to the Total Group with respect to past expenditures and remuneration under buyback contracts entered into between 1997 and 1999 with NIOC for the development of the South Pars 2&3 and Dorood fields. With respect to these contracts, development operations were completed in 2010 and the Total Group is no longer involved in the operation of these fields.

Concerning payments to Iranian entities in 2016, Total E&P Iran (100%), Elf Petroleum Iran (99.8%), Total Sirri (100%) and Total South Pars (99.8%) collectively made payments of approximately IRR 3 billion (approximately $92,705) to (i) the Iranian administration for taxes and social security contributions concerning the personnel of the aforementioned local office and residual buyback contract-related obligations, and (ii) Iranian public entities for payments with respect to the maintenance

13

Table of Contents


of the aforementioned local office (e.g., utilities, telecommunications). The Total Group expects similar types of payments to be made by these affiliates in 2017, albeit in higher amounts due to increased business development activity in Iran. Neither revenues nor profits were recognized from the aforementioned activities in 2016.

Furthermore, Total E&P UK Limited (“TEP UK”), a wholly-owned affiliate of The Total Group, holds a 43.25% interest in a joint venture at the Bruce field in the UK with BP Exploration Operating Company Limited (37.5%, operator), BHP Billiton Petroleum Great Britain Ltd (16%) and Marubeni Oil & Gas (North Sea) Limited (3.75%). This joint venture is party to an agreement (the “Bruce Rhum Agreement”) governing certain transportation, processing and operation services provided to a joint venture at the Rhum field in the UK that is co-owned by BP (50%, operator) and the Iranian Oil Company UK Ltd (“IOC”), a subsidiary of NIOC (50%) (together, the “Rhum Owners”). TEP UK owned and operated the pipeline of the Frigg UK Association and the St Fergus Gas Terminal and was party to an agreement governing provision of transportation and processing services to the Rhum Owners (the “Rhum FUKA Agreement”) (the  Bruce Rhum Agreement and the Rhum FUKA Agreement being referred to collectively as the “Rhum Agreements”). On August 27, 2015, TEP UK signed a sale and purchase agreement to divest its entire interest in the Frigg UK Association pipeline and St Fergus Gas Terminal to NSMP Operations Limited (“NSMP”). On March 15, 2016, the divestment was completed and TEP UK’s interest in the Rhum FUKA Agreement was novated to NSMP. As from this date, TEP UK’s only interest in the Rhum FUKA Agreement is in relation to the settlement of historical force majeure claims with the Rhum Owners relating to the period when the Rhum field was shut down. To The Total Group's knowledge, provision of all services under the Rhum Agreements was initially suspended in November 2010, when the Rhum field stopped production following the adoption of EU sanctions, other than critical safety-related services (i.e., monitoring and marine inspection of the Rhum facilities), which were permitted by EU sanctions regulations. On October 22, 2013, the UK government notified IOC of its decision to apply a temporary management scheme to IOC’s interest in the Rhum field within the meaning of UK Regulations 3 and 5 of the Hydrocarbons (Temporary Management Scheme) Regulations 2013 (the "Hydrocarbons Regulations"). From October 22, 2013 until the termination of the temporary management scheme on March 16, 2016 (as further explained below), all correspondence by TEP UK in respect of IOC’s interest in the Rhum Agreements was with the UK government in its capacity as temporary manager of IOC’s interests. On December 6, 2013, the UK government authorized TEP UK, among others, under Article 43a of EU Regulation 267/2012, as amended by 1263/2012 and under Regulation 9 of the Hydrocarbons Regulations, to carry out activities in relation to the operation and production of the Rhum field. In addition, on September 4, 2013, the U.S. Treasury Department issued a license to BP authorizing BP and certain others to engage in various activities relating to the operation and production of the Rhum field. Following receipt of all necessary authorizations, the Rhum field resumed production on October 26, 2014 with IOC’s interest in the Rhum field and the Rhum Agreements subject to the UK government’s temporary management pursuant to the Hydrocarbons Regulations. Services were provided by TEP UK under the Rhum Agreements from October 26, 2014 and TEP UK received tariff income and revenues from BP and the UK government (in its capacity as temporary manager of IOC’s interest in the Rhum field) in accordance with the terms of the Rhum Agreements until the termination of the temporary management scheme in March 2016. As IOC ceased to be a listed person within the meaning of the Hydrocarbons Regulations on January 16, 2016, the UK government gave notice to IOC on January 22, 2016 of the termination of the temporary management scheme with effect from March 16, 2016 in accordance with regulation 26(1)(a) and 27(1)(a) of the Hydrocarbons Regulations. As a result, since March 16, 2016, TEP UK has liaised directly with IOC concerning its interest in the Bruce Rhum Agreement, and services have been provided by TEP UK under the Bruce Rhum Agreement to IOC as Rhum Owner. In 2016, these activities generated for TEP UK gross revenue of approximately £8 million (approximately $9.9 million) and net profit of approximately £0.20 million (approximately $0.2 million). Subject to the foregoing, TEP UK intends to continue such activities so long as they continue to be permissible under UK and EU law and not be in breach of remaining applicable international economic sanctions.

Downstream

The Total Group does not own or operate any refineries or chemicals plants in Iran and did not purchase Iranian hydrocarbons when prohibited by applicable EU and U.S. economic and financial sanctions (refer to point 1.9.1, above).

The Total Group resumed its trading activities with Iran in February 2016 via its wholly-owned affiliates Totsa Total Oil Trading S.A. and Total Trading Asia Pte Ltd. During 2016, approximately 50 Mb of crude oil from Iran were purchased for nearly €1.8 billion (approximately $1.9 billion) pursuant to a mix of spot and term contracts. Most of this crude oil was used to supply the Total Group's refineries and, therefore, it is not possible to estimate the related gross revenue and net profit. However, approximately 1.4 Mb of this crude oil were sold to entities outside of the Total Group. In addition, in 2016 approximately 11 Mb of petroleum products were bought from/sold to entities with ties to the government of Iran. These operations generated gross revenue of nearly €374 million (approximately $393.5 million) and net profit of approximately €2.7 million (approximately $2.8 million). The affiliates expect to continue these activities in 2017.

14

Table of Contents


Saft Groupe S.A. (“Saft”), a wholly-owned affiliate of the Total Group, in 2016 sold signaling and backup battery systems for metros and railways as well as products for the utilities and oil and gas sectors to companies in Iran, including some having direct or indirect ties with the Iranian government. In 2016, this activity generated gross revenue of approximately €5.6 million (approximately $5.9 million) and net profit of approximately €800,000 (approximately $841,636). Saft expects to continue this activity in 2017.

Saft also attended the Iran Oil Show in 2016, where it discussed business opportunities with Iranian customers, including those with direct or indirect ties with the Iranian government. Saft expects to conduct similar business development activities in 2017.

Total Solar (formerly named Total Energie Developpement), a wholly-owned affiliate of the Total Group, had preliminary discussions in 2016 regarding the potential development of solar projects with companies in Iran, including some having direct or indirect ties with the Iranian government. Neither revenues nor profits were recognized from this activity in 2016, and Total Solar expects to continue this activity in 2017.

Total S.A. signed in 2016 a non-binding memorandum of understanding with the National Petrochemical Company, a company owned by the government of Iran, to consider a project for the construction in Iran of a steamcracker and polyethylene production lines. In relation to the early stages of this project, several visits to Iran were conducted in 2016 and one employee has been seconded to Total Iran B.V. Total S.A. recognized no revenue or profit from this activity in 2016 and similar activities are expected to continue in 2017.

Representatives of the companies Le Joint Français (a subsidiary of Hutchinson SA) and Hutchinson SNC, wholly-owned affiliates of the Total Group, conducted multiple visits to Iran in 2016 to discuss business opportunities in the car industry sector with several companies, including some having direct or indirect ties with the Iranian government. These companies recognized no revenue or profit from this activity in 2016 and expect to continue such discussions in the future.

Hutchinson Gmbh, a wholly-owned affiliate of the Total Group, sold plastic tubing for automobiles in 2016 to Iran Khodro, a company in which the government of Iran holds a 20% interest and which is supervised by Iran’s Industrial Management Organization. In 2016, these activities generated gross revenue of approximately €900,000 (approximately $946,840) and net profit of approximately €150,000 (approximately $157,807). This company expects to continue this activity in 2017.

Hanwha Total Petrochemicals (“HTC”), a joint venture in which Total Holdings UK Limited (a wholly-owned affiliate of The Total Group) holds a 50% interest and Hanwha General Chemicals holds a 50% interest, purchased nearly 25 Mb of condensates from NIOC for approximately KRW 1,300 billion (approximately $1.1 million). These condensates are used as raw material for certain of the Total Group's steamcrackers. HTC expects to continue this activity in 2017.

Total Research & Technology Feluy (“TRTF”), a wholly-owned affiliate of The Total Group, commenced in 2016 the process to file a patent in Iran for pipes comprising a multimodal metallocene-catalyzed polyethylene resin. Related to this process, TRTF had contacts with Iranian government officials, but no fees were paid. TRTF expects to continue the patent filing process in 2017.

Until December 2012, at which time it sold its entire interest, the Total Group held a 50% interest in the lubricants retail company Beh Total (now named Beh Tam) along with Behran Oil (50%), a company controlled by entities with ties to the government of Iran. As part of the sale of the Total Group's interest in Beh Tam, Total S.A. agreed to license the trademark “Total” to Beh Tam for an initial 3-year period for the sale by Beh Tam of lubricants to domestic consumers in Iran. In 2014, Total E&P Iran (“TEPI”), a wholly-owned affiliate of Total S.A., received, on behalf of Total S.A., royalty payments of approximately IRR 24 billion (nearly $1 million) from Beh Tam for such license. These payments were based on Beh Tam’s sales of lubricants during the previous calendar year. In 2015, royalty payments were suspended due to a procedure brought by the Iranian tax authorities against TEPI. At the end of 2016, this procedure was still pending and no royalty payments had been received since 2015. Representatives of Total Outre Mer, a wholly-owned affiliate of the Total Group, made several visits to Beh Tam and Behran Oil during 2016 regarding the possible purchase of shares of Beh Tam. Subsequent to an internal reorganization, the matter was transferred to Total Oil Asia-Pacific Ltd, another wholly-owned affiliate of the Total Group, which had several exchanges with representatives of Behran Oil. As of the end of 2016, no agreement had been reached, no money was paid or received by either company. Similar discussions may take place in the future.


15

Table of Contents


Total Marketing Middle East FZE (“TMME”), a wholly-owned affiliate of the Total Group, sold lubricants to Beh Tam in 2016. The sale in 2016 of approximately 54 tons of lubricants and special fluids generated gross revenue of approximately AED 420,000 (approximately $30,711) and net profit of approximately AED 360,000 (approximately $26,324). TMME expects to continue this activity in 2017.

Total Marketing France (“TMF”), a company wholly-owned by Total Marketing Services (“TMS”), itself a company wholly-owned by Total S.A. and six Total Group employees, provided in 2016 fuel payment cards to the Iranian embassy in France for use in the Total Group's service stations. In 2016, these activities generated gross revenue of nearly €22,000 (approximately $23,145) and net profit of nearly €900 (approximately $947). TMF expects to continue this activity in 2017.

TMF also sold jet fuel in 2016 to Iran Air as part of its airplane refueling activities at Paris Orly airport in France. The sale of approximately 2.8 million liters of jet fuel generated gross revenue of approximately €982,000 (approximately $1.0 million) and net profit of approximately €10,000 (approximately $10,520). TMF expects to continue this activity through at least February 2017, when the contract arrives at its term.

Air Total International (“ATI”), a wholly-owned affiliate of the Total Group, on two occasions in 2016 sold jet fuel to a broker based at Le Bourget airport near Paris that was destined for the refueling of an Iranian government airplane (official presidential/ministerial visits). These sales generated gross revenue of approximately €8,000 (approximately $8,416) and net profit of approximately €1,600 (approximately $1,683). ATI may conduct similar activities in 2017.

Total Belgium (“TB”), a company wholly-owned by the Total Group, provided in 2016 fuel payment cards to the Iranian embassy in Brussels (Belgium) for use in the Total Group's service stations. In 2016, these activities generated gross revenue of approximately €1,500 (approximately $1,578) and net profit of approximately €300 (approximately $316). TB expects to continue this activity in 2017.

Proxifuel, a company wholly-owned by the Total Group, sold in 2016 heating oil to the Iranian embassy in Brussels. In 2016, these activities generated gross revenue of approximately €200 (approximately $210) and net profit of approximately €80 (approximately $84). Proxifuel expects to continue this activity in 2017.

Caldeo, a company wholly-owned by TMS, sold in 2016 approximately 3 cubic meters of domestic heating oil to the Iranian embassy in France, which generated gross revenue of nearly €435 (approximately $458) and net profit of nearly €115 (approximately $121). Caldeo expects to continue this activity in 2017.

Total Namibia (PTY) Ltd (“TN”), a wholly-owned affiliate of Total South Africa (PTY) Ltd (of which the Total Group holds 50.1%), sold petroleum products and services during 2016 to Rössing Uranium Limited, a company in which the Iranian Foreign Investment Co. holds an interest of 15.3%. In 2016, these activities generated gross revenue of nearly N$249 million (approximately $18.2 million) and net profit of approximately N$8 million (approximately $0.6 million). TN expects to continue this activity in 2017.

Employees

As of January 1, 2017, we had approximately 8,902 full-time employees worldwide, of which 1,290 were located in the United States, 3,588 were located in the Philippines, 1,633 were located in Malaysia, and 2,391 were located in other countries. Of these employees, 6,588 were engaged in manufacturing, 881 in construction projects, 406 in research and development, 492 in sales and marketing, and 535 in general and administrative services. Although in certain countries we have works councils and statutory employee representation obligations, our employees are generally not represented by labor unions on an ongoing basis. We have never experienced a work stoppage, and we believe our relations with our employees are good.

Geographic Information

Information regarding financial data by segment and geographic area is available in Note 5 and Note 17 under "Item 8. Financial Statements and Supplementary Data—Notes to Consolidated Financial Statements."

Seasonal Trends


16

Table of Contents


Our business is subject to industry-specific seasonal fluctuations including changes in weather patterns and economic incentives, among others. Sales have historically reflected these seasonal trends with the largest percentage of total revenues realized during the last two quarters of our fiscal year. The construction of solar power systems or installation of solar power components and related revenue may decline during cold winter months. In the United States, many customers make purchasing decisions towards the end of the year in order to take advantage of tax credits or for other budgetary reasons. In addition, revenues may fluctuate due to the timing of project sales, construction schedules, and revenue recognition of certain projects, such as those involving real estate, which may significantly impact the quarterly profile of the Company's results of operations. We may also retain certain development projects on our balance sheet for longer periods of time than in preceding periods in order to optimize the economic value we receive at the time of sale in light of market conditions, which can fluctuate after we have committed to projects. Delays in disposing of projects, or changes in amounts realized on disposition, may lead to significant fluctuations to the period-over-period profile of our results of operations and our cash available for working capital needs.

Available Information

We make available our Annual Reports on Form 10-K, Quarterly Reports on Form 10-Q, Current Reports on Form 8-K, and amendments to those reports filed or furnished pursuant to Section 13(a) or Section 15(d) of the Securities Exchange Act of 1934 (the "Exchange Act") free of charge on our website at www.sunpower.com, as soon as reasonably practicable after they are electronically filed with or furnished to the SEC. The contents of our website are not incorporated into, or otherwise to be regarded as part of this Annual Report on Form 10-K. Copies of such material may be obtained, free of charge, upon written request submitted to our corporate headquarters: SunPower Corporation, Attn: Investor Relations, 77 Rio Robles, San Jose, California, 95134. Copies of materials we file with the SEC may also be accessed at the SEC's Public Reference Room at 100 F Street NE, Washington, D.C., or at the SEC's website at www.sec.gov. The public may obtain additional information on the operation of the SEC's Public Reference Room by calling the SEC at 1-800-SEC-0330.


17

Table of Contents


ITEM 1A. RISK FACTORS

Our business is subject to various risks and uncertainties, including those described below and elsewhere in this Annual Report on Form 10-K, which could adversely affect our business, results of operations, and financial condition. Although we believe that we have identified and discussed below certain key risk factors affecting our business, there may be additional risks and uncertainties that are not currently known to us or that are not currently believed by us to be material that may also harm our business, results of operations and financial condition.

Risks Related to Our Sales Channels

Our operating results are subject to significant fluctuations and are inherently unpredictable.

We do not know whether our revenue will continue to grow, or if it will continue to grow sufficiently to outpace our expenses, which we also expect to grow. As a result, we may not be profitable on a quarterly basis. Our quarterly revenue and operating results are difficult to predict and have in the past fluctuated significantly from quarter to quarter. The principal reason for these significant fluctuations in our results is that we derive a substantial portion of our total revenues from our large commercial and utility-scale and power plant customers, and, consequently:
the amount, timing and mix of sales to our large commercial, utilities and power plant customers, often for a single medium or large-scale project, may cause large fluctuations in our revenue and other financial results because, at any given time, a single large-scale project can account for a material portion of our total revenue in a given quarter;

our inability to monetize our projects as planned, or any delay in obtaining the required government support or initial payments to begin recognizing revenue under the relevant recognition criteria, and the corresponding revenue impact, may similarly cause large fluctuations in our revenue and other financial results;

our ability to monetize projects as planned is also subject to market conditions, including fluctuations in demand based on the availability of regulatory incentives and other factors, changes in the internal rate of return expected by customers in light of market conditions, the increasing number of power plants being constructed or available for sale and competition for financing, which can make both financing and disposition more challenging and may significantly affect project sales prices;

market conditions may deteriorate after we have committed to projects, resulting in delays in disposing of projects, or changes in amounts realized on disposition, which may lead to significant fluctuations in the period-over-period profile of our results of operations and our cash available for working capital needs;

in the event a project is subsequently canceled, abandoned, or is deemed unlikely to occur, we will charge all prior capital costs as an operating expense in the quarter in which such determination is made, which could materially adversely affect operating results;

a delayed disposition of a project could require us to recognize a gain on the sale of assets instead of recognizing revenue;

our agreements with these customers may be canceled if we fail to meet certain product specifications or materially breach the agreement;

in the event of a customer bankruptcy, our customers may seek to terminate or renegotiate the terms of current agreements or renewals; and

the failure by any significant customer to pay for orders, whether due to liquidity issues or otherwise, could materially and adversely affect our results of operations.

Any decrease in revenue from our large commercial and utility-scale power plant customers, whether due to a loss or delay of projects or an inability to collect, could have a significant negative impact on our business. See also "Item 7A. Quantitative and Qualitative Disclosures About Market Risk." See also "Risks Related to Our Sales Channels - Revenues from a limited number of customers and large projects are expected to continue to comprise a significant portion of our total

18

Table of Contents


revenues and any decrease in revenues from those customers or projects, payment of liquidated damages, or an increase in related expenses, could have a material adverse effect on our business, results of operations and financial condition.”
Sales to our residential and light commercial customers are similarly susceptible to fluctuations in volumes and revenue, as well as fluctuations in demand based on the availability of regulatory incentives and other factors. In addition, demand from our commercial and residential customers may fluctuate based on the perceived cost-effectiveness of the electricity generated by our solar power systems as compared to conventional energy sources, such as natural gas and coal (which fuel sources are subject to significant price swings from time to time), and other non-solar renewable energy sources, such as wind. Declining average selling prices immediately affect our residential and light commercial sales volumes, and therefore lead to large fluctuations in revenue.
Further, our revenue mix of materials sales versus project sales can fluctuate dramatically from quarter to quarter, which may adversely affect our margins and financial results in any given period.
Any of the foregoing may cause us to miss our financial guidance for a given period, which could adversely impact the market price for our common stock and our liquidity.
We base our planned operating expenses in part on our expectations of future revenue and a significant portion of our expenses is fixed in the short term. If revenue for a particular quarter is lower than we expect, we likely will be unable to proportionately reduce our operating expenses for that quarter, which would materially adversely affect our operating results for that quarter. See also “-Risks Related to Our Sales Channels-Our business could be adversely affected by seasonal trends and construction cycles,” “-Risks Related to Our Sales Channels-The reduction, modification or elimination of government incentives could cause our revenue to decline and harm our financial results” and “-Risks Related to Our Sales Channels-Existing regulations and policies and changes to these regulations and policies may present technical, regulatory, and economic barriers to the purchase and use of solar power products, which may significantly reduce demand for our products and services.”
We may not achieve some or all of the expected benefits of our restructuring plans and our restructuring may adversely affect our business.

We announced restructuring plans in August 2016 and December 2016 to realign our downstream investments, optimize our supply chain, and reduce operating expenses, in response to market dislocation, including expected near-term challenges primarily relating to our power plant and commercial segments, and to reduce costs and focus on improving cash flow while positioning us to succeed in the next phase of industry growth. As part of such plans, our Board of Directors approved the closure of our Philippine-based Fab 2 manufacturing facility. Implementation of our restructuring plans may be costly and disruptive to our business, and we may not be able to obtain the cost savings and benefits that were initially anticipated in connection with our restructuring. Additionally, as a result of our restructuring, we may experience a loss of continuity, loss of accumulated knowledge, or inefficiency during transitional periods. Reorganization and restructuring can require a significant amount of management and other employees’ time and focus, which may divert attention from operating and growing our business. If we fail to achieve some or all of the expected benefits of restructuring, it could have a material adverse effect on our competitive position, business, financial condition, results of operations and cash flows. For more information about our restructuring plans, see our Current Reports on Form 8-K filed on August 9, 2016 and December 7, 2016 and “Item 8. Financial Statements and Supplementary Data–Notes to Consolidated Financial Statements–Note 8. Restructuring.”
The execution of our growth strategy is dependent upon the continued availability of third-party financing arrangements for our solar power plants, our residential lease program and our customers, and is affected by general economic conditions and other factors.

Our growth strategy depends on third-party financing arrangements. We often require project financing for development and construction of our solar power plant projects, which require significant investments before the equity is later sold to investors. Many purchasers of our systems projects have entered into third-party arrangements to finance their systems over an extended period of time, while many end-customers have chosen to purchase solar electricity under a power purchase agreement ("PPA") with an investor or financing company that purchases the system from us or our authorized dealers. We often execute PPAs directly with the end-user, with the expectation that we will later assign the PPA to a financier. Under such arrangements, the financier separately contracts with us to acquire and build the solar power system, and then sells the electricity to the end-user under the assigned PPA. When executing PPAs with end-users, we seek to mitigate the risk that financing will not be available for the project by allowing termination of the PPA in such event without penalty. However, we may not always be successful in negotiating for penalty-free termination rights for failure to obtain financing, and certain end-

19

Table of Contents


users have required substantial financial penalties in exchange for such rights. These structured finance arrangements are complex and may not be feasible in many situations.
Global economic conditions, including conditions that may make it more difficult or expensive for us to access credit and liquidity, could materially and adversely affect our business and results of operations. Credit markets are unpredictable, and if they become more challenging, we may be unable to obtain project financing for our projects, customers may be unable or unwilling to finance the cost of our products, we may have difficulties in reaching agreements with financiers to finance the construction of our solar power systems, or the parties that have historically provided this financing may cease to do so, or only do so on terms that are substantially less favorable for us or our customers, any of which could materially and adversely affect our revenue and growth in all segments of our business. Our plans to continue to grow our residential lease program may be delayed if credit conditions prevent us from obtaining or maintaining arrangements to finance the program. We are actively arranging additional third-party financing for our residential lease program; however, if we encounter challenging credit markets, we may be unable to arrange additional financing partners for our residential lease program in future periods, which could have a negative impact on our sales. In the event we enter into a material number of additional leases without obtaining corresponding third-party financing, our cash, working capital and financial results could be negatively affected. In addition, a rise in interest rates would likely increase our customers’ cost of financing or leasing our products and could reduce their profits and expected returns on investment in our products. The general reduction in available credit to would-be borrowers or lessees, worldwide economic uncertainty, and the condition of worldwide housing markets could delay or reduce our sales of products to new homebuilders and authorized resellers.
The availability of financing depends on many factors, including market conditions, the demand for and supply of solar projects, and resulting risks of refinancing or disposing of such projects. It also depends in part on government incentives, such as tax incentives. In the United States, with the expiration of the Treasury Grant under Section 1603 of the American Recovery and Reinvestment Act program, we have needed to identify interested financiers with sufficient taxable income to monetize the tax incentives created by our solar systems. In the long term, as we look toward markets not supported (or supported less) by government incentives, we will continue to need to identify financiers willing to finance residential solar systems without such incentives. Our failure to effectively do so could materially and adversely affect our business and results of operations. In addition, the new administration and Congress have expressed interest in comprehensive reform of the U.S. tax code, which could result in the reduction or elimination of various industry-specific tax incentives in return for an overall reduction in corporate tax rates.
The lack of project financing, due to tighter credit markets or other reasons, could delay the development and construction of our solar power plant projects, thus reducing our revenues from the sale of such projects. We may in some cases seek to pursue partnership arrangements with financing entities to assist residential and other customers to obtain financing for the purchase or lease of our systems, which would expose us to credit or other risks. We face competition for financing partners and if we are unable to continue to offer a competitive investment profile, we may lose access to financing partners or they may offer financing on less favorable terms than our competitors, which could materially and adversely affect our business and results of operations.
If we fail to successfully execute our cost reduction roadmap, or fail to develop and introduce new and enhanced products and services, we may be unable to compete effectively, and our ability to generate revenues would suffer.

Our solar panels are currently competitive in the market compared with lower cost conventional solar cells, such as thin-film, due to our products’ higher efficiency, among other things. Given the general downward pressure on prices for solar panels driven by increasing supply and technological change, a principal component of our business strategy is reducing our costs to manufacture our products to remain competitive. We also focus on standardizing our products with the goal of driving down installation costs. If our competitors are able to drive down their manufacturing and installation costs or increase the efficiency of their products faster than we can, our products may become less competitive even when adjusted for efficiency. Further, if raw materials costs and other third-party component costs were to increase, we may not meet our cost reduction targets. If we cannot effectively execute our cost reduction roadmap, our competitive position will suffer, and we could lose market share and our margins would be adversely affected as we face downward pricing pressure.
The solar power market is characterized by continually changing technology and improving features, such as increased efficiency, higher power output and enhanced aesthetics. Technologies developed by our direct competitors, including thin-film solar panels, concentrating solar cells, solar thermal electric and other solar technologies, may provide energy at lower costs than our products. We also face competition in some markets from other energy generation sources, including conventional fossil fuels, wind, biomass, and hydro. In addition, other companies could potentially develop a highly reliable renewable energy system that mitigates the intermittent energy production drawback of many renewable energy systems. Companies could also offer other value-added improvements from the perspective of utilities and other system owners, in which case such

20

Table of Contents


companies could compete with us even if the cost of electricity associated with any such new system is higher than that of our systems. We also compete with traditional utilities that supply energy to our potential customers. Such utilities have greater financial, technical, operational and other resources than we do. If electricity rates decrease and our products become less competitive by comparison, our operating results and financial condition will be adversely affected.
Our failure to further refine our technology, reduce cost in our manufacturing process, and develop and introduce new solar power products could cause our products or our manufacturing facilities to become less competitive or obsolete, which could reduce our market share, cause our sales to decline, and cause the impairment of our assets. This risk requires us to continuously develop new solar power products and enhancements for existing solar power products to keep pace with evolving industry standards, competitive pricing and changing customer preferences, expectations, and requirements. It is difficult to successfully predict the products and services our customers will demand. If we cannot continually improve the efficiency of our solar panels as compared with those of our competitors, our pricing will become less competitive, we could lose market share and our margins would be adversely affected. We have new products, such as our Performance Series, which have not yet been mass-deployed in the market. We need to prove their reliability in the field as well as drive down their cost in order to gain market acceptance.
As we introduce new or enhanced products or integrate new technology and components into our products, we will face risks relating to such transitions including, among other things, the incurrence of high fixed costs, technical challenges, acceptance of products by our customers, disruption in customers’ ordering patterns, insufficient supplies of new products to meet customers’ demand, possible product and technology defects arising from the integration of new technology and a potentially different sales and support environment relating to any new technology. Our failure to manage the transition to newer products or the integration of newer technology and components into our products could adversely affect our business’s operating results and financial condition.
We may fail to realize the expected benefits of our YieldCo strategy, which could materially adversely affect our business, financial condition, and results of operations.

In June 2015, 8point3 Energy Partners, a joint YieldCo vehicle formed by us and First Solar, Inc. to own, operate and acquire solar energy generation assets, launched an initial public offering of Class A shares representing its limited partner interests. The IPO was consummated on June 24, 2015, whereupon the Class A shares were listed on The NASDAQ Global Select Market under the trading symbol “CAFD.”
Immediately after the IPO, we contributed a portfolio of solar generation assets to 8point3 Energy Partners in exchange for cash proceeds as well as equity interests in several 8point3 Energy Partners affiliated entities (collectively, the “8point3 Group”). Additionally, we entered into a Right of First Offer Agreement with 8point3 Energy Partners in connection with the IPO under which we granted 8point3 Energy Partners a right of first offer to purchase certain of our solar energy projects that are in various stages of development in our project pipeline. We have sold four of these projects to 8point3 Energy Partners to date, including two projects which are currently in the process of being sold in phases.
We may be unable to fully realize our expected strategic and financial benefits from the 8point3 Group on a timely basis or at all. The operations of the 8point3 Group are not consolidated with ours. Instead, we account for our investments in the 8point3 Group using the equity method, whereby the book value of our investments is recorded as a non-current asset and our portion of their earnings is recorded in the Consolidated Statements of Operations under the caption “Equity in earnings (loss) of unconsolidated investees.”
There is no assurance that we will realize a return on our equity investments in the 8point3 Group. The ability of the 8point3 Group to make cash distributions will depend primarily upon its cash flow, which is not solely a function of 8point3 Energy Partners’ profitability. There is no assurance that we will receive any further cash distributions. Accordingly, we may never recover the value of the assets we contribute to the YieldCo vehicle, and we may realize less of a return on such contribution than if we had retained or operated these assets. In addition, 8point3 Energy Partners may be unable to obtain funding through the sale of equity securities or otherwise. If adequate funds and other resources are not available on acceptable terms, 8point3 Group may be unable to purchase assets that we wish to sell, or otherwise function as anticipated and planned. In such event, our YieldCo strategy may not succeed, and our business, financial condition and results of operations would be materially adversely affected.
We believe that the viability of our YieldCo strategy will depend, among other things, upon our ability to continue to develop revenue-generating solar assets, to build and manage relationships with sponsors, and to productively manage our relationship with First Solar and the 8point3 Group, which are subject to the project-level, joint venture relationship, business, and industry risks described herein. If we are unable to realize the strategic and financial benefits that we expect to derive from

21

Table of Contents


our YieldCo strategy and 8point3 Energy Partners in particular, our business, financial condition and results of operations could be materially adversely affected.
The increase in the global supply of solar cells and panels, and increasing competition, may cause substantial downward pressure on the prices of such products and cause us to lose sales or market share, resulting in lower revenues, earnings, and cash flows.

Global solar cell and panel production capacity has been materially increasing overall, and solar cell and solar panel manufacturers currently have excess capacity, particularly in China. Excess capacity and industry competition have resulted in the past, and may continue to result, in substantial downward pressure on the price of solar cells and panels, including SunPower products. Intensifying competition could also cause us to lose sales or market share. Such price reductions or loss of sales or market share could have a negative impact on our revenue and earnings, and could materially adversely affect our business, financial condition and cash flows. In addition, our internal pricing forecasts may not be accurate in such a market environment, which could cause our financial results to be different than forecasted. See also under this section, “Risks Related to Our Sales Channels - If we fail to successfully execute our cost reduction roadmap, or fail to develop and introduce new and enhanced products and services, we may be unable to compete effectively, and our ability to generate revenues would suffer.”
The reduction, modification or elimination of government incentives could cause our revenue to decline and harm our financial results.

The market for on-grid applications, where solar power is used to supplement a customer’s electricity purchased from the utility network or sold to a utility under tariff, depends in large part on the availability and size of government mandates and economic incentives because, at present, the cost of solar power generally exceeds retail electric rates in many locations and wholesale peak power rates in some locations. Incentives and mandates vary by geographic market. Various government bodies in most of the countries where we do business have provided incentives in the form of feed-in tariffs, rebates, and tax credits and other incentives and mandates, such as renewable portfolio standards and net metering, to end-users, distributors, system integrators and manufacturers of solar power products to promote the use of solar energy in on-grid applications and to reduce dependency on other forms of energy. These various forms of support for solar power are subject to change (as for example occurred in 2011 in Germany and other European countries, and in 2015 with Nevada’s decision to change net energy metering), and are expected in the longer term to decline. Even changes that may be viewed as positive (such as the extension at the end of 2015 of U.S. tax credits related to solar power) can have negative effects if they result, for example, in delaying purchases that otherwise might have been made before expiration or scheduled reductions in such credits. Governmental decisions regarding the provision of economic incentives often depend on political and economic factors that we cannot predict and that are beyond our control. The reduction, modification or elimination of grid access, government mandates or economic incentives in one or more of our customer markets would materially and adversely affect the growth of such markets or result in increased price competition, either of which could cause our revenue to decline and materially adversely affect our financial results.
Existing regulations and policies and changes to these regulations and policies may present technical, regulatory, and economic barriers to the purchase and use of solar power products, which may significantly reduce demand for our products and services.

The market for electric generation products is heavily influenced by federal, state and local government laws, regulations and policies concerning the electric utility industry in the United States and abroad, as well as policies promulgated by electric utilities. These regulations and policies often relate to electricity pricing and technical interconnection of customer-owned electricity generation, and changes that make solar power less competitive with other power sources could deter investment in the research and development of alternative energy sources as well as customer purchases of solar power technology, which could in turn result in a significant reduction in the demand for our solar power products. The market for electric generation equipment is also influenced by trade and local content laws, regulations and policies that can discourage growth and competition in the solar industry and create economic barriers to the purchase of solar power products, thus reducing demand for our solar products. In addition, on-grid applications depend on access to the grid, which is also regulated by government entities. We anticipate that our solar power products and their installation will continue to be subject to oversight and regulation in accordance with federal, state, local and foreign regulations relating to construction, safety, environmental protection, utility interconnection and metering, trade, and related matters. It is difficult to track the requirements of individual states or local jurisdictions and design equipment to comply with the varying standards. In addition, the U.S., European Union and Chinese governments, among others, have imposed tariffs or are in the process of evaluating the imposition of tariffs on solar panels, solar cells, polysilicon, and potentially other components. These and any other tariffs or similar taxes or duties may increase the price of our solar products and adversely affect our cost reduction roadmap, which could harm our results of operations and financial condition. Any new regulations or policies pertaining to our solar power

22

Table of Contents


products may result in significant additional expenses to us, our resellers and our resellers’ customers, which could cause a significant reduction in demand for our solar power products.
As owners and operators of solar power systems that deliver electricity to the grid, certain of our affiliated entities may be considered public utilities for purposes of the Federal Power Act, as amended (the “FPA”), and are subject to regulation by the Federal Energy Regulatory Commission (“FERC”), as well as various local and state regulatory bodies.

Although we are not directly subject to FERC regulation under the FPA, we are considered to be a “holding company” for purposes of Section 203 of the FPA, which regulates certain transactions involving public utilities, and such regulation could adversely affect our ability to grow the business through acquisitions. Likewise, investors seeking to acquire our public utility subsidiaries or acquire ownership interests in their securities may require prior FERC approval to do so. Such approval could result in transaction delays or uncertainties.

Public utilities under the FPA are required to obtain FERC acceptance of their rate schedules for wholesale sales of electricity and to comply with various regulations. FERC may grant our affiliated entities the authority to sell electricity at market-based rates and may also grant them certain regulatory waivers, such as waivers from compliance with FERC’s accounting regulations. These FERC orders reserve the right to revoke or revise market-based sales authority if FERC subsequently determines that our affiliated entities can exercise market power in the sale of generation products, the provision of transmission services, or if it finds that any of the entities can create barriers to entry by competitors. In addition, if the entities fail to comply with certain reporting obligations, FERC may revoke their power sales tariffs. Finally, if the entities were deemed to have engaged in manipulative or deceptive practices concerning their power sales transactions, they would be subject to potential fines, disgorgement of profits, and/or suspension or revocation of their market-based rate authority. If our affiliated entities were to lose their market-based rate authority, such companies would be required to obtain FERC’s acceptance of a cost-of-service rate schedule and could become subject to the accounting, record-keeping, and reporting requirements that are imposed on utilities with cost-based rate schedules, which would impose cost and compliance burdens on us and have an adverse effect on our results of operations. In addition to the risks described above, we may be subject to additional regulatory regimes at state or foreign levels to the extent we own and operate solar power systems in such jurisdictions.

As our sales to residential customers have continued to grow, we have increasingly become subject to substantial financing and consumer protection laws and regulations.

As we continue to seek to expand our retail customer base, our activities with customers – and in particular, our financing activities with our residential customers – are subject to consumer protection laws that may not be applicable to our commercial and power plant segments, such as federal truth-in-lending, consumer leasing, and equal credit opportunity laws and regulations, as well as state and local finance laws and regulations. Claims arising out of actual or alleged violations of law may be asserted against us by individuals or governmental entities and may expose us to significant damages or other penalties, including fines.
We may incur unexpected warranty and product liability claims that could materially and adversely affect our financial condition and results of operations.

Our current standard product warranty for our solar panels and their components includes a 25-year warranty period for defects in materials and workmanship and for greater than promised declines in power performance. We believe our warranty offering is in line with industry practice. This long warranty period creates a risk of extensive warranty claims long after we have shipped product and recognized revenue. We perform accelerated lifecycle testing that exposes our products to extreme stress and climate conditions in both environmental simulation chambers and in actual field deployments in order to highlight potential failures that could occur over the 25-year warranty period. We also employ measurement tools and algorithms intended to help us assess actual and expected performance; these attempt to compare actual performance against an expected performance baseline that is intended to account for many factors (like weather) that can affect performance. Although we conduct accelerated testing of our solar panels and components, they have not and cannot be tested in an environment that exactly simulates the 25-year warranty period and it is difficult to test for all conditions that may occur in the field. Further, there can be no assurance that our efforts to accurately measure and predict panel and component performance will be successful. Although we have not faced any material warranty claims to date, we have sold products under our warranties since the early 2000s and have therefore not experienced the full warranty cycle.
In our project installations, our current standard warranty for our solar power systems differs by geography and end-customer application and usually includes a limited warranty of 10 years for defects in workmanship, after which the customer may typically extend the period covered by its warranty for an additional fee. We also typically provide a system output

23

Table of Contents


performance warranty, separate from our standard solar panel product warranty, to customers that have subscribed to our post-installation O&M services. The long warranty period and nature of the warranties create a risk of extensive warranty claims long after we have completed a project and recognized revenues. Warranty and product liability claims may also result from defects or quality issues in certain technology and components (whether manufactured by us or third parties) that we incorporate into our solar power systems, such as solar cells, panels, inverters, and microinverters, over which we may have little or no control. See also “-Risks Related to Our Supply Chain-We will continue to be dependent on a limited number of third-party suppliers for certain raw materials and components for our products, which could prevent us from delivering our products to our customers within required timeframes and could in turn result in sales and installation delays, cancellations, penalty payments and loss of market share.” While we generally pass through to our customers manufacturer warranties we receive from our suppliers, in some circumstances, we may be responsible for repairing or replacing defective parts during our warranty period, often including those covered by manufacturers’ warranties, or incur other non-warranty costs. If a manufacturer disputes or otherwise fails to honor its warranty obligations, we may be required to incur substantial costs before we are compensated, if at all, by the manufacturer. Furthermore, our warranties may exceed the period of any warranties from our suppliers covering components, such as third-party solar cells, third-party panels and third-party inverters, included in our systems. In addition, manufacturer warranties may not fully compensate us for losses associated with third-party claims caused by defects or quality issues in their products. For example, most manufacturer warranties exclude certain losses that may result from a system component’s failure or defect, such as the cost of de-installation, re-installation, shipping, lost electricity, lost renewable energy credits or other solar incentives, personal injury, property damage, and other losses. In certain cases the direct warranty coverage we provide to our customers, and therefore our financial exposure, may exceed our recourse available against cell, panel or other manufacturers for defects in their products. In addition, in the event we seek recourse through warranties, we will also be dependent on the creditworthiness and continued existence of the suppliers to our business. In the past, certain of our suppliers have entered bankruptcy and our likelihood of a successful warranty claim against such suppliers is minimal.
Increases in the defect rate of SunPower or third-party products, including components, could cause us to increase the amount of warranty reserves and have a corresponding material, negative impact on our results of operations. Further, potential future product or component failures could cause us to incur substantial expense to repair or replace defective products or components, and we have agreed in some circumstances to indemnify our customers and our distributors against liability from some defects in our solar products. A successful indemnification claim against us could require us to make significant damage payments. Repair and replacement costs, as well as successful indemnification claims, could materially and negatively impact our financial condition and results of operations.
Like other retailers, distributors and manufacturers of products that are used by customers, we face an inherent risk of exposure to product liability claims in the event that the use of the solar power products into which solar cells, solar panels, and microinverters are incorporated results in injury, property damage or other damages. We may be subject to warranty and product liability claims in the event that our solar power systems fail to perform as expected or if a failure of our solar power systems or any component thereof results, or is alleged to result, in bodily injury, property damage or other damages. Since our solar power products are electricity-producing devices, it is possible that our systems could result in injury, whether by product malfunctions, defects, improper installation or other causes. In addition, since we only began selling our solar cells and solar panels in the early 2000s and the products we are developing incorporate new technologies and use new installation methods, we cannot predict the extent to which product liability claims may be brought against us in the future or the effect of any resulting negative publicity on our business. Moreover, we may not have adequate resources to satisfy a successful claim against us. We rely on our general liability insurance to cover product liability claims. A successful warranty or product liability claim against us that is not covered by insurance or is in excess of our available insurance limits could require us to make significant payments of damages. In addition, quality issues can have various other ramifications, including delays in the recognition of revenue, loss of revenue, loss of future sales opportunities, increased costs associated with repairing or replacing products, and a negative impact on our goodwill and reputation, any of which could adversely affect our business, operating results and financial condition.

Revenues from a limited number of customers and large projects are expected to continue to comprise a significant portion of our total revenues and any decrease in revenues from those customers or projects, payment of liquidated damages, or an increase in related expenses, could have a material adverse effect on our business, results of operations and financial condition.

Even though over the long term we expect our customer base and number of large projects to expand and our revenue streams to diversify, a substantial portion of our revenues will continue to depend on sales to a limited number of customers as well as construction of a limited number of large projects, and the loss or delay of sales to, or construction of, or inability to collect from those customers or for those projects, or an increase in expenses (such as financing costs) related to any such large projects, would have a significant negative impact on our business. In fiscal 2016, our top customer accounted for 15% of our

24

Table of Contents


total revenue. These larger projects create concentrated operating and financial risks. The effect of recognizing revenue or other financial measures on the sale of a larger project, or the failure to recognize revenue or other financial measures as anticipated in a given reporting period because a project is not yet completed under applicable accounting rules by period end, may materially affect our financial results. In addition, if construction, warranty or operational challenges arise on a larger project, or if the timing of such a project unexpectedly changes for other reasons, our financial results could be materially, adversely affected. Our agreements for such projects may be cancelled or we may incur large liquidated damages if we fail to execute the projects as planned, obtain certain approvals or consents by a specified time, meet certain product and project specifications, or if we materially breach the governing agreements, or in the event of a customer’s or project entity’s bankruptcy, our customers may seek to cancel or renegotiate the terms of current agreements or renewals. In addition, the failure by any significant customer to make payments when due, whether due to liquidity issues, failure of anticipated government support or otherwise, could materially adversely affect our business, results of operations and financial condition.
We do not typically maintain long-term agreements with our customers and accordingly we could lose customers without warning, which could adversely affect our operating results.

Our product sales to residential dealers and components customers typically are not made under long-term agreements. We often contract to construct or sell large projects with no assurance of repeat business from the same customers in the future. Although we believe that cancellations on our purchase orders to date have been infrequent, our customers may cancel or reschedule purchase orders with us on relatively short notice. Cancellations or rescheduling of customer orders could result in the delay or loss of anticipated sales without allowing us sufficient time to reduce, or delay the incurrence of, our corresponding inventory and operating expenses. In addition, changes in forecasts or the timing of orders from these or other customers expose us to the risks of inventory shortages or excess inventory. These circumstances, in addition to the completion and non-repetition of large projects, declining average selling prices, changes in the relative mix of sales of solar equipment versus solar project installations, and the fact that our supply agreements are generally long-term in nature and many of our other operating costs are fixed, could cause our operating results to fluctuate and may result in a material adverse effect in our business, results of operations, and financial condition. In addition, since we rely partly on our network of international dealers for marketing and other promotional programs, if our dealers fail to perform up to our standards, our operating results could be adversely affected.
Our business could be adversely affected by seasonal trends and construction cycles.

Our business is subject to significant industry-specific seasonal fluctuations. Our sales have historically reflected these seasonal trends, with the largest percentage of our total revenues realized during the second half of each fiscal year. There are various reasons for this seasonality, mostly related to economic incentives and weather patterns. For example, in European countries with feed-in tariffs, the construction of solar power systems may be concentrated during the second half of the calendar year, largely due to the annual reduction of the applicable minimum feed-in tariff and the fact that the coldest winter months in the Northern Hemisphere are January through March. In the United States, many customers make purchasing decisions towards the end of the year in order to take advantage of tax credits. In addition, sales in the new home development market are often tied to construction market demands, which tend to follow national trends in construction, including declining sales during cold weather months.
The competitive environment in which we operate often requires us to undertake customer obligations, which may turn out to be costlier than anticipated and, in turn, materially and adversely affect our business, results of operations and financial condition.

We are often required, as a condition of financing or at the request of our end customer, to undertake certain obligations such as:
system output performance warranties;
system maintenance;
penalty payments or customer termination rights if the system we are constructing is not commissioned within specified timeframes or other construction milestones are not achieved;
guarantees of certain minimum residual value of the system at specified future dates;
system put-rights whereby we could be required to buy back a customer’s system at fair value on a future date if certain minimum performance thresholds are not met; and
indemnification against losses customers may suffer as a result of reductions in benefits received under the solar commercial investment tax credit (“ITC”) under Section 48(c) of the Internal Revenue Code of 1986, as amended (the "Code"), and Treasury grant programs under Section 1603 of the American Recovery and Reinvestment Act (the “Cash Grant”).

25

Table of Contents



Such financing arrangements and customer obligations involve complex accounting analyses and judgments regarding the timing of revenue and expense recognition, and in certain situations these factors may require us to defer revenue or profit recognition until projects are completed or until contingencies are resolved, which could adversely affect our revenues and profits in a particular period.
Risks Related to Our Liquidity

We may be unable to generate sufficient cash flows or obtain access to external financing necessary to fund our operations and make adequate capital investments as planned due to the general economic environment and the continued market pressure driving down the average selling prices of our solar power products, among other factors.

To develop new products, support future growth, achieve operating efficiencies, and maintain product quality, we must make significant capital investments in manufacturing technology, facilities and capital equipment, research and development, and product and process technology. We also anticipate increased costs as we make advance payments for raw materials or pay to procure such materials (especially polysilicon), increase our sales and marketing efforts, invest in joint ventures and acquisitions, invest in our residential lease business, and continue our research and development. Our manufacturing and assembly activities have required and will continue to require significant investment of capital and substantial engineering expenditures. In addition, we expect to invest a significant amount of capital to develop solar power systems and plants for sale to customers. Developing and constructing solar power plants requires significant time and substantial initial investments. The delayed disposition of such projects, or the inability to realize the full anticipated value of such projects on disposition, could have a negative impact on our liquidity. See under this section, “Risks Related to Our Operations - Project development or construction activities may not be successful and we may make significant investments without first obtaining project financing, which could increase our costs and impair our ability to recover our investments.” See also under this section, “Risks Related to Our Sales Channels - A limited number of customers and large projects are expected to continue to comprise a significant portion of our revenues and any decrease in revenues from those customers or projects, payment of liquidated damages, or an increase in related expenses, could have a material adverse effect on our business, results of operations and financial condition.”
Our capital expenditures and use of working capital may be greater than we anticipate if we decide to make additional investments in the development and construction of solar power plants, or if sales of power plants and associated receipt of cash proceeds is delayed, or if we decide to accelerate increases in our manufacturing capacity internally or through capital contributions to joint ventures. In addition, we could in the future make additional investments in certain of our joint ventures or could guarantee certain financial obligations of our joint ventures, which could reduce our cash flows, increase our indebtedness and expose us to the credit risk of our joint venture partners. In addition, if our financial results or operating plans deviate from our current assumptions, we may not have sufficient resources to support our business plan. See under this section, “Risks Related to Our Liquidity - We have a significant amount of debt outstanding. Our substantial indebtedness and other contractual commitments could adversely affect our business, financial condition and results of operations, as well as our ability to meet our payment obligations under our debentures and our other debt.”
Certain of our customers also require performance bonds issued by a bonding agency, or bank guarantees or letters of credit issued by financial institutions, which are returned to us upon satisfaction of contractual requirements. If there is a contractual dispute with the customer, the customer may withhold the security or make a draw under the security, which could have an adverse impact on our liquidity. Our uncollateralized letter of credit facility with Deutsche Bank, as of January 1, 2017, had an outstanding amount of $45.8 million. Our bilateral letter of credit agreements with The Bank of Tokyo-Mitsubishi UFJ, Ltd. (“BTMU”), Credit Agricole, and HSBC Bank USA, National Association, which as of January 1, 2017 had an outstanding amount of $244.8 million, are guaranteed by Total S.A. pursuant to the Credit Support Agreement between us and Total S.A. dated June 29, 2016 (the “Credit Support Agreement”). Any draws under these uncollateralized facilities would require us to immediately reimburse the bank for the drawn amount. A default under the Credit Support Agreement or the guaranteed letter of credit facility, or the acceleration of our other indebtedness greater than $25 million, could cause Total S.A. to declare all amounts due and payable to Total S.A. and direct the bank to cease issuing additional letters of credit on our behalf, which could have a material adverse effect on our operations.
In addition, the Credit Support Agreement will terminate as of December 2018 by its terms, and we may be unable to find adequate credit support in replacement, on acceptable terms or at all. In such case, our ability to obtain adequate amounts of debt financing, through our letter of credit facility or otherwise, may be harmed.
We manage our working capital requirements and fund our committed capital expenditures, including the development and construction of our planned solar power plants, through our current cash and cash equivalents, cash generated from

26

Table of Contents


operations, and funds available under our revolving credit facilities with (i) Credit Agricole Corporate and Investment Bank (“Credit Agricole”) and (ii) Mizuho Bank Ltd. and Goldman Sachs Bank USA (the “Construction Revolver”). On February 17, 2016, we entered into an amendment to the credit agreement with Credit Agricole, expanding our available borrowings under the revolving credit facility to $300 million and adding a $200.0 million letter of credit subfacility, subject to the satisfaction of certain conditions. As of January 1, 2017, $295.3 million remained undrawn under our revolving credit facility with Credit Agricole, with the utilized portion of the facility pertaining to outstanding letters of credit that are fully cash collateralized; however, we are currently not in compliance with the covenant for the Credit Agricole credit facility that requires the ratio that our debt at the end of each quarter to our EBITDA for the last twelve months, as defined, to not exceed 4.5 to 1. We are not in default with Credit Agricole; however, we may not draw on the facility without collateralizing additional future borrowings with cash. We expect to not be in compliance with the aforementioned financial ratio covenant for the Credit Agricole credit facility for at least the remainder of fiscal 2017, which will affect the availability of borrowings under the line, if not remedied. As of January 1, 2017, we had $189.5 million available under the Construction Revolver.
The lenders under our credit facilities and holders of our debentures may also require us to repay our indebtedness to them in the event that our obligations under other indebtedness or contracts in excess of the applicable threshold amount, are accelerated and we fail to discharge such obligations. If our capital resources are insufficient to satisfy our liquidity requirements, for example, due to cross acceleration of indebtedness, we may seek to sell additional equity securities or debt securities or obtain other debt financings. Market conditions, however, could limit our ability to raise capital by issuing new equity or debt securities on acceptable terms, and lenders may be unwilling to lend funds on acceptable terms. The sale of additional equity securities or convertible debt securities may result in additional dilution to our stockholders. Additional debt would result in increased expenses and could impose new restrictive covenants that may be different from those restrictions contained in the covenants under certain of our current debt agreements and debentures. Financing arrangements, including project financing for our solar power plants and letters of credit facilities, may not be available to us, or may not be available in amounts or on terms acceptable to us. If additional financing is not available, we may be forced to seek to sell assets or reduce or delay capital investments, any of which could adversely affect our business, results of operations and financial condition.
If we cannot generate sufficient cash flows, find other sources of capital to fund our operations and solar power plant projects, make adequate capital investments to remain technologically and price competitive, or provide bonding or letters of credit required by our projects, we may need to sell additional equity securities or debt securities, or obtain other debt financings. If adequate funds from these or and other sources are not available on acceptable terms, our ability to fund our operations, develop and construct solar power plants, develop and expand our manufacturing operations and distribution network, maintain our research and development efforts, provide collateral for our projects, meet our debt service obligations, or otherwise respond to competitive pressures would be significantly impaired. Our inability to do any of the foregoing could have a material adverse effect on our business, results of operations and financial condition.
We have a significant amount of debt outstanding. Our substantial indebtedness and other contractual commitments could adversely affect our business, financial condition, and results of operations, as well as our ability to meet our payment obligations under the debentures and our other debt.

We currently have a significant amount of debt and debt service requirements. As of January 1, 2017, we had approximately $1.6 billion of outstanding debt for borrowed money.
This level of debt could have material consequences on our future operations, including:
making it more difficult for us to meet our payment and other obligations under the debentures and our other outstanding debt;
resulting in an event of default if we fail to comply with the financial and other restrictive covenants contained in our debt agreements (with certain covenants becoming more restrictive over time), which event of default could result in all or a significant portion of our debt becoming immediately due and payable;
reducing the availability of our cash flows to fund working capital, capital expenditures, project development, acquisitions and other general corporate purposes, and limiting our ability to obtain additional financing for these purposes;
subjecting us to the risk of increased sensitivity to interest rate increases on our indebtedness with variable interest rates, including borrowings under our credit agreement with Credit Agricole;
limiting our flexibility in planning for, or reacting to, and increasing our vulnerability to, changes in our business, the industry in which we operate and the general economy; and
placing us at a competitive disadvantage compared with our competitors that have less debt or have lower leverage ratios.


27

Table of Contents


In the event, expected or unexpected, that any of our joint ventures is consolidated with our financial statements, such consolidation could significantly increase our indebtedness. See also under this section, “Risks Related to Our Operations - We may in the future be required to consolidate the assets, liabilities and financial results of certain of our existing or future joint ventures, which could have an adverse impact on our financial position, gross margin and operating results.”
Our ability to meet our payment and other obligations under our debt instruments depends on our ability to generate significant cash flows, which, to some extent, is subject to general economic, financial, competitive, legislative and regulatory factors as well as other factors that are beyond our control. We cannot assure you that our business will generate cash flows from operations, or that future borrowings will be available to us under our existing or any future credit facilities or otherwise, in an amount sufficient to enable us to meet our payment obligations under our debentures and our other debt and to fund other liquidity needs. If we are unable to generate sufficient cash flows to service our debt obligations, we may need to refinance or restructure our debt, including our debentures, sell assets, reduce or delay capital investments, or seek to raise additional capital. There can be no assurance that we will be successful in any refinancing effort.
Although we are currently in compliance with the financial and other covenants contained in our debt agreements (except for the financial covenant for the Credit Agricole credit facility discussed above), we cannot assure you that we will be able to remain in compliance with such covenants in the future. We may not be able to cure future violations or obtain waivers from our creditors in order to avoid a default. An event of default under any of our debt agreements could have a material adverse effect on our liquidity, financial condition, and results of operations.
Our current tax holidays in the Philippines, Malaysia, and Switzerland have expired or will expire within the next several years, and other related international tax developments could adversely affect our results.

We benefit from income tax holiday incentives in the Philippines in accordance with our subsidiary’s registration with the Philippine Economic Zone Authority (“PEZA”), which provide that we pay no income tax in the Philippines for those operations subject to the ruling. Tax savings associated with the Philippines tax holidays were approximately $10.0 million, $21.2 million, and $8.3 million in fiscal 2016, 2015, and 2014, respectively. Our income tax holidays were granted as manufacturing lines were placed in service and have expired within this fiscal year. We have applied for extensions and renewals upon expiration; however, while we expect all approvals to be granted, we can offer no assurance that they will be. We believe that if our Philippine tax holidays are not extended or renewed, (a) gross income attributable to activities covered by our PEZA registrations will be taxed at a 5% preferential rate, and (b) our Philippine net income attributable to all other activities will be taxed at the statutory Philippine corporate income tax rate, currently 30%. An increase in our tax liability could materially and adversely affect our business, financial condition and results of operations.
We have an auxiliary company ruling in Switzerland where we sell our solar power products. The auxiliary company ruling confirmed our entitlement to a reduced effective Swiss tax rate of approximately 11.5%. Tax savings associated with this status were approximately $1.9 million, $1.6 million, and $3.5 million in fiscal 2016, 2015, and 2014, respectively. The current ruling expires in 2019. If the ruling is not renewed in 2019, Swiss income would be taxable at the full Swiss tax rate of approximately 24.2%.
We also benefit from a tax holiday granted by the Malaysian government to our former joint venture AUOSP (now our wholly-owned subsidiary, SunPower Malaysia Manufacturing Sdn. Bhd.) subject to certain hiring, capital spending, and manufacturing requirements. We postponed the construction of an additional manufacturing facility (“Fab 3B”), which resulted in failure to meet certain hiring conditions required to continue to benefit from the tax ruling. We have successfully negotiated with the Malaysian government to modify the requirements of the tax holiday; we are currently in compliance with the modified requirements of the tax holiday and we expect to remain in compliance with the updated requirements. In addition, we are currently awaiting a ruling for the extension of our tax holiday for a second five-year term (through June 30, 2021). Although we currently expect an extension to be granted, should we fail to meet certain requirements in the future and are unable to renegotiate the tax ruling further, we could be retroactively and prospectively subject to statutory tax rates and repayment of certain incentives which could negatively impact our business.
More generally, with the finalization of specific actions contained within the Organization for Economic Development and Cooperation’s (“OECD”) Base Erosion and Profit Shifting (“BEPS”) study (“Actions”), many OECD countries have acknowledged their intent to implement the Actions and update their local tax regulations. Among the considerations required by the Actions is the need for appropriate local business operational substance to justify any locally granted tax incentives, such as those described above, and that the incentives are not determined to constitute “state aid” which would invalidate the incentive. If we fail to maintain sufficient operational substance or if the countries determine the incentive regimes do not conform with the BEPS regulations being considered for implementation, adverse material economic impacts may result.

28

Table of Contents


A change in our effective tax rate can have a significant adverse impact on our business, and an adverse outcome resulting from examination of our income or other tax returns could adversely affect our results.

A number of factors may adversely affect our future effective tax rates, such as the jurisdictions in which our profits are determined to be earned and taxed; changes in the valuation of our deferred tax assets and liabilities; adjustments to estimated taxes upon finalization of various tax returns; adjustments to our interpretation of transfer pricing standards; changes in available tax credits, grants and other incentives; changes in stock-based compensation expense; the availability of loss or credit carryforwards to offset taxable income; changes in tax laws or the interpretation of such tax laws (for example, proposals for fundamental U.S. international tax reform); changes in U.S. generally accepted accounting principles ("U.S. GAAP"); expiration or the inability to renew tax rulings or tax holiday incentives; and the repatriation of non-U.S. earnings for which we have not previously provided for U.S. taxes. A change in our effective tax rate due to any of these factors may adversely affect our future results from operations.
Significant judgment is required to determine the recognition and measurement attributes prescribed in the accounting guidance for uncertainty in income taxes. The accounting guidance for uncertainty in income taxes applies to all income tax positions, including the potential recovery of previously paid taxes, which if settled unfavorably could adversely affect our provision for income taxes. In addition, we are subject to examination of our income tax returns by various tax authorities. We regularly assess the likelihood of adverse outcomes resulting from any examination to determine the adequacy of our provision for income taxes. An adverse determination of an examination could have an adverse effect on our operating results and financial condition. See “Item 8. Financial Statements and Supplementary Data–Notes to Consolidated Financial Statements–Note 12. Derivative Financial Instruments.”
Additionally, longstanding international tax norms that determine each country’s jurisdiction to tax cross-border international trade are evolving (for example, those relating to the Actions currently being undertaken by the OECD and similar actions by the G8 and G20) and the change in Administration in the U.S. may lead to further changes in (or departure from) these norms. As these and other tax laws and related regulations change, our financial results could be materially impacted. Given the unpredictability of these possible changes and their potential interdependency, it is very difficult to assess whether the overall effect of such potential tax changes would be cumulatively positive or negative for our earnings and cash flow, but such changes could adversely impact our financial results.
Our credit agreements contain covenant restrictions that may limit our ability to operate our business.

We may be unable to respond to changes in business and economic conditions, engage in transactions that might otherwise be beneficial to us, or obtain additional financing, because our debt agreements, our Credit Support Agreement with Total S.A., our Affiliation Agreement with Total, foreign exchange hedging agreements and equity derivative agreements contain, and any of our other future similar agreements may contain, covenant restrictions that limit our ability to, among other things:
incur additional debt, assume obligations in connection with letters of credit, or issue guarantees;
create liens;

make certain investments or acquisitions;

enter into transactions with our affiliates;
sell certain assets;

redeem capital stock or make other restricted payments;

declare or pay dividends or make other distributions to stockholders; and

merge or consolidate with any person.

Our ability to comply with these covenants is dependent on our future performance, which will be subject to many factors, some of which are beyond our control, including prevailing economic conditions. In addition, our failure to comply with these covenants could result in a default under our other debt instruments, which could permit the holders to accelerate such debt. If any of our debt is accelerated, we may not have sufficient funds available to repay such debt, which could materially and negatively affect our financial condition and results of operations.

29

Table of Contents


Risks Related to Our Supply Chain

We will continue to be dependent on a limited number of third-party suppliers for certain raw materials and components for our products, which could prevent us from delivering our products to our customers within required timeframes and could in turn result in sales and installation delays, cancellations, penalty payments, and loss of market share.

We rely on a limited number of third-party suppliers, including our joint ventures, for certain raw materials and components for our solar cells, panels and power systems, such as polysilicon, inverters and module material. If we fail to maintain our relationships with our suppliers or to build relationships with new suppliers, or if suppliers are unable to meet demand through industry consolidation, we may be unable to manufacture our products or our products may be available only at a higher cost or after a long delay.
To the extent the processes that our suppliers use to manufacture components are proprietary, we may be unable to obtain comparable components from alternative suppliers. In addition, the financial markets could limit our suppliers’ ability to raise capital if required to expand their production or satisfy their operating capital requirements. As a result, they could be unable to supply necessary raw materials, inventory and capital equipment which we would require to support our planned sales operations to us, which would in turn negatively impact our sales volume, profitability, and cash flows. The failure of a supplier to supply raw materials or components in a timely manner, or to supply raw materials or components that meet our quality, quantity and cost requirements, could impair our ability to manufacture our products or could increase our cost of production. If we cannot obtain substitute materials or components on a timely basis or on acceptable terms, we could be prevented from delivering our products to our customers within required timeframes.
Any such delays could result in sales and installation delays, cancellations, penalty payments or loss of revenue and market share, any of which could have a material adverse effect on our business, results of operations, and financial condition.
Our long-term, firm commitment supply agreements could result in excess or insufficient inventory, place us at a competitive disadvantage on pricing, or lead to disputes, each of which could impair our ability to meet our cost reduction roadmap, and in some circumstances may force us to take a significant accounting charge.

If our supply agreements provide insufficient inventory to meet customer demand, or if our suppliers are unable or unwilling to provide us with the contracted quantities, we may be forced to purchase additional supply at market prices, which could be greater than expected and could materially and adversely affect our results of operations. Due to the industry-wide shortage of polysilicon experienced before 2011, we purchased polysilicon that we resold to third-party ingot and wafer manufacturers who deliver wafers to us that we then use in the manufacturing of our solar cells. Without sufficient polysilicon, some of those ingot and wafer manufacturers would not have been able to produce the wafers on which we rely. We have historically entered into multiple long-term fixed supply agreements for periods of up to 10 years to match our estimated customer demand forecasts and growth strategy for the next several years. The long-term nature of these agreements, which often provide for fixed or inflation-adjusted pricing, may prevent us from benefiting from decreasing polysilicon costs, has, and may continue to, cause us to pay more at unfavorable payment terms than the current market prices and payment terms available to our competitors, and has in the past, and could again in the future, cause us to record an impairment. In the event that we have inventory in excess of short-term requirements of polysilicon, in order to reduce inventory or improve working capital, we may, and sometimes do, elect to sell such inventory in the marketplace at prices below our purchase price, thereby incurring a loss.
Additionally, because certain of these agreements are “take or pay,” if our demand for polysilicon from these suppliers were to decrease in the future, we could be required to purchase polysilicon that we do not need, resulting in either storage costs or payment for polysilicon we nevertheless choose not to accept from such suppliers. Further, we face significant, specific counterparty risk under long-term supply agreements when dealing with suppliers without a long, stable production and financial history. In the event any such supplier experiences financial difficulties or goes into bankruptcy, it could be difficult or impossible, or may require substantial time and expense, for us to recover any or all of our prepayments. Any of the foregoing could materially harm our financial condition and results of operations.

30

Table of Contents


We utilize construction loans, term loans, sale-leaseback, preferred equity, and other financing structures to fund acquisition, development, construction, and expansion of photovoltaic power plant projects in the future, and such funds may or may not continue to be available as required to further our plans. Furthermore, such project financing increases our consolidated debt and may be structurally senior to other debt such as our Credit Agricole revolving credit facility and outstanding convertible debentures.

Certain of our subsidiaries and other affiliates are separate and distinct legal entities and, except in limited circumstances, have no obligation to pay any amounts due with respect to our indebtedness or indebtedness of other subsidiaries or affiliates, and do not guarantee the payment of interest on or principal of such indebtedness. Such subsidiaries may borrow funds to finance particular projects. In the event of a default under a project financing which we do not cure, the lenders or lessors generally have rights to the power plant project and related assets. In the event of foreclosure after a default, we may not be able to retain any interest in the power plant project or other collateral supporting such financing. In addition, any such default or foreclosure may trigger cross default provisions in our other financing agreements, including our corporate debt obligations, which could materially and adversely affect our results of operations. In the event of our bankruptcy, liquidation or reorganization (or the bankruptcy, liquidation or reorganization of a subsidiary or affiliate), such subsidiaries’ or other affiliates’ creditors, including trade creditors and holders of debt issued by such subsidiaries or affiliates, will generally be entitled to payment of their claims from the assets of those subsidiaries or affiliates before any assets are made available for distribution to us or the holders of our indebtedness. As a result, holders of our corporate indebtedness will be effectively subordinated to all present and future debts and other liabilities (including trade payables) of certain of our subsidiaries. As of January 1, 2017, our subsidiaries had approximately $427.9 million in subsidiary project financing, which is effectively senior to our corporate debt, such as our Credit Agricole revolving credit facility, our 4.00% debentures due 2023, our 0.875% debentures due 2021, and our 0.75% debentures due 2018.
Risks Related to Our Operations

We have significant international activities and customers, and plan to continue these efforts, which subject us to additional business risks, including logistical complexity and political instability.

A substantial portion of our sales are made to customers outside of the United States, and a substantial portion of our supply agreements are with supply and equipment vendors located outside of the United States. We have solar cell and module production lines located at our manufacturing facilities in the Philippines, Mexico, France, and Malaysia.
Risks we face in conducting business internationally include:
multiple, conflicting and changing laws and regulations, export and import restrictions, employment laws, environmental protection, regulatory requirements, international trade agreements, and other government approvals, permits and licenses;

difficulties and costs in staffing and managing foreign operations as well as cultural differences;

potentially adverse tax consequences associated with our permanent establishment of operations in multiple countries;

relatively uncertain legal systems, including potentially limited protection for intellectual property rights, and laws, changes in the governmental incentives we rely on, regulations and policies which impose additional restrictions on the ability of foreign companies to conduct business in certain countries or otherwise place them at a competitive disadvantage in relation to domestic companies;

taxation by the U.S. of the repatriation of non-U.S. earnings taxed at rates lower than the U.S. statutory effective tax rate;

inadequate local infrastructure and developing telecommunications infrastructures;

financial risks, such as longer sales and payment cycles and greater difficulty collecting accounts receivable;

currency fluctuations, government-fixed foreign exchange rates, the effects of currency hedging activity, and the potential inability to hedge currency fluctuations;


31

Table of Contents


political and economic instability, including wars, acts of terrorism, political unrest, boycotts, curtailments of trade and other business restrictions;

trade barriers such as export requirements, tariffs, taxes and other restrictions and expenses, which could increase the prices of our products and make us less competitive in some countries; and

liabilities associated with compliance with laws (for example, the Foreign Corrupt Practices Act in the United States and similar laws outside of the United States).

We have a complex organizational structure involving many entities globally. This increases the potential impact of adverse changes in laws, rules and regulations affecting the free flow of goods and personnel, and therefore heightens some of the risks noted above. Further, this structure requires us to effectively manage our international inventory and warehouses. If we fail to do so, our shipping movements may not map with product demand and flow. Unsettled intercompany balances between entities could result, if changes in law, regulations or related interpretations occur, in adverse tax or other consequences affecting our capital structure, intercompany interest rates and legal structure. If we are unable to successfully manage any such risks, any one or more could materially and negatively affect our business, financial condition and results of operations.
If we experience interruptions in the operation of our solar cell production lines, or we are not successful in integrating and continuing to operate our newly acquired manufacturing subsidiary (the former joint venture, AUOSP, in which we acquired our partner's interest in fiscal 2016), our revenue and results of operations may be materially and adversely affected.

If our solar cell or module production lines suffer problems that cause downtime, we might be unable to meet our production targets, which would adversely affect our business. Our manufacturing activities require significant management attention, a significant capital investment and substantial engineering expenditures.
In September 2016 we completed the acquisition of 100% of the voting equity interest in our former joint venture AUOSP (now our wholly owned subsidiary). The former AUOSP constructed a manufacturing facility in Malaysia, which we call Fab 3. The success of our manufacturing operations in Malaysia and elsewhere is subject to significant risks including:
cost overruns, delays, supply shortages, equipment problems and other operating difficulties;

custom-built equipment may take longer or cost more to engineer than planned and may never operate as designed;

incorporating first-time equipment designs and technology improvements, which we expect to lower unit capital and operating costs, but which may not be successful;

our ability to obtain or maintain third party financing to fund capital requirements;

difficulties in maintaining or improving our historical yields and manufacturing efficiencies;

difficulties in protecting our intellectual property and obtaining rights to intellectual property developed by the former AUOSP or other manufacturing partners;

difficulties in hiring and retaining key technical, management, and other personnel;

difficulties in successfully or timely integrating the former AUOSP's operations with our own, or implementing IT infrastructure or an effective control environment; and

potential inability to obtain, or obtain in a timely manner, financing, or approvals from governmental authorities for operations.

Any of these or similar difficulties may unexpectedly delay or increase costs of our supply of solar cells.

32

Table of Contents


If we do not achieve satisfactory yields or quality in manufacturing our solar products, our sales could decrease and our relationships with our customers and our reputation may be harmed.

The manufacture of solar cells is a highly complex process. Minor deviations in the manufacturing process can cause substantial decreases in yield and in some cases, cause production to be suspended or yield no output. We have from time to time experienced lower than anticipated manufacturing yields. As we expand our manufacturing capacity and qualify additional suppliers, we may initially experience lower yields. If we do not achieve planned yields, our product costs could increase, and product availability would decrease resulting in lower revenues than expected. In addition, in the process of transforming polysilicon into ingots, a significant portion of the polysilicon is removed in the process. In circumstances where we provide the polysilicon, if our suppliers do not have very strong controls in place to ensure maximum recovery and utilization, our economic yield can be less than anticipated, which would increase the cost of raw materials to us.
Additionally, products as complex as ours may contain undetected errors or defects, especially when first introduced. For example, our solar cells or solar panels may contain defects that are not detected until after they are shipped or are installed because we cannot test for all possible scenarios. These defects could cause us to incur significant warranty, non-warranty, and re-engineering costs, divert the attention of our engineering personnel from product development efforts, and significantly affect our customer relations and business reputation. If we deliver solar products with errors or defects, including cells or panels of third-party manufacturers, or if there is a perception that such solar products contain errors or defects, our credibility and the market acceptance and sales of our products could be harmed. In addition, some of our arrangements with customers include termination or put rights for non-performance. In certain limited cases, we could incur liquidated damages or even be required to buy back a customer’s system at fair value on specified future dates if certain minimum performance thresholds are not met.
A change in our 1603 Treasury cash grant proceeds or solar investment tax credits could adversely affect our business, revenues, margins, results of operations and cash flows.

We have incorporated into our financial planning and agreements with our customers certain assumptions regarding the future level of U.S. tax incentives, including the ITC and Cash Grant, which is administered by the U.S. Treasury Department (“Treasury”) and provides cash grant payments in lieu of the ITC. The ITC and Cash Grant allow qualified applicants to claim an amount equal to 30% of the eligible cost basis for qualifying solar energy property. We hold projects and have sold projects to certain customers based on certain underlying assumptions regarding the ITC and Cash Grant, including for CVSR and Solar Star. We have also accounted for certain projects and programs in our business using the same assumptions.
Owners of our qualifying projects and our residential lease program have applied or will apply for the ITC, and have applied for the Cash Grant. We have structured the tax incentive applications, both in timing and amount, to be in accordance with the guidance provided by Treasury and Internal Revenue Service (“IRS”). Any changes to the Treasury or IRS guidance which we relied upon in structuring our projects, failure to comply with the requirements, including the safe harbor protocols, lower levels of incentives granted, or changes in assumptions including the estimated residual values and the estimated fair market value of financed and installed systems for the purposes of Cash Grant and ITC applications, could materially and adversely affect our business and results of operations. While all grants related to our projects have been fully paid by Treasury, if the IRS or Treasury disagrees, as a result of any future review or audit, with the fair market value of, or other assumptions concerning, our solar projects or systems that we have constructed or that we construct in the future, including the systems for which tax incentives have already been paid, it could have a material adverse effect on our business and financial condition. We also have obligations to indemnify certain of our customers for the loss of tax incentives to such customers. We may have to recognize impairments or lower margins than initially anticipated for certain of our projects or our residential lease program. Additionally, if the amount or timing of the Cash Grant or ITC payments received varies from what we have projected, our revenues, margins and cash flows could be adversely affected and we may have to recognize losses, which would have a material adverse effect on our business, results of operations and financial condition.
There are continuing developments in the interpretation and application of how companies should calculate their eligibility and level of Cash Grant and ITC incentives. There have been recent cases in the U.S. district courts that challenge the criteria for a true lease, which could impact whether the structure of our residential lease program qualifies under the Cash Grant and ITC. Additionally, the Office of the Inspector General of the Treasury has issued subpoenas to a number of significant participants in the rooftop solar energy installation industry. The Inspector General is working with the Civil Division of the U.S. Department of Justice to investigate the administration and implementation of the Cash Grant program, including potential misrepresentations concerning the fair market value of certain solar power systems submitted for Cash Grant. While we have not received a subpoena, we could be asked to participate in the information gathering process. The results of the current investigation could affect the underlying assumption used by the solar industry, including us, in our Cash

33

Table of Contents


Grant and ITC applications, which could reduce eligibility and level of incentives and could adversely affect our results of operations and cash flows.
We were notified by an investor in Section 1603 residential inverted lease structures of an IRS examination of such investor’s income tax filings. Under this structure, we transferred the cash grants to the investor pursuant to the 1603 program regulations. If the IRS redetermines the amount of the cash grant awards, the investor may be required to make corresponding adjustments to its taxable income or other changes. Such adjustments may provide us with an indication of IRS practice regarding the valuation of residential leased solar assets, and we would consider such adjustments in our accounting for our indemnification obligations to investors who receive cash grants and investment tax credits.
We obtain certain of our capital equipment used in our manufacturing process from sole suppliers and if this equipment is damaged or otherwise unavailable, our ability to deliver products on time will suffer, which in turn could result in order cancellations and loss of revenue.

Some of the capital equipment used in the manufacture of our solar power products has been developed and made specifically for us, is not readily available from multiple vendors and would be difficult to repair or replace if it were to become damaged or stop working. If any of these suppliers were to experience financial difficulties or go out of business, or if there were any damage to or a breakdown of our manufacturing equipment, our business would suffer. In addition, a supplier’s failure to supply this equipment in a timely manner, with adequate quality and on terms acceptable to us, could delay our future capacity expansion or manufacturing process improvements and otherwise disrupt our production schedule or increase our costs of production.
Project development or construction activities may not be successful, and we may make significant investments without first obtaining project financing, which could increase our costs and impair our ability to recover our investments.

The development and construction of solar power electric generation facilities and other energy infrastructure projects involve numerous risks. We may be required to spend significant sums for preliminary engineering, permitting, legal, and other expenses before we can determine whether a project is feasible, economically attractive or capable of being built. In addition, we will often choose to bear the costs of such efforts prior to obtaining project financing, prior to getting final regulatory approval, and prior to our final sale to a customer, if any.
Successful completion of a particular project may be adversely affected by numerous factors, including:
failures or delays in obtaining desired or necessary land rights, including ownership, leases and/or easements;

failures or delays in obtaining necessary permits, licenses or other governmental support or approvals, or in overcoming objections from members of the public or adjoining land owners;

uncertainties relating to land costs for projects;

unforeseen engineering problems;

access to available transmission for electricity generated by our solar power plants;

construction delays and contractor performance shortfalls;

work stoppages or labor disruptions and compliance with labor regulations;

cost over-runs;

availability of products and components from suppliers;

adverse weather conditions;

environmental, archaeological and geological conditions; and

availability of construction and permanent financing.


34

Table of Contents


If we are unable to complete the development of a solar power plant, or fail to meet one or more agreed target construction milestone dates, we may be subject to liquidated damages and/or penalties under the EPC agreement or other agreements relating to the power plant, and we typically will not be able to recover our investment in the project. We expect to invest a significant amount of capital to develop projects initially owned by us or ultimately owned by third parties. If we are unable to complete the development of a solar power project, we may write-down or write-off some or all of these capitalized investments, which would have an adverse impact on our net income in the period in which the loss is recognized.
If we cannot offer residential lease customers an attractive value proposition due to an inability to continue to monetize tax benefits in connection with our residential lease arrangements, an inability to obtain financing for our residential lease program, challenges implementing our third-party ownership model in new jurisdictions, declining costs of retail electricity or otherwise, we may be unable to continue to increase the size of our residential lease program, which could have a material, adverse effect on our business, results of operations, and financial condition.

Our residential lease program has been eligible for the ITC and Cash Grant. We have relied on, and expect to continue to rely on, financing structures that monetize a substantial portion of those benefits. If we were unable to continue to monetize the tax benefits in our financing structures or such tax benefits were reduced or eliminated, we might be unable to provide financing or pricing that is attractive to our customers. Under current law, the ITC will be reduced from approximately 30% of the cost of the solar system to approximately 26% for solar systems placed into service after December 31, 2019 and then further reduced to approximately 22% for solar systems placed into service after December 31, 2020 before being reduced permanently to 10% for commercial projects and 0% for residential projects. In addition, Cash Grants are no longer available for new solar systems.
Changes in existing law and interpretations by the IRS, Treasury and the courts could reduce the willingness of financing partners to invest in funds associated with our residential lease program. Additionally, benefits under the Cash Grant and ITC programs are tied, in part, to the fair market value of our systems, as ultimately determined by the federal agency administering the benefit program. This means that, in connection with implementing financing structures that monetize such benefits, we need to, among other things, assess the fair market value of our systems in order to arrive at an estimate of the amount of tax benefit expected to be derived from the benefit programs. We incorporate third-party valuation reports that we believe to be reliable into our methodology for assessing the fair market value of our systems, but these reports or other elements of our methodology may cause our fair market value estimates to differ from those ultimately determined by the federal agency administering the applicable benefit program. If the amount or timing of Cash Grant payments or ITC received in connection with our residential lease program varies from what we have projected, due to discrepancies in our fair value assessments or otherwise, our revenues, cash flows and margins could be adversely affected.
Additionally, if any of our financing partners that currently provide financing for our solar systems decide not to continue to provide financing due to general market conditions, changes in tax benefits associated with our solar systems, concerns about our business or prospects or any other reason, or if they materially change the terms under which they are willing to provide future financing, we will need to identify new financing partners and negotiate new financing terms.
See also “Risks Related to Our Supply Chain - A change in our anticipated 1603 Treasury cash grant proceeds or solar investment tax credit could adversely affect our business, revenues, margins, results of operations and cash flows.”
We have to quickly build infrastructure to support our residential lease program, and any failure or delay in implementing the necessary processes and infrastructure could adversely affect our financial results. We establish credit approval limits based on the credit quality of our customers. We may be unable to collect rent payments from our residential lease customers in the event they enter into bankruptcy or otherwise fail to make payments when due. If we experience higher customer default rates than we currently experience or if we lower credit rating requirements for new customers, it could be more difficult or costly to attract future financing. See also “Risks Related to Our Sales Channels - The execution of our growth strategy is dependent upon the continued availability of third-party financing arrangements for our solar power plants, our residential lease program and our customers, and is affected by general economic conditions.”
We make certain assumptions in accounting for our residential lease program, including, among others, assumptions in accounting for our residual value of the leased systems. As our residential lease program grows, if the residual value of leased systems does not materialize as assumed, it will adversely affect our results of operations. At the end of the term of the lease, our customers have the option to extend the lease and certain of those customers may either purchase the leased systems at fair market value or return them to us. Should there be a large number of returns, we may incur de-installation costs in excess of amounts reserved.

35

Table of Contents


We believe that, as with our other customers, retail electricity prices factor significantly into the value proposition of our products for our residential lease customers. If prices for retail electricity or electricity from other renewable sources decrease, our ability to offer competitive pricing in our residential lease program could be jeopardized because such decreases would make the purchase of our solar systems or the purchase of energy under our lease agreements and PPAs less economically attractive.
Our leases are third-party ownership arrangements. Sales of electricity by third parties face regulatory challenges in some states and jurisdictions. Other challenges pertain to whether third-party owned systems qualify for the same levels of rebates or other non-tax incentives available for customer-owned solar energy systems. Reductions in, or eliminations of, this treatment of these third-party arrangements could reduce demand for our residential lease program. As we look to extend the third party ownership model outside of the United States, we will be faced with the same risks and uncertainties we have in the United States. Our growth outside of the United States could depend on our ability to expand the third party ownership model, and our failure to successfully implement a third-party ownership model globally could adversely affect our financial results.
We act as the general contractor for many of our customers in connection with the installations of our solar power systems and are subject to risks associated with construction, cost overruns, delays and other contingencies tied to performance bonds and letters of credit, or other required credit and liquidity support guarantees, any of which could have a material adverse effect on our business and results of operations.

We act as the general contractor for many of our customers in connection with the installation of our solar power systems. Some customers require performance bonds issued by a bonding agency or letters of credit issued by financial institutions, or may require other forms of liquidity support. Due to the general performance risk inherent in construction activities, it has become increasingly difficult recently to attain suitable bonding agencies willing to provide performance bonding. Obtaining letters of credit may require collateral. In the event we are unable to obtain bonding or sufficient letters of credit or other liquidity support, we will be unable to bid on, or enter into, sales contracts requiring such bonding.
Almost all of our EPC contracts are fixed price contracts. We attempt to estimate all essential costs at the time of entering into the EPC contract for a particular project, and these are reflected in the overall price that we charge our customers for the project. These cost estimates are preliminary and may or may not be covered by contracts between us or the subcontractors, suppliers, and any other parties that may become necessary to complete the project. In addition, we require qualified, licensed subcontractors to install most of our systems. Thus, if the cost of materials or skilled labor were to rise dramatically, or if financing costs were to increase, our operating results could be adversely affected.
In addition, the contracts with some of our larger customers require that we would be obligated to pay substantial penalty payments for each day or other period beyond an agreed target date that a solar installation for any such customer is not completed, up to and including the return of the entire project sale price. This is particularly true in Europe, where long-term, fixed feed-in tariffs available to investors are typically set during a prescribed period of project completion, but the fixed amount declines over time for projects completed in subsequent periods. We face material financial penalties in the event we fail to meet the completion deadlines, including but not limited to a full refund of the contract price paid by the customers. In certain cases we do not control all of the events which could give rise to these penalties, such as reliance on the local utility to timely complete electrical substation construction.
Furthermore, investors often require that the solar power system generate specified levels of electricity in order to maintain their investment returns, allocating substantial risk and financial penalties to us if those levels are not achieved, up to and including the return of the entire project sale price. Also, our customers often require protections in the form of conditional payments, payment retentions or holdbacks, and similar arrangements that condition its future payments on performance. Delays in solar panel or other supply shipments, other construction delays, unexpected performance problems in electricity generation or other events could cause us to fail to meet these performance criteria, resulting in unanticipated and severe revenue and earnings losses and financial penalties. Construction delays are often caused by inclement weather, failure to timely receive necessary approvals and permits, or delays in obtaining necessary solar panels, inverters or other materials. Additionally, we sometimes purchase land in connection with project development and assume the risk of project completion. All such risks could have a material adverse effect on our business and results of operations.
Acquisitions of other companies, project development pipelines and other assets, or investments in joint ventures with other companies could materially and adversely affect our financial condition and results of operations, and dilute our stockholders’ equity.

To expand our business and maintain our competitive position, we have acquired a number of other companies and entered into several joint ventures over the past several years, including our 8point3 joint venture with First Solar, our

36

Table of Contents


acquisitions of Cogenra Solar, Inc. and Solaire Generation, Inc. in fiscal 2015, and our acquisition of 100% of the equity voting interest in AUOSP in fiscal 2016. In the future, we may acquire additional companies, project pipelines, products, or technologies or enter into joint ventures or other strategic initiatives.
Acquisitions and joint ventures involve a number of risks that could harm our business and result in the acquired business or joint venture not performing as expected, including:
insufficient experience with technologies and markets in which the acquired business or joint venture is involved, which may be necessary to successfully operate and/or integrate the business or the joint venture;

problems integrating the acquired operations, personnel, IT infrastructure, technologies or products with the existing business and products;

diversion of management time and attention from the core business to the acquired business or joint venture;

potential failure to retain or hire key technical, management, sales and other personnel of the acquired business or joint venture;

difficulties in retaining or building relationships with suppliers and customers of the acquired business or joint venture, particularly where such customers or suppliers compete with us;

potential failure of the due diligence processes to identify significant issues with product quality and development or legal and financial liabilities, among other things;

potential inability to obtain, or obtain in a timely manner, approvals from governmental authorities or work councils, which could delay or prevent acquisitions, delay our ability to achieve synergies, or our successful operation of acquired companies or joint ventures;

potential necessity to re-apply for permits of acquired projects;

problems managing joint ventures with our partners, meeting capital requirements for expansion, potential litigation with joint venture partners and reliance upon joint ventures which we do not control; for example, our ability to effectively manage 8point3 Energy Partners with First Solar;

differences in philosophy, strategy or goals with our joint venture partners;

subsequent impairment of the acquired assets, including intangible assets; and

assumption of liabilities including, but not limited to, lawsuits, tax examinations, warranty issues, environmental matters and liabilities associated with compliance with laws (for example, the FCPA).

The success of our joint venture 8point3 Energy Partners is subject to additional risks described under the risk factor “Risks Related to Our Sales Channels - We may fail to realize the expected benefits of our YieldCo strategy.”

Additionally, we may decide that it is in our best interests to enter into acquisitions or joint ventures that are dilutive to earnings per share or that negatively impact margins as a whole. In an effort to reduce our cost of goods sold, we have and may continue to enter into acquisitions or joint ventures involving suppliers or manufacturing partners, which would expose us to additional supply chain risks. Acquisitions or joint ventures could also require investment of significant financial resources and require us to obtain additional equity financing, which may dilute our stockholders’ equity, or require us to incur additional indebtedness. Such equity or debt financing may not be available on terms acceptable to us. In addition, we could in the future make additional investments in our joint ventures or guarantee certain financial obligations of our joint ventures, which could reduce our cash flows, increase our indebtedness and expose us to the credit risk of our joint ventures.
To the extent that we invest in upstream suppliers or downstream channel capabilities, we may experience competition or channel conflict with certain of our existing and potential suppliers and customers. Specifically, existing and potential suppliers and customers may perceive that we are competing directly with them by virtue of such investments and may decide to reduce or eliminate their supply volume to us or order volume from us. In particular, any supply reductions from our polysilicon, ingot or wafer suppliers could materially reduce manufacturing volume.

37

Table of Contents


Acquisitions could also result in dilutive issuances of equity securities, the use of our available cash, or the incurrence of debt, which could harm our operating results.

We may in the future be required to consolidate the assets, liabilities and financial results of certain of our existing or future joint ventures, which could have an adverse impact on our financial position, gross margin, and operating results.

The Financial Accounting Standards Board has issued accounting guidance regarding variable interest entities (“VIEs”) that affects our accounting treatment of our existing and future joint ventures. We have variable interests in 8point3 Energy Partners, our joint venture with First Solar. To ascertain whether we are required to consolidate this entity, we determine whether it is a VIE and if we are the primary beneficiary in accordance with the accounting guidance. Factors we consider in determining whether we are the VIE’s primary beneficiary include the decision making authority of each partner, which partner manages the day-to-day operations of the joint venture and each partner’s obligation to absorb losses or right to receive benefits from the joint venture in relation to that of the other partner. Changes in the financial accounting guidance, or changes in circumstances at each of these joint ventures, could lead us to determine that we have to consolidate the assets, liabilities and financial results of such joint ventures. The consolidation of 8point3 Energy Partners would significantly increase our indebtedness. Consolidation of our VIEs could have a material adverse impact on our financial position, gross margin and operating results. In addition, we may enter into future joint ventures or make other equity investments, which could have an adverse impact on us because of the financial accounting guidance regarding VIEs.
Fluctuations in the demand for our products may cause impairment of our project assets and other long-lived assets or cause us to write off equipment or inventory, and each of these events would adversely affect our financial results.

We have tangible project assets on our Consolidated Balance Sheets related to capitalized costs incurred in connection with the development of solar power systems. Project assets consist primarily of capitalized costs relating to solar power system projects in various stages of development that we incur prior to the sale of the solar power system to a third party. These costs include costs for land and costs for developing and constructing a solar power system. These project assets could become impaired if there are changes in the fair value of these capitalized costs. If these project assets become impaired, we may write-off some or all of the capitalized project assets, which would have an adverse impact on our financial results in the period in which the loss is recognized.
In addition, if the demand for our solar products decreases, our manufacturing capacity could be underutilized, and we may be required to record an impairment of our long-lived assets, including facilities and equipment, which would increase our expenses. In improving our manufacturing processes consistent with our cost reduction roadmap, we could write off equipment that is removed from the manufacturing process. In addition, if product demand decreases or we fail to forecast demand accurately, we could be required to write off inventory or record excess capacity charges, which would have a negative impact on our gross margin. Factory-planning decisions may shorten the useful lives of long-lived assets, including facilities and equipment, and cause us to accelerate depreciation. Each of the above events would adversely affect our future financial results.
We may not be able to sustain our recent growth rate, and we may not be able to manage our future growth effectively.

We may not be able to continue to expand our business or manage future growth. We plan to continue to improve our manufacturing processes and build additional manufacturing production over the next five years, which will require successful execution of:
expanding our existing manufacturing facilities and developing new manufacturing facilities, which would increase our fixed costs and, if such facilities are underutilized, would negatively impact our results of operations;

ensuring delivery of adequate polysilicon, ingots, and third-party cells;

enhancing our customer resource management and manufacturing management systems;

implementing and improving additional and existing administrative, financial and operations systems, procedures and controls, including the need to centralize, update and integrate our global financial internal control;

hiring additional employees;

expanding and upgrading our technological capabilities;

managing multiple relationships with our customers, suppliers and other third parties;

38

Table of Contents



maintaining adequate liquidity and financial resources; and

continuing to increase our revenues from operations.

Improving our manufacturing processes, expanding our manufacturing facilities or developing new facilities may be delayed by difficulties such as unavailability of equipment or supplies or equipment malfunction. Ensuring delivery of adequate polysilicon, ingots, and third-party cells is subject to many market risks including scarcity, significant price fluctuations and competition. Maintaining adequate liquidity is dependent upon a variety of factors including continued revenues from operations, working capital improvements, and compliance with our indentures and credit agreements. If we are unsuccessful in any of these areas, we may not be able to achieve our growth strategy and increase production capacity as planned during the foreseeable future. In addition, we need to manage our organizational growth, including rationalizing reporting structures, support teams, and enabling efficient decision making. For example, the administration of the residential lease program requires processes and systems to support this business model. If we are not successful or if we delay our continuing implementation of such systems and processes, we may adversely affect the anticipated volumes in our residential lease business. If we are unable to manage our growth effectively, we may not be able to take advantage of market opportunities, develop new solar cells and other products, satisfy customer requirements, execute our business plan, or respond to competitive pressures.
Fluctuations in foreign currency exchange rates and interest rates could adversely affect our business and results of operations.

We have significant sales globally, and we are exposed to movements in foreign exchange rates, primarily related to sales to European customers that are denominated in Euros. A depreciation of the Euro would adversely affect our margins on sales to European customers. When foreign currencies appreciate against the U.S. dollar, inventories and expenses denominated in foreign currencies become more expensive. An increase in the value of the U.S. dollar relative to foreign currencies could make our solar power products more expensive for international customers, thus potentially leading to a reduction in demand, our sales and profitability. As a result, substantial unfavorable changes in foreign currency exchange rates could have a substantial adverse effect on our financial condition and results of operations. Although we seek to reduce our currency exposure by engaging in hedging transactions where we deem it appropriate, we do not know whether our efforts will be successful. Because we hedge some of our expected future foreign exchange exposure, if associated revenues do not materialize, we could experience losses. In the past, we have experienced an adverse impact on our revenue, gross margin, cash position and profitability as a result of foreign currency fluctuations. In addition, any break-up of the Eurozone would disrupt our sales and supply chain, expose us to financial counterparty risk, and materially and adversely affect our results of operations and financial condition.
We are exposed to interest rate risk because many of our customers depend on debt financing to purchase our solar power systems. An increase in interest rates could make it difficult for our customers to obtain the financing necessary to purchase our solar power systems on favorable terms, or at all, and thus lower demand for our solar power products, reduce revenue and adversely affect our operating results. An increase in interest rates could lower a customer’s return on investment in a system or make alternative investments more attractive relative to solar power systems, which, in each case, could cause our customers to seek alternative investments that promise higher returns or demand higher returns from our solar power systems, which could reduce our revenue and gross margin and adversely affect our operating results. Our interest expense would increase to the extent interest rates rise in connection with our variable interest rate borrowings. Conversely, lower interest rates have an adverse impact on our interest income. See also "Item 7A. Quantitative and Qualitative Disclosures About Market Risk" and “Risks Related to Our Sales Channels-The execution of our growth strategy is dependent upon the continued availability of third-party financing arrangements for our solar power plants, our residential lease program and our customers, and is affected by general economic conditions.”
We depend on third-party contract manufacturers to assemble a portion of our solar cells into solar panels and any failure to obtain sufficient assembly and test capacity could significantly delay our ability to ship our solar panels and damage our customer relationships.

We outsource a portion of module manufacturing to contract manufacturers in China. As a result of outsourcing this final step in our production, we face several significant risks, including limited control over assembly and testing capacity, delivery schedules, quality assurance, manufacturing yields and production costs. If the operations of our third-party contract manufacturers were disrupted or their financial stability impaired, or if they were unable or unwilling to devote capacity to our solar panels in a timely manner, our business could suffer as we might be unable to produce finished solar panels on a timely basis. We also risk customer delays resulting from an inability to move module production to an alternate provider or to

39

Table of Contents


complete production internationally, and it may not be possible to obtain sufficient capacity or comparable production costs at another facility in a timely manner. In addition, migrating our design methodology to third-party contract manufacturers or to a captive panel assembly facility could involve increased costs, resources and development time, and utilizing additional third-party contract manufacturers could expose us to further risk of losing control over our intellectual property and the quality of our solar panels. Any reduction in the supply of solar panels could impair our revenue by significantly delaying our ability to ship products and potentially damage our relationships with new and existing customers, any of which could have a material and adverse effect on our financial condition and results of operation.
While we believe we currently have effective internal control over financial reporting, we may identify a material weakness in our internal control over financial reporting that could cause investors to lose confidence in the reliability of our financial statements and result in a decrease in the value of our common stock.

Our management is responsible for maintaining internal control over financial reporting designed to provide reasonable assurance regarding the reliability of financial reporting and the preparation of consolidated financial statements for external purposes in accordance with U.S. GAAP. Management concluded that as of the end of each of fiscal 2016, 2015, and 2014, our internal control over financial reporting and our disclosure controls and procedures were effective.
We need to continuously maintain our internal control processes and systems and adapt them as our business grows and changes. This process is expensive, time-consuming, and requires significant management attention. We cannot be certain that our internal control measures will continue to provide adequate control over our financial processes and reporting and ensure compliance with Section 404 of the Sarbanes-Oxley Act. Furthermore, as we grow our business or acquire other businesses, our internal controls may become more complex and we may require significantly more resources to ensure they remain effective. Failure to implement required new or improved controls, or difficulties encountered in their implementation, either in our existing business or in businesses that we may acquire, could harm our operating results or cause us to fail to meet our reporting obligations. If we or our independent registered public accounting firm identify material weaknesses in our internal controls, the disclosure of that fact, even if quickly remedied, may cause investors to lose confidence in our financial statements and the trading price of our common stock may decline.
Remediation of a material weakness could require us to incur significant expense and if we fail to remedy any material weakness, our financial statements may be inaccurate, our ability to report our financial results on a timely and accurate basis may be adversely affected, our access to the capital markets may be restricted, the trading price of our common stock may decline, and we may be subject to sanctions or investigation by regulatory authorities, including the Securities and Exchange Commission ("SEC") or The NASDAQ Global Select Market. We may also be required to restate our financial statements from prior periods.
Our agreements with Cypress Semiconductor Corporation (“Cypress”) require us to indemnify Cypress for certain tax liabilities. These indemnification obligations and related contractual restrictions may limit our ability to pursue certain business initiatives.

On October 6, 2005, while a subsidiary of Cypress, our former parent company, we entered into a tax sharing agreement with Cypress providing for each party’s obligations concerning various tax liabilities. The tax sharing agreement is structured such that Cypress would pay all federal, state, local and foreign taxes that are calculated on a consolidated or combined basis while we were a member of Cypress’s consolidated or combined group for federal, state, local and foreign tax purposes. Our portion of tax liabilities or benefits was determined based upon our separate return tax liability as defined under the tax sharing agreement. These tax liabilities or benefits were based on a pro forma calculation as if we were filing a separate income tax return in each jurisdiction, rather than on a combined or consolidated basis, subject to adjustments as set forth in the tax sharing agreement.
On June 6, 2006, we ceased to be a member of Cypress’s consolidated group for federal income tax purposes and certain state income tax purposes. On September 29, 2008, we ceased to be a member of Cypress’s combined group for all state income tax purposes. To the extent that we become entitled to utilize our separate portion of any tax credit or loss carryforwards existing as of such date, we will distribute to Cypress the tax effect, estimated to be 40% for federal and state income tax purposes, of the amount of such tax loss carryforwards so utilized, and the amount of any credit carryforwards so utilized. We will distribute these amounts to Cypress in cash or in our shares, at Cypress’s option. During fiscal 2015 and fiscal 2016, we recorded an estimated liability to Cypress of $3.5 million and $0.2 million, respectively. As of January 1, 2017, we believe there is no additional future liability.
We are jointly and severally liable for any tax liability during all periods in which we were deemed to be a member of the Cypress consolidated or combined group. Accordingly, although the tax sharing agreement allocates tax liabilities between

40

Table of Contents


Cypress and all its consolidated subsidiaries, for any period in which we were included in Cypress’s consolidated or combined group, we could be liable in the event that any federal or state tax liability was incurred, but not discharged, by any other member of the group.
We will continue to be jointly and severally liable to Cypress until the statute of limitations runs or all appeal options are exercised for all years in which we joined in the filing of tax returns with Cypress. If Cypress experiences adjustments to their tax liability pursuant to tax examinations, we may incur an incremental liability.
We would also be liable to Cypress for taxes that might arise from the distribution by Cypress of our former class B common stock to Cypress’s stockholders on September 29, 2008, or “spin-off.” In connection with Cypress’s spin-off of our former class B common stock, we and Cypress, on August 12, 2008, entered into an amendment to our tax sharing agreement (“Amended Tax Sharing Agreement”) to address certain transactions that may affect the tax treatment of the spin-off and certain other matters.
Subject to certain caveats, Cypress obtained a ruling from the IRS to the effect that the distribution by Cypress of our former class B common stock to Cypress’s stockholders qualified as a tax-free distribution under Section 355 of the Code. Despite such ruling, the distribution may nonetheless be taxable to Cypress under Section 355(e) of the Code if 50% or more of the voting power or value of our stock was or is later acquired as part of a plan or series of related transactions that included the distribution of our stock. The Amended Tax Sharing Agreement requires us to indemnify Cypress for any liability incurred as a result of issuances or dispositions of our stock after the distribution, other than liability attributable to certain dispositions of our stock by Cypress, that cause Cypress’s distribution of shares of our stock to its stockholders to be taxable to Cypress under Section 355(e) of the Code.
Under the Amended Tax Sharing Agreement, we also agreed that, until October 29, 2010, we would not effect a conversion of any or all of our former class B common stock to former class A common stock or any similar recapitalization transaction or series of related transactions. On November 16, 2011, we reclassified our former class A common stock and class B common stock into a single class of common stock. In the event this reclassification does result in the spin-off being treated as taxable, we could face substantial liabilities as a result of our obligations under the Amended Tax Sharing Agreement.
Our affiliation with Total S.A. may require us to join in certain tax filings with Total S.A. in the future. The allocation of tax liabilities between us and Total S.A., and any future agreements with Total S.A. regarding tax indemnification and certain tax liabilities may adversely affect our financial position.

We have not joined in tax filings on a consolidated, combined or unitary basis with Total S.A., and no tax sharing agreement is currently in place. We may in the future become required to join in certain tax filings with Total S.A. on a consolidated, combined, or unitary basis in certain jurisdictions, at which point we may seek to enter into a tax sharing agreement with Total S.A., which would allocate the tax liabilities among the parties. The entry into any future agreement with Total S.A. may result in less favorable allocation of certain liabilities than we experienced before becoming subject to consolidated, combined, or unitary filing requirements, and may adversely affect our financial position.
Our ability to use our net operating loss and credit carryforwards to offset future taxable income may be subject to certain limitations.

As of January 1, 2017, we estimate that we have available to offset future taxable income approximately $480 million of federal and $438.5 million of California state operating loss carry-forwards, which expire at various dates from 2028 to 2036, federal credit carryforwards of approximately $54.3 million, which expire at various dates from 2018 to 2036, and $7.5 million of California state credit carryforwards that do not expire. Our ability to utilize our net operating loss and credit carryforwards is dependent upon our ability to generate taxable income in future periods and may be limited due to restrictions imposed on utilization of net operating loss and credit carryforwards under federal and state laws upon a change in ownership, such as the transaction with Cypress.
Section 382 of the Code imposes restrictions on the use of a corporation’s net operating losses, as well as certain recognized built-in losses and other carryforwards, after an “ownership change” occurs. A Section 382 “ownership change” occurs if one or more stockholders or groups of stockholders who own at least 5% of our stock increase their ownership by more than 50 percentage points over their lowest ownership percentage within the prior three-year period (calculated on a rolling basis). The issuance of common stock upon a conversion of our outstanding convertible notes debentures, and/or other issuances or sales of our stock (including certain transactions involving our stock that are outside of our control) could result in (or could have resulted in) an ownership change under Section 382. If an “ownership change” occurs, Section 382 would impose an annual limit on the amount of pre-change net operating losses and other losses we can use to reduce our taxable

41

Table of Contents


income generally equal to the product of the total value of our outstanding equity immediately prior to the “ownership change” and the applicable federal long-term tax-exempt interest rate for the month of the “ownership change” (subject to certain adjustments). The applicable rate for ownership changes occurring in the month of February 2016 is 2.65%.
Because U.S. federal net operating losses generally may be carried forward for up to 20 years, the annual limitation may effectively provide a cap on the cumulative amount of pre-ownership change losses, including certain recognized built-in losses that may be utilized. Such pre-ownership change losses in excess of the cap may be lost. In addition, if an ownership change were to occur, it is possible that the limitations imposed on our ability to use pre-ownership change losses and certain recognized built-in losses could cause a net increase in our U.S. federal income tax liability and require U.S. federal income taxes to be paid earlier than otherwise would be paid if such limitations were not in effect. Further, if for financial reporting purposes the amount or value of these deferred tax assets is reduced, such reduction would have a negative impact on the book value of our common stock.
Our headquarters and manufacturing facilities, as well as the facilities of certain subcontractors and suppliers, are located in regions that are subject to earthquakes, floods, and other natural disasters, and climate change and climate change regulation could have an adverse effect on our operations.

Our headquarters and research and development operations are located in California, and our manufacturing facilities are located in the Philippines, Malaysia, France, and Mexico. Any significant earthquake, flood, or other natural disaster in these countries or countries where our suppliers are located could materially disrupt our management operations and/or our production capabilities, and could result in our experiencing a significant delay in delivery, or substantial shortage, of our products and services.
In addition, legislators, regulators, and non-governmental organizations, as well as companies in many business sectors, are considering ways to reduce green-house gas emissions. Further regulation could be forthcoming at the federal or state level with respect to green-house gas emissions. Such regulation or similar regulations in other countries could result in regulatory or product standard requirements for our global business, including our manufacturing operations. Furthermore, the potential physical impacts of climate change on our operations may include changes in weather patterns (including floods, tsunamis, drought and rainfall levels), water availability, storm patterns and intensities, and temperature levels. These potential physical effects may adversely affect the cost, production, sales and financial performance of our operations.
We could be adversely affected by any violations of the FCPA and foreign anti-bribery laws.

The FCPA generally prohibits companies and their intermediaries from making improper payments to non-U.S. government officials for the purpose of obtaining or retaining business. Other countries in which we operate also have anti-bribery laws, some of which prohibit improper payments to government and non-government persons and entities. Our policies mandate compliance with these anti-bribery laws. We continue to acquire businesses outside of the United States and operate in many parts of the world that have experienced governmental corruption to some degree and, in certain circumstances, strict compliance with anti-bribery laws may conflict with local customs and practices. In addition, due to the level of regulation in our industry, our entry into new jurisdictions through internal growth or acquisitions requires substantial government contact where norms can differ from U.S. standards. While we implement policies and procedures and conduct training designed to facilitate compliance with these anti-bribery laws, thereby mitigating the risk of violations of such laws, our employees, subcontractors and agents may take actions in violation of our policies and anti-bribery laws. Any such violation, even if prohibited by our policies, could subject us to criminal or civil penalties or other sanctions, which could have a material adverse effect on our business, financial condition, cash flows and reputation.
We sell our solar products to agencies of the U.S. government, and as a result, we are subject to a number of procurement rules and regulations, and our business could be adversely affected by an audit by the U.S. government if it were to identify errors or a failure to comply with regulations.

We have sold and continue to sell our solar power systems to various U.S. government agencies. In connection with these contracts, we must comply with and are affected by laws and regulations relating to the award, administration, and performance of U.S. government contracts, which may impose added costs on our business. We are expected to perform in compliance with a vast array of federal laws and regulations, including, without limitation, the Federal Acquisition Regulation, the Truth in Negotiations Act, the Federal False Claims Act, the Anti-Kickback Act of 1986, the Trade Agreements Act, the Buy American Act, the Procurement Integrity Act, and the Davis Bacon Act. A violation of specific laws and regulations, even if prohibited by our policies, could result in the imposition of fines and penalties, reductions of the value of our contracts, contract modifications or termination, or suspension or debarment from government contracting for a period of time.

42

Table of Contents


In some instances, these laws and regulations impose terms or rights that are more favorable to the government than those typically available to commercial parties in negotiated transactions. For example, the U.S. government may terminate any of our government contracts either at its convenience or for default based on performance. A termination arising out of our default may expose us to liability and have a material adverse effect on our ability to compete for future contracts.
U.S. government agencies may audit and investigate government contractors. These agencies review a contractor’s performance under its contracts, cost structure, and compliance with applicable laws, regulations, and standards. If an audit or investigation uncovers improper or illegal activities, we may be subject to civil or criminal penalties and administrative sanctions, including termination of contracts, forfeiture of profits, suspension of payments, fines, and suspension or prohibition from doing business with the U.S. government. In addition, we could suffer reputational harm if allegations of impropriety were made against us.
Compliance with environmental regulations can be expensive, and noncompliance with these regulations may result in adverse publicity and potentially significant monetary damages and fines.

We are required to comply with all foreign, U.S. federal, state and local laws and regulations regarding pollution control and protection of the environment. In addition, under some statutes and regulations, a government agency, or other parties, may seek recovery and response costs from owners or operators of property where releases of hazardous substances have occurred or are ongoing, even if the owner or operator was not responsible for such release or otherwise at fault. We use, generate and discharge toxic, volatile and otherwise hazardous chemicals and wastes in our research and development and manufacturing activities. Any failure by us to control the use of, or to restrict adequately the discharge of, hazardous substances could subject us to, among other matters, potentially significant monetary damages and fines or liabilities or suspensions in our business operations. In addition, if more stringent laws and regulations are adopted in the future, the costs of compliance with these new laws and regulations could be substantial. If we fail to comply with present or future environmental laws and regulations, we may be required to pay substantial fines, suspend production or cease operations, or be subjected to other sanctions.
In addition, U.S. legislation includes disclosure requirements regarding the use of “conflict” minerals mined from the Democratic Republic of Congo and adjoining countries and procedures regarding a manufacturer’s efforts to prevent the sourcing of such “conflict” minerals. We have incurred and will incur additional costs to comply with the disclosure requirements, including costs related to determining the source of any of the relevant minerals and metals used in our products. The implementation of these requirements could affect the sourcing and availability of minerals used in the manufacture of solar products. As a result, there may only be a limited pool of suppliers who provide conflict free minerals, and we cannot be certain that we will be able to obtain products in sufficient quantities or at competitive prices. Since our supply chain is complex, we have not been able to sufficiently verify, and in the future we may not be able to sufficiently verify, the origins for these conflict minerals used in our products. As a result, we may face reputational challenges with our customers and other stakeholders if we are unable to sufficiently verify the origins for all minerals used in our products.
Our success depends on the continuing contributions of our key personnel.

We rely heavily on the services of our key executive officers and the loss of services of any principal member of our management team could adversely affect our operations. In addition, we anticipate that we will need to hire a number of highly skilled technical, manufacturing, sales, marketing, administrative and accounting personnel. In recent years, we have conducted several restructurings, which may negatively affect our ability to execute our strategy and business model. The competition for qualified personnel is intense in our industry. We may not be successful in attracting and retaining sufficient numbers of qualified personnel to support our anticipated growth. We cannot guarantee that any employee will remain employed with us for any definite period of time since all of our employees, including our key executive officers, serve at-will and may terminate their employment at any time for any reason.
Our insurance for certain indemnity obligations we have to our officers and directors may be inadequate, and potential claims could materially and negatively impact our financial condition and results of operations.

Pursuant to our certificate of incorporation, by-laws, and certain indemnification agreements, we indemnify our officers and directors for certain liabilities that may arise in the course of their service to us. Although we currently maintain directors and officers liability insurance for certain potential third-party claims for which we are legally or financially unable to indemnify them, such insurance may be inadequate to cover certain claims. In addition, in previous years, we have primarily self-insured with respect to potential third-party claims. If we were required to pay a significant amount on account of these liabilities for which we self-insured, our business, financial condition, and results of operations could be materially harmed.

43

Table of Contents


Risks Related to Our Intellectual Property

We depend on our intellectual property, and we may face intellectual property infringement claims that could be time-consuming and costly to defend and could result in the loss of significant rights.

From time to time, we, our respective customers, or third parties with whom we work may receive letters, including letters from other third parties, and may become subject to lawsuits with such third parties alleging infringement of their patents. Additionally, we are required by contract to indemnify some of our customers and our third-party intellectual property providers for certain costs and damages of patent infringement in circumstances where our products are a factor creating the customer’s or these third-party providers’ infringement liability. This practice may subject us to significant indemnification claims by our customers and our third-party providers. We cannot assure investors that indemnification claims will not be made or that these claims will not harm our business, operating results or financial condition. Intellectual property litigation is very expensive and time-consuming and could divert management’s attention from our business and could have a material adverse effect on our business, operating results or financial condition. If there is a successful claim of infringement against us, our customers or our third-party intellectual property providers, we may be required to pay substantial damages to the party claiming infringement, stop selling products or using technology that contains the allegedly infringing intellectual property, or enter into royalty or license agreements that may not be available on acceptable terms, if at all. Parties making infringement claims may also be able to bring an action before the International Trade Commission that could result in an order stopping the importation into the United States of our solar products. Any of these judgments could materially damage our business. We may have to develop non-infringing technology, and our failure in doing so or in obtaining licenses to the proprietary rights on a timely basis could have a material adverse effect on our business.
We have filed, and may continue to file, claims against other parties for infringing our intellectual property that may be very costly and may not be resolved in our favor.

To protect our intellectual property rights and to maintain our competitive advantage, we have filed, and may continue to file, suits against parties who we believe infringe our intellectual property. Intellectual property litigation is expensive and time consuming, could divert management’s attention from our business, and could have a material adverse effect on our business, operating results, or financial condition, and our enforcement efforts may not be successful. In addition, the validity of our patents may be challenged in such litigation. Our participation in intellectual property enforcement actions may negatively impact our financial results.
We rely substantially upon trade secret laws and contractual restrictions to protect our proprietary rights, and, if these rights are not sufficiently protected, our ability to compete and generate revenue could suffer.

We seek to protect our proprietary manufacturing processes, documentation, and other written materials primarily under trade secret and copyright laws. We also typically require employees, consultants, and third parties, such as our vendors and customers, with access to our proprietary information to execute confidentiality agreements. The steps we take to protect our proprietary information may not be adequate to prevent misappropriation of our technology. Our systems may be subject to intrusions, security breaches, or targeted theft of our trade secrets. In addition, our proprietary rights may not be adequately protected because:
others may not be deterred from misappropriating our technologies despite the existence of laws or contracts prohibiting such misappropriation;

policing unauthorized use of our intellectual property may be difficult, expensive, and time-consuming, the remedy obtained may be inadequate to restore protection of our intellectual property, and moreover, we may be unable to determine the extent of any unauthorized use;

the laws of other countries in which we market our solar products, such as some countries in the Asia/Pacific region, may offer little or no protection for our proprietary technologies; and

reports we file in connection with government-sponsored research contracts are generally available to the public and third parties may obtain some aspects of our sensitive confidential information.

Reverse engineering, unauthorized copying, or other misappropriation of our proprietary technologies could enable third parties to benefit from our technologies without compensating us for doing so. Our joint ventures or our partners may not be deterred from misappropriating our proprietary technologies despite contractual and other legal restrictions. Legal protection in countries where our joint ventures are located may not be robust and enforcement by us of our intellectual property rights

44

Table of Contents


may be difficult. As a result, our joint ventures or our partners could directly compete with our business. Any such activities or any other inabilities to adequately protect our proprietary rights could harm our ability to compete, to generate revenue, and to grow our business.
We may not obtain sufficient patent protection on the technology embodied in the solar products we currently manufacture and market, which could harm our competitive position and increase our expenses.

Although we substantially rely on trade secret laws and contractual restrictions to protect the technology in the solar products we currently manufacture and market, our success and ability to compete in the future may also depend to a significant degree upon obtaining patent protection for our proprietary technology. We currently own multiple patents and patent applications which cover aspects of the technology in the solar cells and mounting systems that we currently manufacture and market. Material patents that relate to our systems products and services primarily relate to our rooftop mounting products and ground-mounted tracking products. We intend to continue to seek patent protection for those aspects of our technology, designs, and methodologies and processes that we believe provide significant competitive advantages.
Our patent applications may not result in issued patents, and even if they result in issued patents, the patents may not have claims of the scope we seek or we may have to refile patent applications due to newly discovered prior art. In addition, any issued patents may be challenged, invalidated, or declared unenforceable, or even if we obtain an award of damages for infringement by a third party, such award could prove insufficient to compensate for all damages incurred as a result of such infringement.
The term of any issued patent is generally 20 years from its earliest filing date and if our applications are pending for a long time period, we may have a correspondingly shorter term for any patent that may issue. Our present and future patents may provide only limited protection for our technology and may be insufficient to provide competitive advantages to us. For example, competitors could develop similar or more advantageous technologies on their own or design around our patents. Also, patent protection in certain foreign countries may not be available or may be limited in scope and any patents obtained may not be readily enforceable because of insufficient judicial effectiveness, making it difficult for us to aggressively protect our intellectual property from misuse or infringement by other companies in these countries. Our inability to obtain and enforce our intellectual property rights in some countries may harm our business. In addition, given the costs of obtaining patent protection, we may choose not to protect certain innovations that later turn out to be important.
We may not be able to prevent others from using the term SunPower or similar terms, or other trademarks which we hold, in connection with their solar power products which could adversely affect the market recognition of our name and our revenue.

“SunPower” and the SunPower logo are our registered trademarks in certain countries, including the United States, for uses that include solar cells and solar panels. We are seeking registration of these trademarks in other countries, but we may not be successful in some of these jurisdictions. We hold registered trademarks for SunPower®, Maxeon®, Oasis®, EnergyLink™, InvisiMount®, Tenesol®, Greenbotics®, Customer Cost of Energy™ ("CCOE™"), SunPower Spectrum™, Helix™, Equinox™, Signature™, SolarBridge®, The Power of One™, and many more marks, in certain countries, including the United States. We have not registered, and may not be able to register, these trademarks in other key countries. In the foreign jurisdictions where we are unable to obtain or have not tried to obtain registrations, others may be able to sell their products using trademarks compromising or incorporating “SunPower,” or a variation thereof, or our other chosen brands, which could lead to customer confusion. In addition, if there are jurisdictions where another proprietor has already established trademark rights in marks containing “SunPower,” or our other chosen brands, we may face trademark disputes and may have to market our products with other trademarks or without our trademarks, which may undermine our marketing efforts. We may encounter trademark disputes with companies using marks which are confusingly similar to the SunPower mark, or our other marks, which if not resolved favorably, could cause our branding efforts to suffer. In addition, we may have difficulty in establishing strong brand recognition with consumers if others use similar marks for similar products.
Our past and possible future reliance on government programs to partially fund our research and development programs could impair our ability to commercialize our solar power products and services.

Government funding of some of our research and development efforts imposed certain restrictions on our ability to commercialize results and could grant commercialization rights to the government. In some funding awards, the government is entitled to intellectual property rights arising from the related research. Such rights include a nonexclusive, nontransferable, irrevocable, paid-up license to practice or have practiced each subject invention developed under an award throughout the world by or on behalf of the government. Other rights include the right to require us to grant a license to the developed technology or products to a third party or, in some cases, if we refuse, the government may grant the license itself, if the

45

Table of Contents


government determines that action is necessary because we fail to achieve practical application of the technology, because action is necessary to alleviate health or safety needs, to meet requirements of federal regulations, or to give the United States industry preference. Accepting government funding can also require that manufacturing of products developed with federal funding be conducted in the United States.
We may be subject to information technology system failures or network disruptions that could damage our business operations, financial conditions, or reputation.

We may be subject to information technology system failures and network disruptions. These may be caused by natural disasters, accidents, power disruptions, telecommunications failures, acts of terrorism or war, computer viruses, physical or electronic break-ins, or similar events or disruptions. System redundancy may be ineffective or inadequate, and our disaster recovery planning may not be sufficient for all eventualities. Such failures or disruptions could result in delayed or canceled orders. System failures and disruptions could also impede the manufacturing and shipping of products, delivery of online services, transactions processing, and financial reporting.
We may be subject to breaches of our information technology systems, which could lead to disclosure of our internal information, damage our reputation or relationships with dealers and customers, and disrupt access to our online services. Such breaches could subject us to significant reputational, financial, legal, and operational consequences.

Our business requires us to use and store customer, employee, and business partner personally identifiable information (“PII”). This may include names, addresses, phone numbers, email addresses, contact preferences, tax identification numbers, and payment account information. Malicious attacks to gain access to PII affect many companies across various industries, including ours.
We use encryption and authentication technologies to secure the transmission and storage of data. These security measures may be compromised as a result of third-party security breaches, employee error, malfeasance, faulty password management, or other irregularity, and result in persons obtaining unauthorized access to our data. Third parties may attempt to fraudulently induce employees or customers into disclosing passwords or other sensitive information, which may in turn be used to access our information technology systems.
We devote resources to network security, data encryption, and other security measures to protect our systems and data, but these security measures cannot provide absolute security. Because the techniques used to obtain unauthorized access, disable or degrade service, or sabotage systems change frequently and may be difficult to detect for long periods of time, we may be unable to anticipate these techniques or implement adequate preventative measures and as a result, we may experience a breach of our systems and may be unable to protect sensitive data. In addition, hardware, software, or applications we develop or procure from third parties may contain defects in design or manufacture or other problems that could unexpectedly compromise information security. Unauthorized parties may also attempt to gain access to our systems or facilities through fraud, trickery or other forms of deceiving our team members, contractors and temporary staff. If we experience a significant data security breach or fail to detect and appropriately respond to a significant data security breach, we could be exposed to a risk of loss, litigation and possible liability, or government enforcement actions, any of which could detrimentally affect our business, results of operations, and financial condition.
PII may also be shared with contractors and third-party providers to conduct our business. Although such contractors and third-party providers typically implement encryption and authentication technologies to secure the transmission and storage of data, those third-party providers may experience a significant data security breach of the shared PII.
See also “Risks Related to Our Intellectual Property - We rely substantially upon trade secret laws and contractual restrictions to protect our proprietary rights, and, if these rights are not sufficiently protected, our ability to compete and generate revenue could suffer.”

Our business is subject to a variety of U.S. and international laws, rules, policies, and other obligations regarding privacy, data protection, and other matters.

We are subject to federal, state and international laws relating to the collection, use, retention, security, and transfer of PII. In many cases, these laws apply not only to third-party transactions, but also to transfers of information between one company and its subsidiaries, and among the subsidiaries and other parties with which we have commercial relations. The introduction of new products or expansion of our activities in certain jurisdictions may subject us to additional laws and regulations. In addition, foreign data protection, privacy, and other laws and regulations can be more restrictive than those in the United States. These U.S. federal and state and foreign laws and regulations, which can be enforced by private parties or

46

Table of Contents


government entities, are constantly evolving and can be subject to significant change. In addition, the application and interpretation of these laws and regulations are often uncertain, particularly in the new and rapidly evolving industry in which we operate, and may be interpreted and applied inconsistently from country to country and inconsistently with our current policies and practices. These existing and proposed laws and regulations can be costly to comply with and can delay or impede the development of new products, result in negative publicity, increase our operating costs, require significant management time and attention, and subject us to inquiries or investigations, claims or other remedies, including fines or demands that we modify or cease existing business practices.
A failure by us, our suppliers or other parties with whom we do business to comply with a posted privacy policies or with other federal, state or international privacy-related or data protection laws and regulations could result in proceedings against us by governmental entities or others, which could have a detrimental effect on our business, results of operations, and financial condition.
Risks Related to Our Debt and Equity Securities

Our debentures are effectively subordinated to our existing and any future secured indebtedness and structurally subordinated to existing and future liabilities and other indebtedness of our current and any future subsidiaries.

Our debentures are our general, unsecured obligations and rank equally in right of payment with all of our existing and any future unsubordinated, unsecured indebtedness. As of January 1, 2017, we and our subsidiaries had $1.1 billion in principal amount of senior unsecured indebtedness outstanding, which ranks pari passu with our debentures. Our debentures are effectively subordinated to our existing and any future secured indebtedness we may have, including for example, our $300.0 million revolving credit facility with Credit Agricole, to the extent of the value of the assets securing such indebtedness, and structurally subordinated to our existing and any future liabilities and other indebtedness of our subsidiaries. In addition to our unsecured indebtedness described above, as of January 1, 2017, we and our subsidiaries had $495.1 million in principal amount of senior secured indebtedness outstanding, which includes $139.7 million in non-recourse project debt and $293.1 million in non-recourse long-term debt related to our residential lease business. These liabilities may also include other indebtedness, trade payables, guarantees, lease obligations, and letter of credit obligations. Our debentures do not restrict us or our current or any future subsidiaries from incurring indebtedness, including senior secured indebtedness, in the future, nor do they limit the amount of indebtedness we can issue that is equal in right of payment.
Recent or future regulatory actions may adversely affect the trading price and liquidity of our debentures.

We believe that many investors in our debentures employ, or will seek to employ, a convertible arbitrage strategy with respect to our debentures. Investors that employ a convertible arbitrage strategy with respect to convertible debt instruments typically implement that strategy by selling short the common stock underlying the convertible debt instruments and dynamically adjusting their short position while they hold the debt instruments. Investors may also implement this strategy by entering into swaps on the common stock underlying the convertible debt instruments in lieu of or in addition to short selling the common stock. As a result, rules regulating equity swaps or short selling of securities or other governmental action that interferes with the ability of market participants to effect short sales or equity swaps with respect to our common stock could adversely affect the ability of investors in our debentures to conduct the convertible arbitrage strategy that we believe they employ, or will seek to employ, with respect to our debentures. This could, in turn, adversely affect the trading price and liquidity of our debentures.
The SEC and other regulatory and self-regulatory authorities have implemented various rules in recent years and may adopt additional rules in the future that may impact those engaging in short selling activity involving equity securities (including our common stock). In particular, Rule 201 of SEC Regulation SHO restricts certain short selling when the price of a “covered security” triggers a “circuit breaker” by falling 10% or more from the security’s closing price as of the end of regular trading hours on the prior day. If this circuit breaker is triggered, short sale orders can be displayed or executed for the remainder of that day and the following day only if the order price is above the then-current national best bid, subject to certain limited exceptions. Because our common stock is a “covered security”, these Rule 201 restrictions, if triggered, may interfere with the ability of investors in our debentures to effect short sales in our common stock and conduct a convertible arbitrage strategy.
In addition, during 2012, the SEC approved two proposals submitted by the national securities exchanges and the Financial Industry Regulatory Authority, Inc. (“FINRA”) concerning extraordinary market volatility that may impact the ability of investors to effect a convertible arbitrage strategy. One initiative is the “Limit Up-Limit Down” plan, which requires securities exchanges, alternative trading systems, broker-dealers, and other trading centers to establish policies and procedures that prevent the execution of trades or the display of bids or offers outside of specified price bands. If the bid or offer quotations

47

Table of Contents


for a security are at the far limit of the price band for more than 15 seconds, trading in that security will be subject to a five-minute trading pause. The Limit Up-Limit Down plan became effective, on a pilot basis, on April 8, 2013 and has been extended several times, most recently through April 21, 2017.
The second initiative revised existing national securities exchange and FINRA rules that establish the market-wide circuit breaker system. The market-wide circuit breaker system provides for specified market-wide halts in trading of listed stocks and options for certain periods following specified market declines. The changes lowered the percentage-decline thresholds for triggering a market-wide trading halt and shortened the amount of time that trading is halted. Market declines under the new system are measured based on a decline in the S&P 500 Index compared to the prior day’s closing value rather than a decline in the Dow Jones Industrial Average compared to the prior quarterly closing value. The changes to the market-wide circuit breaker system became effective, on a pilot basis, on April 8, 2013 and have been extended so that the system will continue in effect so long as the Limit Up-Limit Down plan is effective, currently until April 21, 2017. The potential restrictions on trading imposed by the Limit Up-Limit Down plan and the market-wide circuit breaker system may interfere with the ability of investors in our debentures to effect short sales in our common stock and conduct a convertible arbitrage strategy.
The enactment of the Dodd-Frank Wall Street Reform and Consumer Protection Act, (the "Dodd-Frank Act") on July 21, 2010 also introduced regulatory changes that may impact trading activities relevant to our debentures. As a result of this legislation and implementing rules, certain interest rate swaps and credit default swaps are currently required to be cleared through regulated clearinghouses. Certain other swaps (regulated by the U.S. Commodity Futures Trading Commission (the "CFTC") and security-based swaps (regulated by the SEC) are likely going to be required to be cleared through regulated clearinghouses in the future. In addition, certain swaps and security-based swaps will be required to be traded on exchanges or comparable trading facilities. Furthermore, swap dealers, security-based swap dealers, major swap participants and major security-based swap participants will be required to comply with margin and capital requirements, the indirect cost of which will likely be borne by market participants. Market participants will also be subject to certain direct margin requirements. In addition, certain market participants are required to comply with public reporting requirements to provide transaction and pricing data on both cleared and uncleared swaps. Public reporting requirements will also apply with respect to security-based swaps in the future. These requirements could adversely affect the ability of investors in our debentures to maintain a convertible arbitrage strategy with respect to our debentures (including increasing the costs incurred by such investors in implementing such strategy). This could, in turn, adversely affect the trading price and liquidity of our debentures. Although some of the implementing rules have been adopted and are currently effective, we cannot predict how the SEC, CFTC, and other regulators will ultimately implement the legislation or the magnitude of the effect that this legislation will have on the trading price or liquidity of our debentures.
Although the direction and magnitude of the effect that the amendments to Regulation SHO, FINRA and securities exchange rule changes, and/or implementation of the Dodd-Frank Act may have on the trading price and the liquidity of our debentures will depend on a variety of factors, many of which cannot be determined at this time, past regulatory actions have had a significant impact on the trading prices and liquidity of convertible debentures. For example, between July 2008 and September 2008, the SEC issued a series of emergency orders placing restrictions on the short sale of the common stock of certain financial services companies. The orders made the convertible arbitrage strategy that many holders of convertible debentures employ difficult to execute and adversely affected both the liquidity and trading price of convertible debentures issued by many of the financial services companies subject to the prohibition. Any governmental action that similarly restricts the ability of investors in our debentures to effect short sales of our common stock, including the amendments to Regulation SHO, FINRA and exchange rule changes, and the implementation of the Dodd-Frank Act, could similarly adversely affect the trading price and the liquidity of our debentures.
Total’s majority ownership of our common stock may adversely affect the liquidity and value of our common stock.

As of January 1, 2017, Total owned approximately 57% of our outstanding common stock. Pursuant to the Affiliation Agreement between us and Total, the Board of Directors of SunPower includes five designees from Total, giving Total majority control of our Board. As a result, subject to the restrictions in the Affiliation Agreement, Total possesses significant influence and control over our affairs. Our non-Total stockholders have reduced ownership and voting interest in our company and, as a result, have less influence over the management and policies of our company than they exercised prior to Total’s tender offer. As long as Total controls us, the ability of our other stockholders to influence matters requiring stockholder approval is limited. Total’s stock ownership and relationships with members of our Board of Directors could have the effect of preventing minority stockholders from exercising significant control over our affairs, delaying or preventing a future change in control, impeding a merger, consolidation, takeover, or other business combination or discouraging a potential acquirer from making a tender offer or otherwise attempting to obtain control of us, limiting our financing options. These factors in turn could adversely affect the market price of our common stock or prevent our stockholders from realizing a premium over the market price of our common

48

Table of Contents


stock. The Affiliation Agreement limits Total and any member of the Total affiliated companies (“Total Group”) from effecting, seeking, or entering into discussions with any third party regarding any transaction that would result in the Total Group beneficially owning our shares in excess of certain thresholds during a standstill period. The Affiliation Agreement also imposes certain limitations on the Total Group’s ability to seek to affect a tender offer or merger to acquire 100% of our outstanding voting power. Such provisions may not be successful in preventing the Total Group from engaging in transactions which further increase their ownership and negatively impact the price of our common stock. See also “Risks Related to Our Liquidity - We may be unable to generate sufficient cash flows or obtain access to external financing necessary to fund our operations and make adequate capital investments as planned due to the general economic environment and the continued market pressure driving down the average selling prices of our solar power products, among other factors.” Finally, the market for our common stock has become less liquid and more thinly traded as a result of the Total tender offer. The lower number of shares available to be traded could result in greater volatility in the price of our common stock and affect our ability to raise capital on favorable terms in the capital markets.
Conversion of our outstanding 0.75% debentures, 0.875% debentures, 4.00% debentures, and future substantial issuances or dispositions of our common stock or other securities, could dilute ownership and earnings per share or cause the market price of our stock to decrease.

The conversion of some or all of our outstanding 0.75%, 0.875%, or 4.00% debentures into shares of our common stock will dilute the ownership interests of existing stockholders, including holders who had previously converted their debentures. Any sales in the public market of the common stock issuable upon such conversion could adversely affect prevailing market prices of our common stock. Sales of our common stock in the public market or sales of any of our other securities could dilute ownership and earnings per share, and even the perception that such sales could occur could cause the market prices of our common stock to decline. In addition, the existence of our outstanding debentures may encourage short selling of our common stock by market participants who expect that the conversion of the debentures could depress the prices of our common stock.
Future sales of our common stock in the public market could lower the market price for our common stock and adversely impact the trading price of our debentures.

In the future, we may sell additional shares of our common stock to raise capital. We cannot predict the size of future issuances or the effect, if any, that they may have on the market price for our common stock. In addition, a substantial number of shares of our common stock is reserved for issuance upon the exercise of stock options, restricted stock awards, restricted stock units, warrants, and upon conversion of the debentures and our outstanding 0.75%, 0.875%, and 4.00% debentures. The issuance and sale of substantial amounts of common stock, or the perception that such issuances and sales may occur, could adversely affect the trading price of our debentures and the market price of our common stock and impair our ability to raise capital through the sale of additional equity or equity-linked securities.
The price of our common stock, and therefore of our outstanding 0.75%, 0.875%, and 4.00% debentures, may fluctuate significantly.

Our common stock has experienced extreme price and volume fluctuations. The trading price of our common stock could be subject to further wide fluctuations due to many factors, including the factors discussed in this risk factors section. In addition, the stock market in general, and The NASDAQ Global Select Market and the securities of technology companies and solar companies in particular, have experienced severe price and volume fluctuations. These trading prices and valuations, including our own market valuation and those of companies in our industry generally, may not be sustainable. These broad market and industry factors may decrease the market price of our common stock, regardless of our actual operating performance. Because the 0.75%, 0.875%, and 4.00% debentures are convertible into our common stock (and/or cash equivalent to the value of our common stock), volatility or depressed prices of our common stock could have a similar effect on the trading price of the debentures.
If securities or industry analysts change their recommendations regarding our stock adversely, our stock price and trading volume could decline.

The trading market for our common stock is influenced by the research and reports that industry or securities analysts publish about us, our business or our market. If one or more of the analysts who cover us change their recommendation regarding our stock adversely, our stock price would likely decline. If one or more of these analysts ceases coverage of our company or fails to regularly publish reports on us, we could lose visibility in the financial markets, which in turn could cause our stock price or trading volume, and the value of our debentures, to decline.

49

Table of Contents


We do not intend to pay dividends on our common stock in the foreseeable future.

We have never declared or paid cash dividends. For the foreseeable future, we intend to retain any earnings, after considering any dividends on any preferred stock, to finance the development of our business, and we do not anticipate paying any cash dividends on our common stock. Any future determination to pay dividends will be at the discretion of our Board of Directors and will be dependent upon then-existing conditions, including our operating results and financial condition, capital requirements, contractual restrictions, business prospects, and other factors that our Board of Directors considers relevant. Accordingly, holders of our common stock must rely on sales of their common stock after price appreciation, which may never occur, as the only way to realize a return on their shares of common stock.
Delaware law and our certificate of incorporation and by-laws contain anti-takeover provisions, our outstanding 0.75%, 0.875%, and 4.00% debentures provide for a right to convert upon certain events, and our Board of Directors entered into a rights agreement and declared a rights dividend, any of which could delay or discourage takeover attempts that stockholders may consider favorable.

Provisions in our certificate of incorporation and by-laws may have the effect of delaying or preventing a change of control or changes in our management. These provisions include the following:
the right of the Board of Directors to elect a director to fill a vacancy created by the expansion of the Board of Directors;

the prohibition of cumulative voting in the election of directors, which would otherwise allow less than a majority of stockholders to elect director candidates;

the requirement for advance notice for nominations for election to the Board of Directors or for proposing matters that can be acted upon at a stockholders’ meeting;

the ability of the Board of Directors to issue, without stockholder approval, up to 10 million shares of preferred stock with terms set by the Board of Directors, which rights could be senior to those of common stock;

our Board of Directors is divided into three classes of directors, with the classes to be as nearly equal in number as possible;

stockholders may not call special meetings of the stockholders, except by Total under limited circumstances; and
our Board of Directors is able to alter our by-laws without obtaining stockholder approval.

Certain provisions of our outstanding debentures could make it more difficult or more expensive for a third party to acquire us. Upon the occurrence of certain transactions constituting a fundamental change, including an entity (such as Total) becoming the beneficial owner of 75% of our voting stock, holders of our outstanding debentures will have the right, at their option, to require us to repurchase, at a cash repurchase price equal to 100% of the principal amount plus accrued and unpaid interest on the debentures, all or a portion of their debentures. We may also be required to issue additional shares of our common stock upon conversion of such debentures in the event of certain fundamental changes. In addition, we entered into a Rights Agreement with Computershare Trust Company, N.A., commonly referred to as a “poison pill,” which could delay or discourage takeover attempts that stockholders may consider favorable.


50

Table of Contents


ITEM 1B: UNRESOLVED STAFF COMMENTS

None.

ITEM 2: PROPERTIES

The table below presents details for each of our principal properties:
Facility
 
Location
 
Approximate
Square
Footage
 
Held
 
Lease Term
Solar cell manufacturing facility1, 2
 
Philippines
 
392,000
 
Owned
 
n/a
Solar cell manufacturing facility3
 
Malaysia
 
885,000
 
Owned
 
n/a
Former solar cell manufacturing facility1, 4
 
Philippines
 
641,000
 
Owned
 
n/a
Solar cell manufacturing support and storage facility
 
Philippines
 
167,000
 
Leased
 
2024
Former solar module assembly facility1, 4
 
Philippines
 
183,000
 
Owned
 
n/a
Solar module assembly facility
 
Mexico
 
320,000
 
Leased
 
2021
Solar module assembly facility
 
Mexico
 
186,000
 
Leased
 
2026
Solar module assembly facility
 
France
 
11,000
 
Owned
 
n/a
Solar module assembly facility
 
France
 
13,000
 
Leased
 
2018
Corporate headquarters
 
California, U.S.
 
129,000
 
Leased
 
2021
Global support offices
 
California, U.S.
 
163,000
 
Leased
 
2023
Global support offices
 
Texas, U.S.
 
69,000
 
Leased
 
2019
Global support offices
 
France
 
27,000
 
Leased
 
2023
Global support offices
 
Philippines
 
65,000
 
Owned
 
n/a
1 
The lease for the underlying land expires in May 2048 and is renewable for an additional 25 years.
2 
The solar cell manufacturing facility we operate in the Philippines has a total annual capacity of 350 MW.
3The solar cell manufacturing facility we operate in Malaysia has a total rated annual capacity of over 800 MW.
4We still own this facility as of January 1, 2017 but relevant operations ceased during fiscal 2016.

As of January 1, 2017, our principal properties include operating solar cell manufacturing facilities with a combined total annual capacity of over 1.1 GW and solar module assembly facilities with a combined total annual capacity of approximately 1.9 GW. For more information about our manufacturing capacity, see "Item 1. Business."

We do not identify or allocate assets by business segment. For more information on property, plant and equipment by country, see "Item 8. Financial Statements and Supplementary Data—Notes to Consolidated Financial Statements—Note 5. Balance Sheet Components."

ITEM 3. LEGAL PROCEEDINGS

Tax Benefit Indemnification Litigation

On March 19, 2014, a lawsuit was filed by NRG Solar LLC, now known as NRG Renew LLC (“NRG”), against SunPower Corporation, Systems, our wholly-owned subsidiary (“SunPower Systems”), in the Superior Court of Contra Costa County, California.  The complaint asserts that, according to the indemnification provisions in the contract pertaining to SunPower Systems’ sale of a large California solar project to NRG, SunPower Systems owes NRG $75.0 million in connection with certain tax benefits associated with the project that were approved by the U.S. Treasury Department ("Treasury") for an amount that was less than expected. We do not believe that the facts support NRG’s claim under the operative indemnification provisions and SunPower Systems is vigorously contesting the claim.  Additionally, SunPower Systems filed a cross-complaint against NRG seeking damages in excess of $7.5 million for breach of contract and related claims arising from NRG’s failure to fulfill its obligations under the contract, including its obligation to take “reasonable, available steps” to engage Treasury.  We are currently unable to determine if the resolution of this matter will have a material effect on our consolidated financial statements.

51

Table of Contents



Class Action and Derivative Suits

On August 16, 2016 and August 26, 2016, two securities class action lawsuits were filed against the Company and certain of its officers and directors (the "Defendants") in the United States District Court for the Northern District of California on behalf of a class consisting of those who acquired the Company's securities from February 17, 2016 through August 9, 2016 (the "Class Period"). The substantially identical complaints allege violations of Sections 10(b) and 20(a) of the Exchange Act,
15 U.S.C. §§78j(b) and 78t(a) and SEC Rule 10b-5, 17 C.F.R. §240.10b-5. The complaints were filed following the issuance of the Company's August 9, 2016 earnings release and revised guidance and generally allege that throughout the Class Period, Defendants made materially false and/or misleading statements and failed to disclose material adverse facts about the Company’s business, operations, and prospects. On December 9, 2017, the court consolidated the cases and appointed a lead plaintiff.

Four shareholder derivative actions have been filed in federal court, purporting to be brought on the Company's behalf against certain of the Company's current and former officers and directors based on the same events alleged in the securities class action lawsuits described above. The Company is named as a nominal defendant. The plaintiffs assert claims for alleged breaches of fiduciary duties, unjust enrichment, and waste of corporate assets for the period February 2016 through the present and generally allege that the defendants made or caused the Company to make materially false and/or misleading statements and failed to disclose material adverse facts about the Company’s business, operations, and prospects. The plaintiffs also claim that the alleged conduct is a breach of the Company's Code of Business Conduct and Ethics, and that defendants, including members of the Company's Audit Committee, breached their fiduciary duties by failing to ensure the adequacy of the Company's internal controls, and by causing or allowing the Company to disseminate false and misleading statements in the Company’s SEC filings and other disclosures. The securities class action lawsuits and the federal derivative actions have all been related by the Court and assigned to one judge.

Shareholder derivative actions purporting to be brought on the Company’s behalf were brought in the Superior Court of California for the County of Santa Clara against certain of the Company’s current and former officers and directors based on the same events alleged in the securities class action and federal derivative lawsuits described above, and alleging breaches of fiduciary duties.

The Company is currently unable to determine if the resolution of these matters will have a material adverse effect on the Company's financial position, liquidity, or results of operations.

Other Litigation

We are a party to various other litigation matters and claims that arise from time to time in the ordinary course of our business. While we believe that the ultimate outcome of such matters will not have a material adverse effect on our business, their outcomes are not determinable and negative outcomes may adversely affect our financial position, liquidity, or results of operations.

ITEM 4: MINE SAFETY DISCLOSURES

Not applicable.


52

Table of Contents


PART II

ITEM 5: MARKET FOR REGISTRANT’S COMMON EQUITY, RELATED STOCKHOLDER MATTERS AND ISSUER PURCHASES OF EQUITY SECURITIES

Market Information

Our common stock is listed on the Nasdaq Global Select Market under the trading symbol "SPWR." During fiscal 2016 and 2015, the high and low closing trading prices of our common stock were as follows:
 
 
SPWR
 
 
High
 
Low
Fiscal Year 2016
 
 
 
 
Fourth quarter
 
$
9.11

 
$
6.30

Third quarter
 
$
16.07

 
$
7.53

Second quarter
 
$
22.09

 
$
13.49

First quarter
 
$
30.46

 
$
20.38

Fiscal Year 2015
 
 
 
 
Fourth quarter
 
$
30.77

 
$
19.12

Third quarter
 
$
28.73

 
$
20.95

Second quarter
 
$
34.85

 
$
30.01

First quarter
 
$
33.60

 
$
23.35


As of February 10, 2017, there were approximately 814 record holders of our common stock. A substantially greater number of holders are in "street name" or beneficial holders, whose shares are held of record by banks, brokers, and other financial institutions.

Dividends

We have never declared or paid any cash dividend on our common stock, and we do not currently intend to pay a cash dividend on our common stock in the foreseeable future. Certain of the Company's debt agreements place restrictions on the Company and its subsidiaries' ability to pay cash dividends. For more information on our common stock and dividend rights, see "Item 8. Financial Statements and Supplementary Data—Notes to Consolidated Financial Statements—Note 14. Common Stock."

Issuer Purchases of Equity Securities

The following table sets forth all purchases made by or on behalf of us or any "affiliated purchaser," as defined in Rule 10b-18(a)(3) under the Exchange Act, of shares of our common stock during each of the indicated periods.
Period
 
Total Number of Shares Purchased1
 
Average Price
Paid Per Share
 
Total Number of Shares Purchased as Part of Publicly Announced Plans or Programs
 
Maximum Number of Shares That May Yet Be Purchased Under the Publicly Announced Plans or Programs
October 3, 2016 through October 30, 2016
 
44,123

 
$
8.65

 

 

October 31, 2016 through November 27, 2016
 
6,626

 
$
7.01

 

 

November 28, 2016 through January 1, 2017
 
19,129

 
$
7.13

 

 

 
 
69,878

 
$
8.08

 

 

1 
The shares purchased represent shares surrendered to satisfy tax withholding obligations in connection with the vesting of restricted stock issued to employees.

53

Table of Contents


ITEM 6: SELECTED CONSOLIDATED FINANCIAL DATA

The following selected consolidated financial data should be read together with "Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations" and "Item 8. Financial Statements and Supplementary Data" included elsewhere in this Annual Report on Form 10-K.
 
 
Year Ended
 (In thousands, except per share data)
 
January 1, 2017
 
January 3, 2016
 
December 28, 2014
 
December 29, 2013
 
December 30, 2012
Consolidated Statements of Operations Data
 
 
 
 
 
 
 
 
 
 
Revenue
 
$
2,559,562

 
$
1,576,473

 
$
3,027,265

 
$
2,507,203

 
$
2,417,501

Gross margin
 
$
189,966

 
$
244,646

 
$
625,127

 
$
491,072

 
$
246,398

Operating income (loss)
 
$
(462,414
)
 
$
(206,294
)
 
$
251,240

 
$
158,909

 
$
(287,708
)
Income (loss) from continuing operations before income taxes and equity in earnings (loss) of unconsolidated investees
 
$
(564,595
)
 
$
(242,311
)
 
$
184,614

 
$
41,583

 
$
(329,663
)
Income (loss) from continuing operations per share of common stock:
 
 
 
 
 
 
 
 
 
 
Basic
 
$
(3.41
)
 
$
(1.39
)
 
$
1.91

 
$
0.79

 
$
(3.01
)
Diluted
 
$
(3.41
)
 
$
(1.39
)
 
$
1.55

 
$
0.70

 
$
(3.01
)
 
 
As of
(In thousands)
 
January 1, 2017
 
January 3, 2016
 
December 28, 2014
 
December 29, 2013
 
December 30, 2012
Consolidated Balance Sheet Data
 
 
 
 
 
 
 
 
 
 
Cash and cash equivalents
 
$
425,309

 
$
954,528

 
$
956,175

 
$
762,511

 
$
457,487

Working capital
 
$
824,524

 
$
1,515,918

 
$
1,273,236

 
$
528,017

 
$
976,627

Total assets
 
$
4,567,167

 
$
4,856,993

 
$
4,345,582

 
$
3,898,690

 
$
3,340,948

Long-term debt
 
$
451,243

 
$
478,948

 
$
214,181

 
$
93,095

 
$
375,661

Convertible debt, net of current portion
 
$
1,113,478

 
$
1,110,960

 
$
692,955

 
$
300,079

 
$
438,629

Total stockholders' equity
 
$
1,007,832

 
$
1,449,149

 
$
1,534,174

 
$
1,116,153

 
$
993,352




54

Table of Contents


ITEM 7: MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS

Overview

SunPower is a leading global energy company that delivers complete solar solutions to residential, commercial, and power plant customers worldwide through an array of hardware, software, and financing options and through utility-scale solar power system construction and development capabilities, O&M services, and "Smart Energy" solutions. Our Smart Energy initiative is designed to add layers of intelligent control to homes, buildings and grids—all personalized through easy-to-use customer interfaces. Of all the solar cells commercially available to the mass market, we believe our solar cells have the highest conversion efficiency, a measurement of the amount of sunlight converted by the solar cell into electricity. For more information about our business, please refer to the section titled "Part I. Item 1. Business" in this Annual Report on Form 10-K.
    
Segments Overview

We operate in three end-customer segments: (i) Residential Segment, (ii) Commercial Segment and (iii) Power Plant Segment. Our President and Chief Executive Officer, as the chief operating decision maker, reviews our business and manages resource allocations and measures performance of our activities among these three end-customer segments. The Residential and Commercial Segments combined are referred to as Distributed Generation. For more information about our business segments, see the section titled "Part I. Item 1. Business" in this Annual Report on Form 10-K. For more segment information, see "Item 8. Financial Statements and Supplementary Data—Note 17. Segment Information" in this Annual Report.

Unit of Power

When referring to our solar power systems, our facilities’ manufacturing capacity, and total sales, the unit of electricity in watts for kilowatts ("KW"), megawatts ("MW"), and gigawatts ("GW") is direct current ("DC"), unless otherwise noted as alternating current ("AC").

Seasonal Trends

Our business is subject to industry-specific seasonal fluctuations including changes in weather patterns and economic incentives, among others. Sales have historically reflected these seasonal trends with the largest percentage of total revenues realized during the last two quarters of a fiscal year. The construction of solar power systems or installation of solar power components and related revenue may decline during cold winter months. In the United States, many customers make purchasing decisions towards the end of the year in order to take advantage of tax credits or for other budgetary reasons. In addition, revenues may fluctuate due to the timing of project sales, construction schedules, and revenue recognition of certain projects, such as those involving the sale of real estate, which may significantly impact the quarterly profile of our results of operations. We may also retain certain development projects on our balance sheet for longer periods of time than in preceding periods in order to optimize the economic value we receive at the time of sale in light of market conditions, which can fluctuate after we have committed to projects. Delays in disposing of projects, or changes in amounts realized on disposition, may lead to significant fluctuations to the period-over-period profile of our results of operations and our cash available for working capital needs.

Fiscal Years

We have a 52-to-53-week fiscal year that ends on the Sunday closest to December 31. Accordingly, every fifth or sixth year will be a 53-week fiscal year. The current fiscal year, fiscal 2016, is a 52-week fiscal year, fiscal year 2015 was a 53-week fiscal year and had a 14-week fourth fiscal quarter, while fiscal year 2014 was a 52-week fiscal year. Fiscal 2016 ended on January 1, 2017, fiscal 2015 ended on January 3, 2016, and fiscal 2014 ended on December 28, 2014.

Outlook

Demand

In fiscal 2016 we faced market challenges, primarily in our Power Plant Segment, which impacted our margins and prompted us to implement changes to our business in order to realign our downstream investments, optimize our supply chain, and reduce operating expenses. Our actions included the consolidation of our manufacturing operations in order to accelerate operating cost reductions and improve overall operating efficiency. Factors that impacted our margins included write-downs totaling $46.2 million on certain solar power development projects during 2016 because of adjustments to pricing assumptions,

55

Table of Contents


as well as charges totaling $58.2 million that were recorded in fiscal 2016 in connection with the contracted sale of raw material inventory to third parties as we sought to improve our working capital. In fiscal 2017, we plan to focus on projects that we expect will be profitable; however, market conditions can deteriorate after we have committed to projects. For example, shifts in the timing of demand and changes in the internal rate of return ("IRR") that our customers expect can significantly affect project sale prices. A pronounced increase in expected customer and investor IRR rates in light of market conditions may continue to drive lower overall project sale prices in fiscal 2017. For more information see "Part I. Item 1A. Risk Factors—Risks Related to Our Sales Channels—Our operating results are subject to significant fluctuations and are inherently unpredictable" in this Annual Report on Form 10-K.

In the face of these near-term challenges, we remain focused on each of our three business segments as well as on continued investment in next-generation technology. We plan to expand the footprint of our SunPower EquinoxTM and HelixTM complete solutions in our Residential and Commercial businesses. We plan to focus our Power Plant business development resources on a limited number of core markets, primarily in the Americas, where we believe we have a sustainable competitive advantage. Outside of these core markets, we will focus our Power Plant business on the sale of our new Oasis® complete solution, incorporating Performance Series panel technology, to developers and EPC companies in global markets. 8point3 Energy Partners remains a source of demand for our business and we plan to continue to sell to it our solar energy generating assets, including utility-scale solar power plants and commercial solar projects. We have used and expect to continue to use additional financing structures and sources of demand in order to maximize economic returns. For additional information on transactions with 8point3 Energy Partners and associated revenue recognition, see "Item 8. Financial Statements and Supplementary Data—Note 10. Equity Method Investments" in this Annual Report on Form 10-K.

In late fiscal 2015, the U.S. government enacted a budget bill that extended the solar commercial investment tax credit (the “Commercial ITC”) under Section 48(c) of the Internal Revenue Code of 1986 (the “IRC”) and the individual solar investment tax credit under Section 25D of the IRC (together with the Commercial ITC, the “ITC”) for five years, at rates gradually decreasing from 30% through 2019 to 22% in 2021. After 2021, the Commercial ITC is retained at 10%. We also saw other recent developments that contributed to a favorable policy environment, including (i) a significant focus on reducing world-wide carbon emissions through such events as the COP21 sustainable innovation forum held in Paris and the announcement of the Clean Power Plan in the United States, and (ii) domestic policy measures such as the extension of bonus depreciation and approval of California Net Metering "NEM 2.0." We believe these factors will strengthen long-term demand for our products in all three business segments in U.S. and global markets and provide us an opportunity to expand our suite of energy solutions. However, in the near term, the extension of the ITC has had adverse impacts on our business, as it has reduced the pressure for commercial or residential customers to make purchases before the end of 2016, which was the time when the ITC had previously been set to expire, and instead has pushed demand from these customers into future periods. In addition, the new administration and Congress have expressed interest in comprehensive reform of the U.S. tax code, which could result in the reduction or elimination of various industry-specific tax incentives in return for an overall reduction in corporate tax rates. For more information about the ITC and other policy mechanisms, please refer to the section titled "Item 1. Business—Regulations—Public Policy Considerations" in this Annual Report on Form 10-K. For more information about how we avail ourselves of the benefits of public policies and the risks related to public policies, please see the risk factors set forth under the caption "Part I. Item 1A. Risk Factors—Risks Related to Our Sales Channels" in this Annual Report on Form 10-K, including "—The reduction, modification or elimination of government incentives could cause our revenue to decline and harm our financial results" and "—Existing regulations and policies and changes to these regulations and policies may present technical, regulatory, and economic barriers to the purchase and use of solar power products, which may significantly reduce demand for our products and services."

Supply
 
We are focused on delivering complete solutions to customers in all three of our business segments. As part of our complete solution approach, we launched our SunPower HelixTM product for our Commercial Segment during fiscal 2015 and our SunPower EquinoxTM product for our Residential Segment during fiscal 2016. The SunPower Equinox and Helix systems are pre-engineered modular solutions for residential and commercial applications, respectively, that combine our high-efficiency solar module technology with integrated plug-and-play power stations, cable management systems, and mounting hardware that enable our customers to quickly and easily complete system installations and manage their energy production. Our SunPower EquinoxTM systems utilize our latest X-Series cell and ACPV technology for residential applications, where we are also expanding our initiatives on storage and Smart Energy solutions. During fiscal 2016 we also launched our new generation technology for our existing Oasis® modular solar power blocks for power plant applications. With the addition of these modular solutions in our residential and commercial applications, we are able to provide complete solutions across all end-customer segments. Additionally, we continue to focus on producing on our new lower cost, high efficiency Performance Series product line, which will enhance our ability to rapidly expand our global footprint with minimal capital cost.


56

Table of Contents


We continue to see significant and increasing opportunities in technologies and capabilities adjacent to our core product offerings that can significantly reduce our customers' CCOE measurement, including the integration of energy storage and energy management functionality into our systems, and have made investments to realize those opportunities, including our investment in a data-driven Energy Services Management Platform from Tendril Networks, Inc., and our strategic partnership with EnerNOC to deploy their Software as a Service energy intelligence software solution to our commercial and power plant customers, enabling our customers to make intelligent energy choices by addressing how they buy energy, how they use energy and when they use it. We have added advanced module-level control electronics to our portfolio of technology designed to enable longer series strings and significant balance of system components cost reductions in large arrays. We are developing next generation microinverter technology and currently offer solar panels that use microinverters designed to eliminate the need to mount or assemble additional components on the roof or the side of a building and enable optimization and monitoring at the solar panel level to ensure maximum energy production by the solar system. We also continue to work on making combined solar and distributed energy storage solutions broadly commercially available to certain customers in the United States through our agreement to offer Sunverge SIS energy solutions comprising batteries, power electronics, and multiple energy inputs controlled by software in the cloud.

We continue to improve our unique, differentiated solar cell and panel technology. We emphasize improvement of our solar cell efficiency and LCOE and CCOE performance through enhancement of our existing products, development of new products and reduction of manufacturing cost and complexity in conjunction with our overall cost-control strategies. We are now producing our solar cells with over 25% efficiency in the lab, have reached production panel efficiencies over 24%, and have started up our high-volume Performance Series production lines in Mexico.

We plan to reduce our overall solar cell manufacturing output to match profitable demand levels, with increasing bias toward our highest efficiency X-Series product platform, which utilizes our latest solar cell technology, and our Performance Series product, which utilizes conventional cell technology that we purchase from third parties in low-cost supply chain ecosystems such as China. We recently closed our Fab 2 cell manufacturing facility and our panel assembly facility in the Philippines and are focusing on our latest generation, lower cost panel assembly facilities in Mexico. As part of this realignment, we expect to reduce our back-contact panel assembly capacity while ramping production of our new Performance Series technology.

We are focused on reducing the cost of our solar panels and systems and are working with our suppliers and partners along all steps of the value chain to reduce costs by improving manufacturing technologies and expanding economies of scale. We also continually focus on reducing manufacturing cost and complexity in conjunction with our overall cost-control strategies. We believe that the global demand for solar systems is highly elastic and that our aggressive, but achievable, cost reduction roadmap will reduce installed costs for our customers across all business segments and drive increased demand for our solar solutions.

We also work with our suppliers and partners to ensure the reliability of our supply chain. We have contracted with some of our suppliers for multi-year supply agreements, under which we have annual minimum purchase obligations. For more information about our purchase commitments and obligations, please see "Item 7. Management's Discussion and Analysis of Financial Condition and Results of Operations—Liquidity and Capital Resources—Contractual Obligations" and "Item 8. Financial Statements and Supplementary Data—"Note 9. Commitments and Contingencies" in the Notes to the Consolidated Financial Statements in this Annual Report on Form 10-K.

We currently believe our supplier relationships and various short- and long-term contracts will afford us the volume of material and services required to meet our planned output; however, we face the risk that the pricing of our long-term contracts may exceed market value. We purchase our polysilicon under fixed-price long-term supply agreements; purchases in fiscal 2016 under these agreements significantly exceeded market value and the volume contracted to be purchased in fiscal 2017 exceeds our planned utilization, which may result in higher inventory balances until we are able to fully utilize the polysilicon inventory in future periods. We have also elected to sell polysilicon inventory in excess of short-term needs to third parties at a loss, and may enter into further similar transactions in future periods. For more information about these risks, please see "—Our long-term, firm commitment supply agreements could result in excess or insufficient inventory, place us at a competitive disadvantage on pricing, or lead to disputes, each of which could impair our ability to meet our cost reduction roadmap" and "—We will continue to be dependent on a limited number of third-party suppliers for certain raw materials and components for our products, which could prevent us from delivering our products to our customers within required timeframes and could in turn result in sales and installation delays, cancellations, penalty payments and loss of market share" under "Part 1. Item 1A. Risk Factors—Risks Related to Our Supply Chain" in this Annual Report on Form 10-K.

Projects Under Contract


57

Table of Contents


The table below presents significant construction and development projects under contract as of January 1, 2017:
Project
 
Location
 
Size (MW)
 
Third-Party Owner / Purchaser(s)
 
Power Purchase Agreement(s)
 
Expected Substantial Completion of Project1
Iberdrola Gala Solar Project
 
Oregon, USA
 
71
 
Avangrid Renewables, LLC
 
Customer A
 
2017
Boulder Solar Project II
 
Nevada, USA
 
62
 
AEP Renewables, LLC
 
Sierra Pacific Power Company
 
2017
1Expected completion of revenue recognition assumes completion of construction in the stated fiscal year.


As of January 1, 2017, an aggregate of approximately $222.6 million of remaining revenue is expected to be recognized on projects reflected in the table above through the expected completion dates noted. Projects will be removed from the table above in the period in which substantially all of the revenue for such project has been recognized.

Projects with Executed Power Purchase Agreements - Not Sold / Not Under Contract

The table below presents significant construction and development projects with executed PPAs, but not sold or under contract as of January 1, 2017:
Project
 
Location
 
Size (MW)
 
Power Purchase Agreement(s)
 
Expected Substantial Completion of Project1
Ticul Solar Projects
 
Mexico
 
399
 
Comision Federal Electricidad
 
2018
Guajiro Solar Project
 
Mexico
 
117
 
Comision Federal Electricidad
 
2018
El Pelicano Solar Project
 
Chile
 
111
 
Empresa de Transporte de Pasajeros Metro S.A.
 
2017
1 
Expected completion of revenue recognition assumes completion of construction and sale of the project in the stated fiscal year.

Our project pipeline extends beyond the projects represented in the tables above. Significant projects with development and milestone activities in progress will be excluded from the table above until an associated PPA has been executed.

Components of Results of Operations

The following section describes certain line items in our Consolidated Statements of Operations:

Revenue

We recognize revenue from the following activities and transactions within our end-customer segments:

Solar power components: the sale of panels and balance of system components, primarily to dealers, system integrators and distributors, in some cases on a multi-year, firm commitment basis.

Solar power systems: the design, manufacture, and sale of high-performance rooftop and ground-mounted solar power systems under construction and development agreements.

Residential leases: revenue recognized on systems under lease agreements with residential customers for terms of up to 20 years.

Other: revenue related to our solar power services and solutions, such as post-installation systems monitoring and maintenance in connection with construction contracts and commercial PPAs.

For a discussion of how and when we recognize revenue, see "—Critical Accounting Estimates—Revenue Recognition."

Cost of Revenue

58

Table of Contents



We generally recognize our cost of revenue in the same period that we recognize related revenue. Our cost of revenue fluctuates from period to period due to the mix of projects that we complete and the associated revenue that we recognize, particularly for construction contracts and large-scale development projects involving real estate. For a discussion of how and when we recognize revenue, see "—Critical Accounting Estimates—Revenue Recognition."

The cost of solar panels is the single largest cost element in our cost of revenue. Our cost of solar panels consists primarily of: (i) polysilicon, silicon ingots and wafers used in the production of solar cells; (ii) other materials and chemicals including glass, frame, and backing; and (iii) direct labor costs and assembly costs. Other cost of revenue associated with the construction of solar power systems includes real estate, mounting systems, inverters, capitalized financing costs, and construction subcontract and dealer costs. Other factors that contribute to our cost of revenue include salaries and personnel-related costs, depreciation, facilities related charges, freight, as well as charges related to sales of raw material inventory and write-downs on certain solar power development projects when costs exceed expected selling prices.

Gross Margin

Our gross margin each quarter is affected by a number of factors, including average selling prices for our solar power components, the timing and nature of project revenue recognition, the types of projects in progress, the gross margins estimated for those projects in progress, our product mix, our actual manufacturing costs, the utilization rate of our solar cell manufacturing facilities, and actual overhead costs.

Research and Development

Research and development expense consists primarily of salaries and related personnel costs; depreciation of equipment; and the cost of solar panel materials, various prototyping materials, and services used for the development and testing of products. Research and development expense is reported net of contributions under collaborative arrangements.

Sales, General and Administrative

Sales, general and administrative expense consists primarily of salaries and related personnel costs, professional fees, bad debt expenses, and other selling and marketing expenses.

Restructuring

Restructuring expense in fiscal 2016 consists mainly of costs associated with our August 2016 and December 2016 restructuring plans aimed to realign our downstream investments, optimize our supply chain, and reduce operating expenses in response to expected near-term challenges. Charges in connection with these plans consist primarily of asset impairments, severance benefits, and lease and related termination costs. For more information, see "Item 8. Financial Statements and Supplementary Data—Note 8. Restructuring" in this Annual Report.

Restructuring expense in fiscal 2015 and 2014 consists mainly of costs associated with our November 2014 reorganization plan aimed towards realigning resources consistently with SunPower's global strategy and improving overall operating efficiency and cost structure. Charges in connection with this plan are primarily related to severance benefits. Remaining restructuring costs are related to plans effected in prior fiscal periods. Restructuring activities related to these legacy plans were substantially complete as of January 1, 2017; however, we expect to continue to incur costs as we finalize previous estimates and actions in connection with these plans, primarily due to other costs, such as legal services.

Other Income (Expense), Net

Interest expense primarily relates to: (i) amortization expense recorded for warrants issued to Total S.A. in connection with the Liquidity Support Agreement executed in the first quarter of fiscal 2012; (ii) debt under our senior convertible debentures; (iii) fees for our outstanding letters of credit; and (iv) other outstanding bank and project debt.

Other, net includes gains or losses on foreign exchange and derivatives as well as gains or losses related to sales and impairments of certain investments.

In fiscal 2016, significant items contributing to Other income (expense), net consisted of a gain on the settlement of preexisting relationships in connection with our acquisition of AUOSP, a loss on our equity method investment in connection with our acquisition of AUOSP, and goodwill impairment. For more information on these items, see "—Note 3. Business

59

Table of Contents


Combinations" and "—Note 4. Goodwill and Other Intangible Assets" under "Item 8. Financial Statements and Supplementary Data" in this Annual Report.

Income Taxes

Deferred tax assets and liabilities are recognized for temporary differences between financial statement and income tax bases of assets and liabilities. Valuation allowances are provided against deferred tax assets when management cannot conclude that it is more likely than not that some portion or all deferred tax assets will be realized.

We currently benefit from income tax holidays incentives in the Philippines in accordance with our registration with the Philippine Economic Zone Authority ("PEZA"). We also benefit from a tax holiday granted by the Malaysian government to our former joint venture AUOSP (now our wholly-owned subsidiary, SunPower Malaysia Manufacturing Sdn. Bhd.) subject to certain hiring, capital spending, and manufacturing requirements. We have an auxiliary company ruling in Switzerland, where we sell our solar power products, which currently reduces our Swiss tax rate. For additional information see "—Note 1. The Company and Summary of Significant Accounting Policies" and "—Note 13. Income Taxes" under "Item 8. Financial Statements and Supplementary Data" in this Annual Report on Form 10-K.

For financial reporting purposes, during periods when we were a subsidiary of Cypress, income tax expense and deferred income tax balances were calculated as if we were a separate entity and had prepared our own separate tax return. Effective with the closing of our public offering of common stock in June 2006, we were no longer eligible to file federal and most state consolidated tax returns with Cypress. As of September 29, 2008, Cypress completed a spin-off of all of its shares of our former class B common stock to its shareholders, so we are no longer eligible to file any remaining state consolidated tax returns with Cypress. Under our tax sharing agreement with Cypress, we agreed to pay Cypress for any federal and state income tax credit or net operating loss carryforwards utilized in our federal and state tax returns in subsequent periods that originated while our results were included in Cypress’s federal tax returns.

Equity in Earnings (Loss) of Unconsolidated Investees

Equity in earnings (loss) of unconsolidated investees represents our reportable share of earnings (loss) generated from entities in which we own an equity interest accounted for under the equity method.

Net Loss Attributable to Noncontrolling Interests and Redeemable Noncontrolling Interests

We have entered into facilities with third-party investors under which the parties invest in entities that hold SunPower solar power systems and leases with residential customers. We determined that we hold controlling interests in these less-than-wholly-owned entities and have fully consolidated these entities as a result. The investors were determined to hold noncontrolling interests, some of which are redeemable at the option of the noncontrolling interest holder. We apply the hypothetical liquidation at book value method in allocating recorded net income (loss) to each investor based on the change in the reporting period of the amount of net assets of the entity to which each investor would be entitled to under the governing contractual arrangements in a liquidation scenario.

Results of Operations

Revenue
 
 
Fiscal Year
(In thousands)
 
2016
 
% of total revenue
 
2015
 
% of total revenue
 
2014
 
% of total revenue
Distributed Generation
 
 
 
 
 
 
 
 
 
 
 
 
    Residential
 
$
720,331

 
28%
 
$
643,520

 
41%
 
$
655,936

 
22%
    Commercial
 
436,915

 
17%
 
277,143

 
17%
 
361,828

 
12%
Power Plant
 
1,402,316

 
55%
 
655,810

 
42%
 
2,009,501

 
66%
Total revenue
 
$
2,559,562

 
 
 
$
1,576,473

 
 
 
$
3,027,265

 
 

Total Revenue:  Our total revenue increased by 62% during fiscal 2016 as compared to fiscal 2015, primarily due to increased sales of solar power systems across all Segments and particularly due to revenue recognized on the sale of several

60

Table of Contents


utility-scale solar power projects in the Power Plant Segment during the second half of fiscal 2016, such as the 128 MW Henrietta project and the 125 MW Boulder Solar I project.

Our total revenue decreased 48% during fiscal 2015 as compared to fiscal 2014 primarily because during fiscal 2015 we deferred the recognition of any revenue or profit on the sale of projects involving real estate to 8point3 Energy Partners under the accounting treatment described in "Item 8. Financial Statements and Supplementary Data—Note 3. 8point3 Energy Partners LP" in our Annual Report on Form 10-K for the fiscal year ended January 3, 2016. The decrease in revenue in fiscal 2015 was also due to substantial completion of revenue recognition at the end of fiscal 2014 on certain large-scale solar power systems. A decline in sales of solar power systems and components to residential and commercial customers also contributed to the period-over-period decrease in total revenue.

Concentrations: The Power Plant Segment as a percentage of total revenue recognized was approximately 55% during fiscal 2016 as compared to 42% during fiscal 2015. The revenue for the Power Plant Segment as a percentage of total revenue recognized increased primarily due to: (i) an increase in the volume of utility-scale solar power projects sold in fiscal 2016 in our Power Plants Segment, and (ii) an increase in the revenue recognized in fiscal 2016 in our Power Plant Segment due to the accounting treatment of certain utility-scale projects as partial sales of real estate as described in "Item 8. Financial Statements and Supplementary Data—Note 10. Equity Method Investments" in this Annual Report on Form 10-K.

Sales for the Power Plant Segment as a percentage of total revenue recognized were approximately 42% and 66% during fiscal 2015 and fiscal 2014, respectively. The revenue for the Power Plant Segment as a percentage of total revenue recognized decreased primarily because we deferred the recognition of any revenue or profit on the sale of projects involving real estate to 8point3 Energy Partners under the accounting treatment described in "Item 8. Financial Statements and Supplementary Data—Note 3. 8point3 Energy Partners LP" in our Annual Report on Form 10-K for the fiscal year ended January 3, 2016. The decrease during fiscal 2015 was additionally driven by substantial completion of revenue recognition at the end of fiscal 2014 on certain large-scale solar power systems.

The table below represents our significant customers that accounted for greater than 10 percent of total revenue in fiscal 2016, 2015, and 2014, respectively.
 
 
Fiscal Year
Revenue
 
2016
 
2015
 
2014
Significant Customers:
 
Business Segment
 
 
 
 
 
 
8point3 Energy Partners
 
Power Plant
 
10%
 
n/a

 
n/a

Southern Renewable Partnerships, LLC
 
Power Plant
 
15%
 
n/a

 
n/a

MidAmerican Energy Holdings Company
 
Power Plant
 
*
 
14
%
 
49
%
*
denotes less than 10% during the period

Residential Revenue: Residential revenue increased 12% percent during fiscal 2016 as compared to fiscal 2015, primarily due to an increase in sales of residential solar power systems in North America driven by stronger sales through our dealer network, an increase in the number of leases placed in service under our residential leasing program within the United States, and an increase in the proportion of capital leases relative to total leases placed in service.

Residential revenue decreased 2% during fiscal 2015 as compared to fiscal 2014 primarily due to a decline in the sales of solar power components and systems to our residential customers, particularly in Japan, where a reduction in the country's feed-in tariff during the last half of fiscal 2015 reduced demand for solar power systems and the decline in the value of the Japanese Yen reduced demand for imported goods in general. The decrease in residential revenue was partially offset by an increase in residential component sales in North America driven by stronger sales through our dealer network and an increase in the number of leases placed in service under our residential leasing program within the United States.

Commercial Revenue:  Commercial revenue increased 58% during fiscal 2016 as compared to fiscal 2015, primarily because of stronger sales of commercial components and systems in North America due to a favorable policy environment that encouraged investment in renewable energy by commercial customers.

Commercial revenue decreased 23% during fiscal 2015 as compared to fiscal 2014 primarily because we deferred the recognition of any revenue or profit on the sale to 8point3 Energy Partners of projects involving real estate under the accounting treatment described in "Item 8. Financial Statements and Supplementary Data—Note 3. 8point3 Energy Partners

61

Table of Contents


LP" in our Annual Report on Form 10-K for the fiscal year ended January 3, 2016. The decrease in revenue during fiscal 2015 was also due to the completion of certain commercial solar power system projects, and the associated revenue recognition, during fiscal 2014 and a decrease in commercial component sales across all geographies, particularly in Japan, where a reduction in the country's feed-in tariff during the third quarter of fiscal 2015 reduced demand for solar power systems and the decline in the value of the Japanese Yen reduced demand for imported goods in general.

Power Plant Revenue: Power Plant revenue increased 114% during fiscal 2016 as compared to fiscal 2015, respectively, primarily due to: (i) an increase in the volume of utility-scale solar power projects sold in fiscal 2016, primarily in North America, including the 128 MW Henrietta project and the 125 MW Boulder Solar I project, and (ii) the deferral of revenue in fiscal 2015 due to the accounting treatment of certain utility-scale projects as partial sales of real estate as described in "Item 8. Financial Statements and Supplementary Data—Note 10. Equity Method Investments" in this Annual Report.

Power Plant revenue decreased 67% during fiscal 2015 as compared to fiscal 2014 primarily because we deferred the recognition of any revenue or profit on the sale of projects involving real estate to 8point3 Energy Partners under the accounting treatment described in "Item 8. Financial Statements and Supplementary Data—Note 3. 8point3 Energy Partners LP" in our Annual Report on Form 10-K for the fiscal year ended January 3, 2016. The decrease in revenue during fiscal 2015 was also due to substantial completion of revenue recognition at the end of fiscal 2014 on certain large-scale solar power systems located within the United States.

Cost of Revenue
 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Distributed Generation
 
 
 
 
 
 
    Residential
 
$
603,559

 
$
508,449

 
$
541,812

    Commercial
 
438,711

 
259,600

 
326,324

Power Plant
 
1,327,326

 
563,778

 
1,534,002

Total cost of revenue
 
$
2,369,596

 
$
1,331,827

 
$
2,402,138

Total cost of revenue as a percentage of revenue
 
93
%
 
84
%
 
79
%
Total gross margin percentage
 
7
%
 
16
%
 
21
%

Total Cost of Revenue: Our total cost of revenue increased 78% during fiscal 2016 as compared to fiscal 2015, primarily as a result of the increase in the recognition of revenue and corresponding costs of certain large-scale solar power systems within the United States during fiscal 2016, as well as write-downs totaling $46.2 million on certain solar power development projects during fiscal 2016. The increase in total cost of revenue during 2016 was also a result of charges totaling $58.2 million recorded in fiscal 2016 in connection with the contracted sale of raw material inventory to third parties.

Our total cost of revenue decreased 45% in fiscal 2015 as compared to fiscal 2014 primarily because we deferred the recognition of any revenue or profit, and corresponding costs, on the sale of projects involving real estate to 8point3 Energy Partners under the accounting treatment described in "Item 8. Financial Statements and Supplementary Data—Note 3. 8point3 Energy Partners LP" in our Annual Report on Form 10-K for the fiscal year ended January 3, 2016. The decrease in the cost of sales during fiscal 2015 was also a result of the substantial completion at the end of fiscal 2014 of recognition of revenue and corresponding costs of certain large-scale solar power systems within the United States.

Gross Margin
 
 
Fiscal Year
 
 
2016
 
2015
 
2014
Distributed Generation
 
 
 
 
 
 
    Residential
 
16%
 
21%
 
17%
    Commercial
 
—%
 
6%
 
10%
Power Plant
 
5%
 
14%
 
24%

Residential Gross Margin: Gross margin for our Residential Segment decreased five percentage points during fiscal 2016 as compared to fiscal 2015, as a result of declining average selling prices in Japan, where a reduction in the country's

62

Table of Contents


feed-in tariff during the last half of fiscal 2015 continued to reduce demand for solar power systems and the volatility of the value of the Japanese Yen reduced demand for imported goods in general, partially offset by an increased volume of sales with favorable margins for residential leases and higher average selling prices for residential components and systems in North America. The decrease in gross margin during 2016 was also a result of charges totaling $15.2 million recorded in fiscal 2016 in connection with the contracted sale of raw material inventory to third parties, as compared to a similar charge of $10.9 million recorded in fiscal 2015.

Gross margin for our Residential Segment increased four percentage points during fiscal 2015 as compared to fiscal 2014 primarily as a result of increased volume of sales with favorable margins for residential leases and solar power systems and components in the United States, partially offset by lower margins on solar power components resulting from declines in average selling prices in Japan and a charge of $10.9 million recorded in fiscal 2015 in connection with the contracted sale of raw material inventory to a third party.

Commercial Gross Margin: Gross margin for our Commercial Segment decreased six percentage points during fiscal 2016 as compared to fiscal 2015, primarily because of pricing pressures on sales of solar power systems due to factors such as an increase in the internal rate of return expected by our customers in light of market conditions, as well as declining average selling prices in Japan, where a reduction in the country's feed-in tariff during the during the last half of fiscal 2015 continued to reduce demand for solar power systems and the volatility of the value of the Japanese Yen reduced demand for imported goods in general. The decrease in gross margin during 2016 was also a result of charges totaling $12.5 million recorded in fiscal 2016 in connection with the contracted sale of raw material inventory to third parties, as compared to a similar charge of $5.7 million recorded in fiscal 2015.

Gross margin for our Commercial Segment decreased four percentage points during fiscal 2015 as compared to fiscal 2014 primarily because we deferred the recognition of any profit on the sale of projects involving real estate to 8point3 Energy Partners under the accounting treatment described in "Item 8. Financial Statements—Notes to Consolidated Financial Statements—Note 3. 8point3 Energy Partners LP" in our Annual Report on Form 10-K for the fiscal year ended January 3, 2016. Gross margin during fiscal 2015 also decreased as a result of higher than expected costs on and changes in the scope of certain commercial EPC projects in the United States and a charge of $5.7 million recorded in fiscal 2015 in connection with the contracted sale of raw material inventory to a third party.

Power Plant Gross Margin: Gross margin for our Power Plant Segment decreased nine percentage points during fiscal 2016 as compared to fiscal 2015 primarily because we experienced pressure on project pricing due to increased global competition and other factors, including an increase in the internal rate of return expected by our customers in light of market conditions, which led to write-downs totaling $46.2 million in fiscal 2016 on certain solar power development projects. The decrease in gross margin during 2016 was also a result of charges totaling $30.5 million recorded in fiscal 2016 in connection with the contracted sale of raw material inventory to third parties, as compared to a similar charge of $16.1 million recorded in fiscal 2015.

Gross margin for our Power Plant Segment decreased 10 percentage points during fiscal 2015 as compared to fiscal 2014 primarily because we deferred the recognition of any profit on the sale to 8point3 Energy Partners of projects involving real estate under the accounting treatment described in "Item 8. Financial Statements and Supplementary Data—Note 3. 8point3 Energy Partners LP" in our Annual Report on Form 10-K for the fiscal year ended January 3, 2016. The decrease in gross margin during 2015 was also a result of the substantial completion of large-scale solar power systems with favorable margins at the end of fiscal 2014 within the United States and a charge of $16.1 million recorded in fiscal 2015 in connection with the contracted sale of raw material inventory to a third party.

Research and Development ("R&D")
 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
R&D
 
$
116,130

 
$
99,063

 
$
73,343

As a percentage of revenue
 
5
%
 
6
%
 
2
%

R&D expense increased $17.1 million in fiscal 2016 as compared to fiscal 2015, primarily due to an increase in labor costs as a result of additional headcount and salary related expenses, as well as an increase in other net expenses such as materials, consulting and outside services as we continue to develop our next generation solar technology and expand our product offering. The remaining increase was a result of other net expenses to support R&D programs as well as amortization

63

Table of Contents


of intangible assets attributable to R&D activity.
R&D expense increased $25.7 million or 35%, in fiscal 2015 as compared to fiscal 2014 primarily due to a $16.8 million increase in labor costs as a result of additional headcount and salary related expenses and a $4.5 million increase in consulting and outside services as we continue to develop our next generation solar technology and expand our product offerings. The remaining increase was a result of other net expenses to support R&D programs as well as amortization of intangible assets attributable to R&D activity. These increases were partially offset by contributions under the R&D Agreement with Total.

Sales, General and Administrative ("SG&A")
 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
SG&A
 
$
329,061

 
$
345,486

 
$
288,321

As a percentage of revenue
 
13
%
 
22
%
 
10
%

SG&A expense decreased $16.4 million in fiscal 2016 as compared to fiscal 2015 primarily due to labor savings resulting from our August 2016 and December 2016 restructuring plans, as well as a decrease in stock-based compensation expense attributable to SG&A functions. The decrease was partially offset by an increase in marketing activity for residential and commercial products in North America and through digital media, as well as increased other costs related to ongoing legal proceedings and non-cash charges primarily related to depreciation and the amortization and disposition of intangible assets.

SG&A expense increased $57.2 million, or 19.8%, during fiscal 2015 as compared to fiscal 2014 due to a $21.4 million increase in selling and marketing expenses as we grow our sales teams and increase our marketing activity in North America and through digital media and a $26.5 million increase in legal, consulting, and other costs related to the formation and IPO of 8point3 Energy Partners, acquisitions, and ongoing legal proceedings.

Restructuring Charges
 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Restructuring charges
 
$
207,189

 
$
6,391

 
$
12,223

As a percentage of revenue
 
8
%
 
%
 
%

Restructuring charges increased $200.8 million during fiscal 2016 as compared to fiscal 2015 due to our August 2016 and December 2016 restructuring plans, $166.7 million of which consisted of non-cash charges related to asset impairments. The remaining charges were primarily related to severance benefits and lease and related termination costs.

Restructuring charges decreased $5.8 million, or 48%, during fiscal 2015 as compared to fiscal 2014 and were primarily related to severance and other charges associated with our November 2014 restructuring plan. Remaining charges are associated with legacy restructuring plans approved in fiscal 2012 and 2011.

See "Item 8. Financial Statements and Supplementary Data—Note 8. Restructuring" for further information regarding our restructuring plans.


64

Table of Contents


Other Income (Expense), Net

 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Interest income
 
$
2,652

 
$
2,120

 
$
2,583

Interest expense
 
(60,735
)
 
(43,796
)
 
(69,658
)
Gain on settlement of preexisting relationships in connection with acquisition
 
203,252

 

 

Loss on equity method investment in connection with acquisition
 
(90,946
)
 

 

Goodwill impairment
 
(147,365
)
 

 

Other, net
 
(9,039
)
 
5,659

 
449

Other expense, net
 
$
(102,181
)
 
$
(36,017
)
 
$
(66,626
)
As a percentage of revenue
 
(4
)%
 
(2
)%
 
(2
)%
    
Other expense, net increased $66.2 million, in fiscal 2016 as compared to fiscal 2015, primarily driven by a $147.4 million expense related to the impairment of goodwill and a $90.9 million expense related to the impairment of our equity method investment in AUOSP, partially offset by a $203.3 million gain recognized on the termination of our preexisting relationships upon completing our acquisition of AUOSP, all of which occurred in the third quarter of fiscal 2016. For more information on these transactions, see "—Note 3. Business Combinations" and "—Note 4. Goodwill and Other Intangible Assets" in "Item 8. Financial Statements and Supplementary Data" in this Annual Report on Form 10-K.

The remainder of the increase in Other expense, net was driven by the gain recognized on the sale of a residential lease portfolio to 8point3 Energy Partners during fiscal 2015 which did not recur in fiscal 2016, an increase in interest expense in fiscal 2016 due to the issuance of the 4.00% debentures due 2023 late in the fourth quarter of fiscal 2015, and additional interest incurred on financing activities related to our residential lease business in fiscal 2016, as well as unfavorable changes in the fair value of foreign currency derivatives and other net expenses.

Other expense, net decreased $30.6 million, or 46%, in fiscal 2015 as compared to fiscal 2014 primarily driven by the $27.9 million gain recognized on the sale of a residential lease portfolio to 8point3 Energy Partners, a decrease in interest expense due to the maturity of the 4.50% debentures in March of fiscal 2015, as well as favorable changes in the fair value of foreign currency derivatives and other net expenses.

Income Taxes
 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Provision for income taxes
 
$
(7,319
)
 
$
(66,694
)
 
$
(8,760
)
As a percentage of revenue
 
 %
 
(4
)%
 
%

In fiscal 2016, our income tax provision of $7.3 million, on a loss before income taxes and equity in earnings of unconsolidated investees of $564.6 million, was primarily due to tax expense in profitable jurisdictions, the amortization of U.S. prepaid income tax related to intercompany transactions, offset by tax benefits from provision to return adjustments in U.S. and foreign jurisdictions and realization of the tax benefit related to net operating losses that are eligible to be claimed as a refund on the prior year U.S. tax returns.

In fiscal 2015, our income tax provision of $66.7 million on a loss before income taxes and equity in earnings of unconsolidated investees of $242.3 million was due to an increase in taxable income resulting from gains realized primarily on the sale of projects involving real estate and a coinciding utilization of carryforward tax attributes; however, revenue and margin on the transactions that generated tax gains were deferred due to real estate accounting guidelines.  For further information on the accounting treatment of projects involving real estate, see "Item 8. Financial Statements and Supplementary Data—Note 10. Equity Method Investments" in this Annual Report on Form 10-K.  Other factors contributing to the increase in provision for income taxes in fiscal 2015 were a shift in the geographic mix of taxable income to jurisdictions with higher statutory tax rates, prior year transfer pricing adjustments, intracompany profit deferral and accrual of unrecognized tax benefits, and deemed foreign dividends.


65

Table of Contents


A material amount of our total revenue is generated from customers located outside of the United States, and a substantial portion of our assets and employees are located outside of the United States. U.S. income taxes and foreign withholding taxes have not been provided on the undistributed earnings of our non-U.S. subsidiaries as such earnings are intended to be indefinitely reinvested in operations outside the United States to the extent that such earnings have not been currently or previously subjected to taxation of the United States.

We record a valuation allowance to reduce our U.S., France, and Spain deferred tax assets to the amount that is more likely than not to be realized. In assessing the need for a valuation allowance, we consider historical levels of income, expectations and risks associated with the estimates of future taxable income and ongoing prudent and feasible tax planning strategies. In the event we determine that we would be able to realize additional deferred tax assets in the future in excess of the net recorded amount, or if we subsequently determine that realization of an amount previously recorded is unlikely, we would record an adjustment to the deferred tax asset valuation allowance, which would change income tax in the period of adjustment. As of January 1, 2017, we believe there is insufficient evidence to realize additional deferred tax assets other than U.S. net operating losses that can be carried back for a refund on prior year tax returns.

Equity in Earnings of Unconsolidated Investees
 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Equity in earnings of unconsolidated investees
 
$
28,070

 
$
9,569

 
$
7,241

As a percentage of revenue
 
1
%
 
1
%
 
%

Our equity in earnings of unconsolidated investees increased $18.5 million in fiscal 2016, compared to fiscal 2015, primarily due to our share of the earnings generated by the activities of the 8point3 Group during fiscal 2016 as well as our share of the earnings generated by the activities of our former joint venture AUOSP during fiscal 2016 prior to the acquisition and subsequent consolidation of AUOSP on September 29, 2016. For more information on the acquisition of AUOSP, see "Item 8. Financial Statements and Supplemental Data—Note 3. Business Combinations" in this Annual Report on Form 10-K.

In fiscal 2015 and 2014, our equity in earnings of unconsolidated investees was a net gain of $9.6 million and $7.2 million, respectively, and was primarily due to increased activities at AUOSP during the two fiscal years. The $9.6 million net gain in fiscal 2015 also includes the activities of the 8point3 Group that took place during the last half of fiscal 2015.

Net Income (loss)
 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Net income (loss)
 
$
(543,844
)
 
$
(299,436
)
 
$
183,095


Net loss increased by $244.4 million in fiscal 2016 as compared to fiscal 2015. The increase in net loss was primarily driven by: (i) a $200.8 million increase in restructuring expense related to our August 2016 and December 2016 restructuring plans; (ii) a $66.2 million increase in other expense, net primarily driven by the impairment of goodwill and the loss on our equity method investment in our former joint venture AUOSP during fiscal 2016 (partially offset by the settlement of preexisting relationships with AUOSP), a gain recognized on the sale of a residential lease portfolio to 8point3 Energy Partners during fiscal 2015 which did not recur in fiscal 2016, an overall increase in interest expense in fiscal 2016 due to the issuance of our 4.00% debentures late in the fourth quarter of fiscal 2015 and additional interest incurred on financing activities related to our residential lease business, and unfavorable changes in the fair value of foreign currency derivatives and other net expenses; (iii) a decrease in gross margin of $54.7 million primarily driven by charges totaling $58.2 million recorded in fiscal 2016 in connection with the contracted sale of raw material inventory to third parties, partially offset by a similar charge of $32.7 million in fiscal 2015, write-downs totaling $46.2 million on certain solar power development projects during fiscal 2016 that were based on the estimated selling price of such projects, and by declines in the margins of our Residential and Commercial Segments due to lower average selling prices in some markets; and (iv) a $0.6 million net increase in operating expenses due to increased marketing spend and increased R&D headcount, mostly offset by a reduction in total labor costs and stock-based compensation expense in SG&A functions resulting from our August 2016 and December 2016 restructuring plans. The increase in net loss was partially offset by: (i) a $59.4 million decrease in provision for income taxes primarily due to a shift from domestic taxable income to domestic taxable loss which reduced the overall tax provision in the period; and (ii) a $18.5 million increase in our equity in earnings of unconsolidated investees due to the activities of the 8point3 Group during fiscal 2016 and the activities at our former AUOSP joint venture prior to our acquisition of AUOSP.


66

Table of Contents


Net income decreased by $482.5 million and changed from a net income to a net loss in fiscal 2015 as compared to fiscal 2014. The decrease in net income (loss) was primarily driven by: (i) a $380.5 million decrease in gross margin, primarily due to the substantial completion of revenue recognition on various large-scale solar power systems at the end of fiscal 2014 and the deferral of all profits on transactions with the 8point3 Group involving real estate in fiscal 2015; (ii) a $77.1 million increase in operating expenses due to increased headcount and marketing spend and costs incurred for acquisition-related diligence and the formation and IPO of 8point3 Energy Partners; and (iii) a $57.9 million increase in income tax due to an increase in taxable income resulting from gains realized primarily on the sale of projects involving real estate, on which revenue was deferred, and a coinciding utilization of carryforward tax attributes. The decrease in net income was partially offset by: (i) a $30.6 million decrease in Other expense, net driven by the gain recognized on the sale of a residential lease portfolio to 8point3 Energy Partners, a decrease in interest expense due to the maturity of the 4.50% debentures in March of fiscal 2015, as well as favorable changes in the fair value of foreign currency derivatives and other net expenses; and (ii) a $2.3 million increase in our equity in earnings of unconsolidated investees due to activities at AUOSP and the 8point3 Group during fiscal 2015.

Information about other significant variances in our results of operations is described above.

Net Loss Attributable to Noncontrolling Interests and Redeemable Noncontrolling Interests

 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Net loss attributable to noncontrolling interests and redeemable noncontrolling interests
 
$
72,780

 
$
112,417

 
$
62,799


We have entered into facilities with third-party tax equity investors under which the investors invest in a structure known as a partnership flip. We determined that we hold controlling interests in these less-than-wholly-owned entities and therefore we have fully consolidated these entities. We apply the hypothetical liquidation at book value method in allocating recorded net income (loss) to each investor based on the change in the reporting period, of the amount of net assets of the entity to which each investor would be entitled to under the governing contractual arrangements in a liquidation scenario.

In fiscal 2016, 2015, and 2014, we attributed $72.8 million, $112.4 million and $62.8 million, respectively, of net losses primarily to the third-party investors as a result of allocating certain assets, including tax credits and accelerated tax depreciation benefits, to the investors. The $39.6 million decrease in net loss attributable to noncontrolling interests and redeemable noncontrolling interests is primarily attributable to a decrease in income per watt for leases placed in service under new facilities executed with third-party investors, partially offset by an increase in total number of leases placed in service under new and existing facilities with third-party investors. The $49.6 million increase in net loss attributable to noncontrolling interests and redeemable noncontrolling interests in fiscal 2015, as compared to fiscal 2014, is primarily attributable to additional leases placed in service under new facilities executed with third-party investors in fiscal 2015.

Critical Accounting Estimates

We prepare our consolidated financial statements in conformity with U.S. generally accepted accounting principles, which requires management to make estimates and assumptions that affect the amounts of assets, liabilities, revenues, and expenses recorded in our financial statements. We base our estimates on historical experience and on various other assumptions that we believe to be reasonable under the circumstances, the results of which form the basis for making judgments about the carrying values of assets and liabilities that are not readily apparent from other sources. Actual results may differ from these estimates under different assumptions and conditions. In addition to our most critical estimates discussed below, we also have other key accounting policies that are less subjective and, therefore, judgments involved in their application would not have a material impact on our reported results of operations (See "Item 8. Financial Statements and Supplementary Data—Note 1. The Company and Summary of Significant Accounting Policies" in this Annual Report on Form 10-K).

Revenue Recognition

Solar Power Components

We sell our solar panels and balance of system components primarily to dealers, system integrators and distributors, and recognize revenue, net of accruals for estimated sales returns, when persuasive evidence of an arrangement exists, delivery of the product has occurred, title and risk of loss has passed to the customer, the sales price is fixed or determinable, collectability

67

Table of Contents


of the resulting receivable is reasonably assured and the risks and rewards of ownership have passed to the customer. Other than standard warranty obligations, there are no rights of return and there are no significant post-shipment obligations, including installation, training, or customer acceptance clauses, with any of our customers that could have an impact on revenue recognition. Our revenue recognition policy is consistent across all geographic areas and end-customer segments.

Construction Contracts

Revenue is also composed of EPC projects which are governed by customer contracts that require us to deliver functioning solar power systems and are generally completed within three to twelve months from commencement of construction. Construction on large projects may be completed within eighteen to thirty six months, depending on the size and location. We recognize revenue from fixed-price construction contracts, which do not include land or land rights, using the percentage-of-completion method of accounting. Under this method, revenue arising from fixed price construction contracts is recognized as work is performed based on the percentage of incurred costs to estimated total forecasted costs.

Incurred costs used in our percentage-of-completion calculation include all direct material, labor and subcontract costs, and those indirect costs related to contract performance, such as indirect labor, supplies, and tools. Project material costs are included in incurred costs when the project materials have been installed by being permanently attached or fitted to the solar power system as required by the project’s engineering design.

In addition to an EPC deliverable, a limited number of arrangements also include multiple deliverables such as post-installation systems monitoring and maintenance. For contracts with separately priced monitoring and maintenance, we recognize revenue related to such separately priced elements over the contract period. For contracts including monitoring and maintenance not separately priced, we determined that post-installation systems monitoring and maintenance qualify as separate units of accounting. Such post-installation monitoring and maintenance are deferred at the time the contract is executed based on the best estimate of selling price on a standalone basis and are recognized to revenue over the contractual term. The remaining EPC revenue is recognized on a percentage-of-completion basis.

In addition, when arrangements include contingent revenue clauses, such as customer termination or put rights for non-performance, we defer the contingent revenue if there is a reasonable possibility that such rights or contingencies may be triggered. In certain limited cases, we could be required to buy-back a customer’s system at fair value on specified future dates if certain minimum performance thresholds are not met for specified periods. To date, no such repurchase obligations have been triggered (see "Note 9. Commitments and Contingencies" under "Item 8. Financial Statements and Supplementary Data—Notes to Consolidated Financial Statements" in this Annual Report on Form 10-K).

Provisions for estimated losses on uncompleted contracts, if any, are recognized in the period in which the loss first becomes probable and reasonably estimable. Contracts may include profit incentives such as milestone bonuses. These profit incentives are included in the contract value when their realization is reasonably assured.

Development Projects

We develop and sell solar power plants which generally include the sale or lease of related real estate. Revenue recognition for these solar power plants require adherence to specific guidance for real estate sales, which provides that if we execute a sale of land in conjunction with an EPC contract requiring the future development of the property, we recognize revenue and the corresponding costs under the full accrual method when all of the following requirements are met: the sale is consummated, the buyer's initial and any continuing investments are adequate, the resulting receivables are not subject to subordination, the future costs to develop the property can be reasonably estimated, we have transferred the customary risk and rewards of ownership to the buyer, and we do not have prohibited continuing involvement with the property or the buyer. In general, a sale is consummated upon the execution of an agreement documenting the terms of the sale and receipt of a minimum initial payment by the buyer to substantiate the transfer of risk to the buyer. Depending on the value of the initial and continuing investment of the buyer, and provided the recovery of the costs of the solar power plant are assured if the buyer defaults, we may defer revenue and profit during construction by aligning our revenue recognition and release of deferred project costs to cost of sales with the receipt of payment from the buyer. At the time we have unconditionally received payment from the buyer, revenue is recognized and deferred project costs are released to cost of sales at the same rate of profit estimated throughout the construction of the project. Further, in situations where we have a noncontrolling equity interest in the buyer, we may defer all or a portion of our revenue or profit in accordance with specific guidance for partial sales of real estate.
  
We have determined that our standard product and workmanship warranties do not represent prohibited forms of continuing involvement that would otherwise preclude revenue recognition as these warranties do not result in the retention of substantial risks or rewards of ownership or result in a seller guarantee as described in real estate accounting guidance.

68

Table of Contents


Similarly, we have determined that when we provide post-installation monitoring and maintenance services and associated system output performance warranties to customers of projects that include the sale or lease of real estate, these are not forms of prohibited continuing involvement since the terms and conditions of the post-installation monitoring and maintenance services are commensurate with market rates, control over the right to terminate the post-installation monitoring and maintenance contract and associated system output performance warranties rests with the customer since the customer has the right to terminate for convenience, and the terms and conditions for the system output performance warranties do not result in any additional services or efforts by us or in the retention of ownership risks outside of our control.

Residential Leases

We offer a solar lease program, in partnership with third-party financial institutions, which allows our residential customers to obtain SunPower systems under lease agreements for terms of up to 20 years. Leases are classified as either operating- or sales-type leases in accordance with the relevant accounting guidelines, which involve making a variety of estimates, including the fair value and residual value of leased solar power systems. Changes in these estimates can have a significant impact on the related accounting results, including the relative proportion of leases classified as operating- or sales-type leases.

For those systems classified as sales-type leases, the net present value of the minimum lease payments, net of executory costs, is recognized as revenue when the lease is placed in service. This net present value as well as the net present value of the residual value of the lease at termination are recorded as receivables in our Consolidated Balance Sheets. The difference between the initial net amounts and the gross amounts are amortized to revenue over the lease term using the interest method. The residual values of our solar systems are determined at the inception of the lease by applying an estimated system fair value at the end of the lease term.

For those systems classified as operating leases, rental revenue is recognized, net of executory costs, on a straight-line basis over the term of the lease.

Allowance for Doubtful Accounts and Sales Returns

We maintain allowances for doubtful accounts for estimated losses resulting from the inability of our customers to make required payments. A considerable amount of judgment is required to assess the likelihood of the ultimate realization of accounts receivable. We make our estimates of the collectability of our accounts receivable by analyzing historical bad debts, specific customer creditworthiness and current economic trends.

In addition, at the time revenue is recognized from the sale of solar panels and balance of system components, we record estimates for sales returns which reduce revenue. These estimates are based on historical sales returns and analysis of credit memo data, among other known factors.

Warranty Reserves

We generally provide a 25-year standard warranty for our solar panels that we manufacture for defects in materials and workmanship. The warranty provides that we will repair or replace any defective solar panels during the warranty period. In addition, we pass through to customers long-term warranties from the original equipment manufacturers of certain system components, such as inverters. Warranties of 25 years from solar panel suppliers are standard in the solar industry, while certain system components carry warranty periods ranging from five to 20 years.

In addition, we generally warrant our workmanship on installed systems for periods ranging up to 25 years and also provide a separate system output performance warranty to customers that have subscribed to our post-installation monitoring and maintenance services which expires upon termination of the post-installation monitoring and maintenance services related to the system. The warrantied system output performance level varies by system depending on the characteristics of the system and the negotiated agreement with the customer, and the level declines over time to account for the expected degradation of the system. Actual system output is typically measured annually for purposes of determining whether warrantied performance levels have been met. The warranty excludes system output shortfalls attributable to force majeure events, customer curtailment, irregular weather, and other similar factors. In the event that the system output falls below the warrantied performance level during the applicable warranty period, and provided that the shortfall is not caused by a factor that is excluded from the performance warranty, the warranty provides that we will pay the customer a liquidated damage based on the value of the shortfall of energy produced relative to the applicable warrantied performance level.

We maintain reserves to cover the expected costs that could result from these warranties. Our expected costs are

69

Table of Contents


generally in the form of product replacement or repair. Warranty reserves are based on our best estimate of such costs and are recognized as a cost of revenue. We continuously monitor product returns for warranty failures and maintain a reserve for the related warranty expenses based on various factors including historical warranty claims, results of accelerated lab testing, field monitoring, vendor reliability estimates, and data on industry averages for similar products. Due to the potential for variability in these underlying factors, the difference between our estimated costs and our actual costs could be material to our consolidated financial statements. If actual product failure rates or the frequency or severity of reported claims differ from our estimates or if there are delays in our responsiveness to outages, we may be required to revise our estimated warranty liability. Historically, warranty costs have been within management’s expectations.

Valuation of Inventories

Inventories are accounted for on a first-in-first-out basis and are valued at the lower of cost or net realizable value. We evaluate the realizability of our inventories, including future purchase commitments under fixed-price long-term supply agreements, based on assumptions about expected demand and market conditions. Our assumption of expected demand is developed based on our analysis of bookings, sales backlog, sales pipeline, market forecast and competitive intelligence. Our assumption of expected demand is compared to available inventory, production capacity, future polysilicon purchase commitments, available third-party inventory and growth plans. Our factory production plans, which drive materials requirement planning, are established based on our assumptions of expected demand. We respond to reductions in expected demand by temporarily reducing manufacturing output and adjusting expected valuation assumptions as necessary. In addition, expected demand by geography has changed historically due to changes in the availability and size of government mandates and economic incentives.

We evaluate the terms of our long-term inventory purchase agreements with suppliers for the procurement of polysilicon, ingots, wafers, and solar cells and establish accruals for estimated losses on adverse purchase commitments as necessary, such as lower of cost or net realizable value adjustments, forfeiture of advanced deposits and liquidated damages. Obligations related to non-cancellable purchase orders for inventories match current and forecasted sales orders that will consume these ordered materials and actual consumption of these ordered materials are compared to expected demand regularly. We anticipate total obligations related to long-term supply agreements for inventories will be realized because quantities are less than management's expected demand for its solar power products over a period of years; however, if raw materials inventory balances temporarily exceed near-term demand, we may elect to sell such inventory to third parties to optimize working capital needs. In addition, because the purchase prices required by our long-term polysilicon agreements are significantly higher than current market prices for similar materials, if we are not able to profitably utilize this material in our operations or elect to sell near-term excess, we may incur additional losses. Other market conditions that could affect the realizable value of our inventories and are periodically evaluated by management include the aging of inventories on hand, historical inventory turnover ratio, anticipated sales price, new product development schedules, the effect new products might have on the sale of existing products, product obsolescence, customer concentrations, the current market price of polysilicon as compared to the price in our fixed-price arrangements, and product merchantability, among other factors. If, based on assumptions about expected demand and market conditions, we determine that the cost of inventories exceeds its net realizable value or inventory is excess or obsolete, or we enter into arrangements with third parties for the sale of raw materials that do not allow us to recover our current contractually committed price for such raw materials, we record a write-down or accrual, which may be material, equal to the difference between the cost of inventories and the estimated net realizable value. If actual market conditions are less favorable than those projected by management, additional inventory write-downs may be required that could negatively affect our gross margin and operating results. If actual market conditions are more favorable, we may have higher gross margin when products that have been previously written down are sold in the normal course of business.

Stock-Based Compensation

We provide stock-based awards to our employees, executive officers and directors through various equity compensation plans including our employee stock option and restricted stock plans. We measure and record compensation expense for all stock-based payment awards based on estimated fair values. The fair value of restricted stock awards and units is based on the market price of our common stock on the date of grant. We have not granted stock options since fiscal 2008. We are required under current accounting guidance to estimate forfeitures at the date of grant. Our estimate of forfeitures is based on our historical activity, which we believe is indicative of expected forfeitures. In subsequent periods if the actual rate of forfeitures differs from our estimate, the forfeiture rates are required to be revised, as necessary. Changes in the estimated forfeiture rates can have a significant effect on stock-based compensation expense since the effect of adjusting the rate is recognized in the period the forfeiture estimate is changed.

We also grant performance share units to executive officers and certain employees that require us to estimate expected achievement of performance targets over the performance period. This estimate involves judgment regarding future

70

Table of Contents


expectations of various financial performance measures. If there are changes in our estimate of the level of financial performance measures expected to be achieved, the related stock-based compensation expense may be significantly increased or reduced in the period that our estimate changes.

Variable Interest Entities ("VIE")

We regularly evaluate our relationships and involvement with unconsolidated VIEs, including our investments in the 8point3 Group and our other equity and cost method investments, to determine whether we have a controlling financial interest in them or have become the primary beneficiary, thereby requiring us to consolidate their financial results into our financial statements. In connection with the sale of the equity interests in the entities that hold solar power plants, we also consider whether we retain a variable interest in the entity sold, either through retaining a financial interest or by contractual means. If we determine that the entity sold is a VIE and that we hold a variable interest, we then evaluate whether we are the primary beneficiary. If we determine that we are the primary beneficiary, we will consolidate the VIE. The determination of whether we are the primary beneficiary is based upon whether we have the power to direct the activities that most directly impact the economic performance of the VIE and whether we absorb any losses or benefits that would be potentially significant to the VIE.

Accounting for Business Combinations

We record all acquired assets and liabilities, including goodwill, other intangible assets and in-process research and development, at fair value. The initial recording of goodwill, other intangible assets and in-process research and development requires certain estimates and assumptions concerning the determination of the fair values and useful lives. The judgments made in the context of the purchase price allocation can materially affect our future results of operations. Accordingly, for significant acquisitions, we obtain assistance from third-party valuation specialists. The valuations calculated from estimates are based on information available at the acquisition date. Goodwill is not amortized, but is subject to annual tests for impairment or more frequent tests if events or circumstances indicate it may be impaired. Other intangible assets are amortized over their estimated useful lives and are subject to impairment if events or circumstances indicate a possible inability to realize the carrying amount. For additional details see "Note 3. Business Combinations" and "Note 4. Goodwill and Other Intangible Assets" under "Item 8. Financial Statements and Supplementary Data—Notes to Consolidated Financial Statements" in this Annual Report on Form 10-K.

Valuation of Long-Lived Assets

Our long-lived assets include property, plant and equipment, solar power systems leased and to be leased, and other intangible assets with finite lives. We evaluate our long-lived assets for impairment whenever events or changes in circumstances indicate that the carrying value of such assets may not be recoverable. Factors considered important that could result in an impairment review include significant under-performance relative to expected historical or projected future operating results, significant changes in the manner of use of acquired assets and significant negative industry or economic trends. Our impairment evaluation of long-lived assets includes an analysis of estimated future undiscounted net cash flows expected to be generated by the assets over their remaining estimated useful lives. If our estimate of future undiscounted net cash flows is insufficient to recover the carrying value of the assets over the remaining estimated useful lives, we record an impairment loss in the amount by which the carrying value of the assets exceeds the fair value. Fair value is generally measured based on either quoted market prices, if available, or discounted cash flow analyses.

Valuation of Project Assets - Plant and Land

Project assets consist primarily of capitalized costs relating to solar power system projects in various stages of development that we incur prior to the sale of the solar power system to a third-party. These costs include costs for land and costs for developing and constructing a solar power system. Development costs can include legal, consulting, permitting, and other similar costs. Once we enter into a definitive sales agreement, we reclassify these project asset costs to deferred project costs within "Prepaid expenses and other current assets" in our Consolidated Balance Sheet until we have met the criteria to recognize the sale of the project asset or solar power project as revenue. We release these project costs to cost of revenue as each respective project asset or solar power system is sold to a customer, since the project is constructed for a customer (matching the underlying revenue recognition method).

We evaluate the realizability of project assets whenever events or changes in circumstances indicate that the carrying amount may not be recoverable. We consider the project to be recoverable if it is anticipated to be sellable for a profit once it is either fully developed or fully constructed or if costs incurred to date may be recovered via other means, such as a sale prior to the completion of the development cycle. We examine a number of factors to determine if the project will be profitable,

71

Table of Contents


including whether there are any environmental, ecological, permitting, or regulatory conditions that have changed for the project since the start of development. In addition, we must anticipate market conditions, such as the future cost of energy and changes in the factors that our future customers use to value our project assets in sale arrangements, including the internal rate of return that customers expect. Changes in such conditions could cause the cost of the project to increase or the selling price of the project to decrease. Due to the development, construction, and sale timeframe of our larger solar projects, we classify project assets which are not expected to be sold within the next 12 months as "Project assets - plants and land, net of current portion" on the Consolidated Balance Sheets. Once specific milestones have been achieved, we determine if the sale of the project assets will occur within the next 12 months from a given balance sheet date and, if so, we then reclassify the project assets as current.

Goodwill Impairment

Goodwill is tested for impairment at least annually, or more frequently if certain indicators are present. If goodwill is determined more likely than not to be impaired upon an initial assessment of qualitative factors, a two-step valuation and accounting process is used to test for goodwill impairment. The first step is to determine if there is an indication of impairment by comparing the estimated fair value of each reporting unit to its carrying value, including existing goodwill. Goodwill is considered impaired if the carrying value of a reporting unit exceeds the estimated fair value. Upon an indication of impairment, a second step is performed to determine the amount of the impairment by comparing the implied fair value of the reporting unit’s goodwill with its carrying value.

We conduct our annual impairment test of goodwill as of the first day of the fourth fiscal quarter of each year, or on an interim basis if circumstances warrant. Impairment of goodwill is tested at our reporting unit level. Management determined that the Residential Segment, the Commercial Segment, and the Power Plant Segment are also the reporting units. In estimating the fair value of the reporting units, we make estimates and judgments about our future cash flows using an income approach defined as Level 3 inputs under fair value measurement standards. The income approach, specifically a discounted cash flow analysis, included assumptions for, among others, forecasted revenue, gross margin, operating income, working capital cash flow, perpetual growth rates and long-term discount rates, all of which require significant judgment by management. The sum of the fair values of our reporting units are also compared to our total external market capitalization to validate the appropriateness of its assumptions and such reporting unit values are adjusted, if appropriate. These assumptions also consider the current industry environment and the resulting impact on our expectations for the performance of our business. In the event that management determines that the value of goodwill has become impaired, we will incur an accounting charge for the amount of the impairment during the fiscal quarter in which the determination is made. For additional details see "Item 8. Financial Statements—Notes to Consolidated Financial Statements—Note 4. Goodwill and Other Intangible Assets" in this Annual Report on Form 10-K.

Accounting for Income Taxes

Our global operations involve manufacturing, research and development, and selling and project development activities. Profit from non-U.S. activities is subject to local country taxation, but not subject to U.S. tax until repatriated to the United States. It is our intention to indefinitely reinvest these earnings outside the United States. We record a valuation allowance to reduce our U.S., French, and Spanish deferred tax assets to the amount that is more likely than not to be realized. In assessing the need for a valuation allowance, we consider historical levels of income, expectations and risks associated with the estimates of future taxable income and ongoing prudent and feasible tax planning strategies. In the event we determine that we would be able to realize additional deferred tax assets in the future in excess of the net recorded amount, or if we subsequently determine that realization of an amount previously recorded is unlikely, we would record an adjustment to the deferred tax asset valuation allowance, which would change income tax in the period of adjustment. As of January 1, 2017, we believe there is insufficient evidence to realize additional deferred tax assets beyond the U.S. net operating losses that can be benefitted through a carryback election; however, the reversal of the valuation allowance, which could be material, could occur in a future period.

The calculation of tax expense and liabilities involves dealing with uncertainties in the application of complex global tax regulations, including in the tax valuation of projects sold to tax equity partnerships and other third parties. We recognize potential liabilities for anticipated tax audit issues in the United States and other tax jurisdictions based on our estimate of whether, and the extent to which, additional taxes will be due. If payment of these amounts ultimately proves to be unnecessary, the reversal of the liabilities would result in tax benefits being recognized in the period in which we determine the liabilities are no longer necessary. If the estimate of tax liabilities proves to be less than the ultimate tax assessment, a further charge to expense would result. We accrue interest and penalties on tax contingencies which are classified as "Provision for income taxes" in our Consolidated Statements of Operations and are not considered material.


72

Table of Contents


Pursuant to the Tax Sharing Agreement with Cypress, our former parent company, we are obligated to indemnify Cypress upon current utilization of carryforward tax attributes generated while we were part of the Cypress consolidated or combined group. Further, to the extent Cypress experiences any tax examination assessments attributable to our operations while part of the Cypress consolidated or combined group, Cypress will require an indemnification from us for those aspects of the assessment that relate to our operations. See also "Item 1A. Risk Factors—Risks Related to Our Operations—Our agreements with Cypress require us to indemnify Cypress for certain tax liabilities. These indemnification obligations and related contractual restrictions may limit our ability to pursue certain business initiatives."

In addition, foreign exchange gains (losses) may result from estimated tax liabilities which are expected to be realized in currencies other than the U.S. dollar.


73

Table of Contents


Liquidity and Capital Resources
 
Cash Flows

A summary of the sources and uses of cash and cash equivalents is as follows:
 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Net cash provided by (used in) operating activities
 
$
(312,283
)
 
$
(726,231
)
 
$
8,360

Net cash provided by (used in) investing activities
 
$
(377,450
)
 
$
109,399

 
$
(309,239
)
Net cash provided by financing activities
 
$
159,779

 
$
619,967

 
$
498,566


Operating Activities

Net cash used in operating activities in fiscal 2016 was $312.3 million and was primarily the result of: (i) a net loss of $543.8 million; (ii) a $203.3 million non-cash settlement of preexisting relationships in connection with the acquisition of AUOSP; (iii) a $172.5 million increase in long-term financing receivables related to our net investment in sales-type leases; (iv) a $70.4 million increase in inventories driven by purchases of polysilicon; (v) a $38.2 million decrease in billings in excess of costs and estimated earnings driven by the recognition revenue and corresponding costs of certain utility-scale projects; (vi) a $33.5 million increase in accounts receivable, primarily driven by billings; (vii) a $28.1 million increase in equity in earnings of unconsolidated investees; (viii) a $17.0 million decrease in customer advances; (ix) a $12.1 million decrease in accounts payable and other accrued liabilities, primarily attributable to recognition of revenue of certain utility-scale projects; (x) a $6.6 million net change in deferred income taxes, and (xi) a $2.8 million in excess tax benefit from stock-based compensation. This was partially offset by: (i) other net non-cash charges of $241.6 million related to depreciation, non-cash interest charges and stock-based compensation; (ii) $166.7 million in non-cash restructuring charges; (iii) a $147.4 million impairment of goodwill; (iv) $90.9 million in impairment of equity method investments; (v) a $74.3 million decrease in advance payments made to suppliers; (vi) a $48.8 million decrease in prepaid expenses and other assets, primarily related to recognition of revenue and corresponding costs of certain utility-scale projects; (vii) a $33.2 million decrease in project assets primarily related to revenue recognition and corresponding costs of certain utility-scale and commercial projects; (viii) $6.9 million dividend from 8point3 Energy Partners LP; (ix) a $6.2 million decrease in costs and estimated earnings in excess of billings driven by milestone billings.

Net cash used in operating activities in fiscal 2015 was $726.2 million and was primarily the result of: (i) a net loss of $299.4 million; (ii) a $763.1 million increase in project assets primarily related to our Henrietta, Hooper and Quinto Solar Energy Projects; (iii) a $237.8 million increase in inventories driven by project assets for construction of solar power systems for Commercial and Power Plant projects in North America and purchases of polysilicon; (iv) a $143.0 million increase in long-term financing receivables related to our net investment in sales-type leases; (v) a $87.0 million increase in prepaid expenses and other assets; (vi) a $39.4 million excess tax benefit from stock-based compensation; (vii) a $27.9 million gain on the sale of a residential lease portfolio to 8point3 Energy Partners; (viii) a $20.8 million increase in customer advances; and (ix) a $9.6 million increase in equity in earnings of unconsolidated investees. This was partially offset by: (i) a $311.7 million decrease in accounts receivable, primarily driven by the collection of retainage related to Solar Star Projects; (ii) other net non-cash charges of $205.7 million related to depreciation, non-cash interest charges and stock-based compensation; (iii) a $148.4 million decrease in costs and estimated earnings in excess of billings driven by a decrease related to the Solar Star Projects; (iv) a $90.9 million increase in accounts payable and other accrued liabilities; (v) a $63.7 million increase in deferred income taxes and income tax liabilities; (vi) a $50.6 million decrease in advance payment made to suppliers; and (vii) a $30.7 million increase in billings in excess of costs and estimated earnings driven by an increase related to Solar Star and other projects.

Net cash provided by operating activities in fiscal 2014 was $8.4 million and was primarily the result of: (i) a net income of $183.1 million; (ii) a $205.5 million decrease in prepaid expenses and other assets driven by a decline in deferred costs related to the Solar Star Projects; (iii) net non-cash charges of $186.0 million related to depreciation, non-cash interest charges, and stock based compensation; (iv) a $45.8 million increase in accounts payable and other accrued liabilities; and (v) a $21.7 million net increase in deferred income taxes and other liabilities. This was partially offset by: (i) a $225.2 million decrease in billings in excess of costs and estimated earnings driven by a decline related to the Solar Star Projects; (ii) a $155.3 million increase in costs and estimated earnings in excess of billings driven by an increase related to the Solar Star Projects; (iii) a $94.3 million increase in long-term financing receivables related to our net investment in sales-type leases; (iv) a $68.2 million increase in project assets primarily related to our Quinto Solar Energy project; (v) a $26.3 million increase in advance payments made to suppliers; (vi) a $31.5 million increase in accounts receivable; (vii) a $23.5 million decrease in customer advances; and (viii) a $9.4 million net change in other operating assets.

74

Table of Contents



Investing Activities

Net cash used in investing activities in fiscal 2016 was $377.5 million, which included (i) $310.1 million in capital expenditures primarily related to the expansion of our solar cell manufacturing capacity and costs associated with solar power systems, leased and to be leased; (ii) $24.0 million paid for the acquisition of AUOSP, net of cash acquired; (iii) a $22.7 million increase in restricted cash; (iv) $11.5 million paid for investments in consolidated and unconsolidated investees; (v) $9.8 million in payments to 8point3 Energy Partners; (vi) $5.0 million paid for purchases of marketable securities; and (vii) $0.5 million paid for intangibles. This was offset by: (i) $6.2 million in proceeds from sales or maturities of marketable securities.

Net cash provided by investing activities in fiscal 2015 was $109.4 million, which included $539.8 million in proceeds from 8point3 Energy Partners. This was partially offset by (i) $328.4 million in capital expenditures primarily related to the expansion of our solar cell manufacturing capacity and costs associated with solar power systems, leased and to be leased; (ii) $64.8 million paid for acquisitions; (iii) a $23.2 million increase in restricted cash; (iv) $9.9 million paid for intangibles; and (v) $4.1 million paid for investments in unconsolidated investees.

Net cash used in investing activities in fiscal 2014 was $309.2 million, which included: (i) $166.9 million related to capital expenditures primarily related to the expansion of our solar cell manufacturing capacity and costs associated with solar power systems, leased and to be leased; (ii) $97.0 million paid for investments in unconsolidated investees driven by a $72.0 million equity contribution to AUOSP; (iii) $35.1 million paid for acquisitions; and (iv) a $11.6 million increase in restricted cash. This was partially offset by $1.4 million proceeds from maturities of marketable securities.

Financing Activities

Net cash provided by financing activities in fiscal 2016 was $159.8 million, which included: (i) $146.1 million in net proceeds from the issuance of non-recourse residential financing, net of issuance costs; and (ii) $127.3 million of net contributions from noncontrolling interests and redeemable noncontrolling interests related to the residential lease projects. This was partially offset by: (i) $56.4 million in net repayments from the issuance of non-recourse power plant and commercial financing, net of issuance costs; (ii) $30.0 million in net repayments of bank loans and other debt; (iii) $21.5 million in purchases of treasury stock for tax withholding obligations on vested restricted stock; and (iv) $5.7 million in cash paid for acquisitions.

Net cash provided by financing activities in fiscal 2015 was $620.0 million, which included: (i) $416.3 million in proceeds from issuance of our 4.00% convertible debentures due 2023; (ii) $424.6 million in proceeds from the issuance of project loans, net of issuance costs; (iii) $170.6 million of net contributions from noncontrolling interests and redeemable noncontrolling interests related to the residential lease program; (iv) $90.6 million in net proceeds from the issuance of non-recourse debt financing, net of issuance costs; (v) $39.9 million in proceeds from exercise of stock options and excess tax benefit from stock-based compensation; (vi) $29.3 million in proceeds from 8point3 Energy Partners; (vii) $15.0 million in net proceeds from sale-leaseback financing; and (viii) $12.4 million in contributions from noncontrolling interests related to real estate projects. This was partially offset by: (i) $250.3 million in net payment to settle the 4.50% debentures due 2015, and the 4.50% Bond Hedge and Warrant (defined below); (ii) $252.6 million in repayments of bank loans, project loans and other debt, primarily the Quinto Credit Facility; (iii) $43.8 million in purchases of treasury stock for tax withholding obligations on vested restricted stock; and (iv) $32.0 million of net repayments of residential lease financing.

Net cash provided by financing activities in fiscal 2014 was $498.6 million, which included: (i) $395.3 million in net proceeds from the issuance of our 0.875% convertible debentures due 2021; (ii) $100.7 million of contributions from noncontrolling interests and redeemable noncontrolling interests related to the residential lease program; (iii) $81.9 million of proceeds from issuance of non-recourse debt financing to finance solar power systems and leases under our residential lease program; (iv) $61.5 million in proceeds from issuance of project loans; (v) $46.4 million in net proceeds from sale-leaseback financing arrangements; and (vi) $3.4 million in proceeds from exercise of stock options and excess tax benefit from stock-based compensation. This was partially offset by: (i) $57.5 million in purchases of stock for tax withholding obligations on vested restricted stock; (ii) $42.3 million cash paid to repurchase convertible debt; (iii) a $40.7 million assumption of a project loan by a customer; (iv) $17.1 million in repayments of bank loans, project loans and other debt; (v) $15.7 million of repayments of residential lease financing; (vi) a $12.2 million net payment to settle the 4.75% Bond Hedge and Warrant; and (vii) $5.1 million of distributions to noncontrolling interests and redeemable noncontrolling interests.

Debt and Credit Sources

Convertible Debentures

75

Table of Contents



As of January 1, 2017, an aggregate principal amount of $425.0 million of the 4.00% debentures due 2023 remained issued and outstanding. The 4.00% debentures due 2023 were issued on December 15, 2015. Interest on the 4.00% debentures due 2023 is payable on January 15 and July 15 of each year, beginning on July 15, 2016. Holders are able to exercise their right to convert the debentures at any time into shares of our common stock at an initial conversion price approximately equal to $30.53 per share, subject to adjustment in certain circumstances. If not earlier repurchased or converted, the 4.00% debentures due 2023 mature on January 15, 2023. Holders may require us to repurchase all or a portion of their 4.00% debentures due 2023, upon a fundamental change, as described in the related indenture, at a cash repurchase price equal to 100% of the principal amount plus accrued and unpaid interest. If we undergo a non-stock change of control fundamental change, as described in the related indenture, the 4.00% debentures due 2023 will be subject to redemption at our option, in whole but not in part, for a period of 30 calendar days following a repurchase date relating to the non-stock change of control fundamental change, at a cash redemption price equal to 100% of the principal amount plus accrued and unpaid interest. Otherwise, the 4.00% debentures due 2023 are not redeemable at our option prior to the maturity date. In the event of certain events of default, Wells Fargo Bank, National Association ("Wells Fargo"), the trustee, or the holders of a specified amount of then-outstanding 4.00% debentures due 2023 will have the right to declare all amounts then outstanding due and payable.

As of January 1, 2017, an aggregate principal amount of $400.0 million of the 0.875% debentures due 2021 remained issued and outstanding. The 0.875% debentures due 2021 were issued on June 11, 2014. Interest on the 0.875% debentures due 2021 is payable on June 1 and December 1 of each year. Holders are able to exercise their right to convert the debentures at any time into shares of our common stock at an initial conversion price approximately equal to $48.76 per share, subject to adjustment in certain circumstances. If not earlier repurchased or converted, the 0.875% debentures due 2021 mature on June 1, 2021. Holders may require us to repurchase all or a portion of their 0.875% debentures due 2021, upon a fundamental change, as described in the related indenture, at a cash repurchase price equal to 100% of the principal amount plus accrued and unpaid interest. If we undergo a non-stock change of control fundamental change, as described in the related indenture, the 0.875% debentures due 2021 will be subject to redemption at our option, in whole but not in part, for a period of 30 calendar days following a repurchase date relating to the non-stock change of control fundamental change, at a cash redemption price equal to 100% of the principal amount plus accrued and unpaid interest. Otherwise, the 0.875% debentures due 2021 are not redeemable at our option prior to the maturity date. In the event of certain events of default, Wells Fargo, the trustee, or the holders of a specified amount of then-outstanding 0.875% debentures due 2021 will have the right to declare all amounts then outstanding due and payable.

As of January 1, 2017, an aggregate principal amount of $300.0 million of the 0.75% debentures due 2018 remained issued and outstanding. The 0.75% debentures due 2018 were issued on May 29, 2013. Interest on the 0.75% debentures due 2018 is payable on June 1 and December 1 of each year. Holders are able to exercise their right to convert the debentures at any time into shares of our common stock at an initial conversion price equal to $24.95 per share. The applicable conversion rate may be subject to adjustment in certain circumstances. If not earlier converted, the 0.75% debentures due 2018 mature on June 1, 2018. Holders may require us to repurchase all or a portion of their 0.75% debentures due 2018, upon a fundamental change, as described in the related indenture, at a cash repurchase price equal to 100% of the principal amount plus accrued and unpaid interest. If we undergo a non-stock change of control fundamental change, as described in the related indenture, the 0.75% debentures due 2018 will be subject to redemption at our option, in whole but not in part, for a period of 30 calendar days following a repurchase date relating to the non-stock change of control fundamental change, at a cash redemption price equal to 100% of the principal amount plus accrued and unpaid interest. Otherwise, the 0.75% debentures due 2018 are not redeemable at our option prior to the maturity date. In the event of certain events of default, Wells Fargo, the trustee, or the holders of a specified amount of then-outstanding 0.75% debentures due 2018 will have the right to declare all amounts then outstanding due and payable. Please see "Part I. Item 1A. Risk Factors—Risks Related to our Debt and Equity Securities—Conversion of our outstanding 0.75% debentures, 0.875% debentures, 4.00% debentures, and future substantial issuances or dispositions of our common stock or other securities, could dilute ownership and earnings per share or cause the market price of our stock to decrease" in this Annual Report on Form 10-K.

Mortgage Loan Agreement with IFC

On May 6, 2010, we entered into a mortgage loan agreement with IFC. Under the loan agreement, we borrowed $75.0 million and are required to repay the amount borrowed starting two years after the date of borrowing, in 10 equal semiannual installments over the following 5 years. We are required to pay interest of LIBOR plus 3% per annum on outstanding borrowings; a front-end fee of 1% on the principal amount of borrowings at the time of borrowing; and a commitment fee of 0.5% per annum on funds available for borrowing and not borrowed. We may prepay all or a part of the outstanding principal, subject to a 1% prepayment premium. We have pledged certain assets as collateral supporting repayment obligations.
  

76

Table of Contents


As of January 1, 2017, we had $17.5 million outstanding under the mortgage loan agreement. Additionally, in accordance with the terms of the mortgage loan agreement, we are required to establish a debt service reserve account which shall contain the amount, as determined by IFC, equal to the aggregate principal and interest due on the next succeeding interest payment date after such date. As of January 1, 2017, we had restricted cash and cash equivalents of $9.2 million related to the IFC debt service reserve. On January 17, 2017, the Company repaid the entire outstanding balance, and the associated interest, of the mortgage loan agreement with IFC (see Note 18).

Loan Agreement with California Enterprise Development Authority ("CEDA")

On December 29, 2010, we borrowed from CEDA the proceeds of the $30.0 million aggregate principal amount of CEDA's tax-exempt Recovery Zone Facility Revenue Bonds (SunPower Corporation - Headquarters Project) Series 2010 (the "Bonds") maturing April 1, 2031 under a loan agreement with CEDA. Certain of our obligations under the loan agreement were contained in a promissory note dated December 29, 2010 issued by us to CEDA, which assigned the promissory note, along with all right, title and interest in the loan agreement, to Wells Fargo, as trustee, with respect to the Bonds for the benefit of the holders of the Bonds. The Bonds bear interest at a fixed-rate of 8.50% per annum.

As of January 1, 2017, the $30.0 million aggregate principal amount of the Bonds was classified as "Long-term debt" in our Consolidated Balance Sheets.

Revolving Credit Facility with Credit Agricole

On July 3, 2013, we entered into a revolving credit agreement with Credit Agricole Corporate and Investment Bank ("Credit Agricole"), as administrative agent, and certain financial institutions, under which we may borrow up to $250.0 million. On August 26, 2014, we entered into an amendment to the revolving credit facility that extends, among other things, the maturity date of the facility from July 3, 2016 to August 26, 2019 (the "Maturity Date"). Amounts borrowed may be repaid and reborrowed until the Maturity Date. On February 17, 2016, the Company entered into an amendment to the credit agreement, expanding the available borrowings under the revolving credit facility to $300.0 million and adding a $200.0 million letter of credit subfacility, subject to the satisfaction of certain conditions. The revolving credit facility includes representations, covenants, and events of default customary for financing transactions of this type. The revolving credit facility was entered into in conjunction with the delivery by Total S.A. of a guarantee of our obligations under the facility. On January 31, 2014, (i) our obligations under the revolving credit facility became secured by a pledge of certain accounts receivable and inventory, (ii) certain of our subsidiaries entered into guaranties of the revolving credit facility, and (iii) Total S.A.'s guarantee of our obligations under the revolving credit facility expired.

We are required to pay (a) interest on outstanding borrowings under the facility of (i) with respect to any LIBOR rate loan, an amount ranging from 1.50% to 2.00% (depending on our leverage ratio from time to time) plus the LIBOR rate divided by a percentage equal to one minus the stated maximum rate of all reserves required to be maintained against "Eurocurrency liabilities" as specified in Regulation D; and (ii) with respect to any alternate base rate loan, an amount ranging from 0.50% to 1.00% (depending on our leverage ratio from time to time) plus the greater of (1) the prime rate, (2) the Federal Funds rate plus 0.50%, and (3) the one-month LIBOR rate plus 1%; and (b) a commitment fee ranging from 0.25% to 0.35% (depending on our leverage ratio from time to time) per annum on funds available for borrowing and not borrowed. We will be required to pay interest on letters of credit under the agreement of (a) with respect to any performance letter of credit, an amount ranging from 0.90% to 1.20% (depending on our leverage ratio from time to time); and (b) with respect to any other letter of credit, an amount ranging from 1.50% to 2.00% (depending on our leverage ratio from time to time).

As of January 1, 2017, we had $4.7 million of outstanding borrowings under the revolving credit facility, all of which were related to letters of credit that are fully cash collateralized. Although we are not in default with Credit Agricole, we are currently not in compliance with the covenant for this credit facility that would permit us to draw further and therefore we may not make additional draws on the facility without collateralizing the borrowings with cash. We expect to not be in compliance with the covenant for the Credit Agricole credit facility for at least the remainder of the 2017 fiscal year, which will affect the availability of borrowings under the line, if not remedied.

August 2016 Letter of Credit Facility Agreement

In August 2016, we entered into a letter of credit facility with Banco Santander, S.A. which provides for the issuance, upon request by us, of letters of credit to support our obligations in an aggregate amount not to exceed $85 million. As of January 1, 2017, there were no letters of credit issued and outstanding under the facility with Banco Santander, S.A.

2016 Letter of Credit Facility Agreements

77

Table of Contents



In June 2016, we entered into a Continuing Agreement for Standby Letters of Credit and Demand Guarantees with Deutsche Bank AG New York Branch and Deutsche Bank Trust Company Americas (the “2016 Non-Guaranteed LC Facility”) which provides for the issuance, upon request by us, of letters of credit to support our obligations in an aggregate amount not to exceed $50.0 million. The 2016 Non-Guaranteed LC Facility will terminate on June 29, 2018. As of January 1, 2017, letters of credit issued and outstanding under the 2016 Non-Guaranteed LC Facility totaled $45.8 million.

In June 2016, we entered into bilateral letter of credit facility agreements (the “2016 Guaranteed LC Facilities”) with The Bank of Tokyo-Mitsubishi UFJ ("BTMU"), Credit Agricole, and HSBC USA Bank, National Association ("HSBC"). Each letter of credit facility agreement provides for the issuance, upon our request, of letters of credit by the issuing bank thereunder in order to support certain of our obligations until December 31, 2018. Payment of obligations under each of the letter of credit facilities are guaranteed by Total S.A. pursuant to the Credit Support Agreement. Aggregate letter of credit amounts may be increased upon the agreement of the respective parties but, otherwise, may not exceed $75.0 million with BTMU, $75.0 million with Credit Agricole and $175.0 million with HSBC, for a total capacity of $325.0 million. Each letter of credit issued under one of the letter of credit facilities generally must have an expiration date, subject to certain exceptions, no later than the earlier of (a) two years from completion of the applicable project and (b) March 31, 2020.

In June 2016, in connection with the 2016 Guaranteed LC Facilities, we entered into a transfer agreement to transfer to the 2016 Guaranteed LC Facilities all existing outstanding letters of credit issued under our letter of credit facility agreement with Deutsche Bank AG New York Branch and Deutsche Bank Trust Company Americas, as administrative agent, and certain financial institutions, entered into in August 2011 and amended from time to time. In connection with the transfer of the existing outstanding letters of credit, the aggregate commitment amount under the August 2011 letter of credit facility was permanently reduced to zero on June 29, 2016. As of January 1, 2017, there were no letters of credit issued and outstanding under the August 2011 letter of credit facility with Deutsche Bank. As of January 1, 2017, letters of credit issued and outstanding under the 2016 Guaranteed LC Facilities totaled $244.8 million.

September 2011 Letter of Credit Facility with Deutsche Bank and Deutsche Bank Trust Company Americas (together, "Deutsche Bank Trust")

On September 27, 2011, we entered into a letter of credit facility with Deutsche Bank Trust which provides for the issuance, upon request by us, of letters of credit to support our obligations in an aggregate amount not to exceed $200.0 million. Each letter of credit issued under the facility is fully cash-collateralized and we have entered into a security agreement with Deutsche Bank Trust, granting them a security interest in a cash collateral account established for this purpose.

As of January 1, 2017 letters of credit issued under the Deutsche Bank Trust facility totaled $3.1 million, which was fully collateralized with restricted cash as classified on the Consolidated Balance Sheets.

Revolving Credit Facility with Mizuho and Goldman Sachs

On May 4, 2016, we entered into a revolving credit facility (the "Construction Revolver") with Mizuho Bank Ltd., as administrative agent, and Goldman Sachs Bank USA, under which we may borrow up to $200 million. The Construction Revolver also includes a $100 million accordion feature.  Amounts borrowed under the Construction Revolver may be repaid and reborrowed in support of our commercial and small scale utility projects in the United States until the May 4, 2021 maturity date. The Construction Revolver includes representations, covenants, and events of default customary for financing transactions of this type.

Borrowings under the Construction Revolver bear interest at the applicable LIBOR rate plus 1.50% for the first two years (with the final year at LIBOR plus 1.75%). All outstanding indebtedness under the facility may be voluntarily prepaid in whole or in part without premium or penalty (with certain limitations to partial repayments), other than customary breakage costs. The Construction Revolver is secured by the assets of, and equity in, the various project companies to which the borrowings relate, but is otherwise non-recourse to us and our other affiliates.

As of January 1, 2017, outstanding borrowings under the Construction Revolver totaled $10.5 million.

Non-recourse Financing and Other Debt

In order to facilitate the construction, sale or ongoing operation of certain solar projects, including our residential leasing program, we regularly obtain project-level financing. These financings are secured either by the assets of the specific project being financed or by our equity in the relevant project entity and the lenders do not have recourse to the general assets of the

78

Table of Contents


Company for repayment of such debt obligations, and hence the financings are referred to as non-recourse. Non-recourse financing is typically in the form of loans from third-party financial institutions, but also takes other forms, including "flip partnership" structures, sale-leaseback arrangements, or other forms commonly used in the solar or similar industries. We may seek non-recourse financing covering solely the construction period of the solar project or may also seek financing covering part or all of the operating life of the solar project. We classify non-recourse financings in our Consolidated Balance Sheets in accordance with their terms; however, in certain circumstances, we may repay or refinance these financings prior to stated maturity dates in connection with the sale of the related project or similar such circumstances. In addition, in certain instances, the customer may assume the loans at the time that the project entity is sold to the customer. In these instances, subsequent debt assumption is reflected as a financing outflow and operating inflow in the Consolidated Statements of Cash Flows to reflect the substance of the assumption as a facilitation of customer financing from a third party.

For our residential lease program, non-recourse financing is typically accomplished by aggregating an agreed-upon volume of solar power systems and leases with residential customers into a specific project entity. The Company has entered into the following non-recourse financings with respect to its residential lease program:

In fiscal 2016, we entered into bridge loans to finance solar power systems and leases under our residential lease program. The loans are repaid over terms ranging from two to seven years. Some loans may be prepaid without penalties at our option at any time, while other loans may be prepaid, subject to a prepayment fee, after one year. During fiscal 2016, we had net proceeds of $5.7 million, in connection with these loans. As of January 1, 2017, the aggregate carrying amount of these loans, presented in "Long-term debt" on our Consolidated Balance Sheets, was $6.7 million.

We enter into long-term loans to finance solar power systems and leases under our residential lease program. The loans are repaid over their terms of between 17 and 18 years, and may be prepaid without penalty at our option beginning seven years after the original issuance of the loan. During fiscal 2016 and 2015, we had net proceeds of $111.8 million and $90.6 million, respectively, in connection with these loans. As of January 1, 2017, and January 3, 2016, the aggregate carrying amount of these loans, presented in "Short-term debt" and "Long-term debt" on our Consolidated Balance Sheets, was $283.9 million and $171.8 million, respectively.

We have entered into multiple arrangements under which solar power systems are financed by third-party investors or customers, including by a legal sale of the underlying asset that is accounted for as a borrowing under relevant accounting guidelines as the requirements to recognize the transfer of the asset were not met. Under the terms of these arrangements, the third parties make an upfront payment to us, which we recognize as a liability that will be reduced over the term of the arrangement as lease receivables and government incentives are received by the third party. As the liability is reduced, we make a corresponding reduction in receivables. We use this approach to account for both operating and sales-type leases with our residential lease customers in our consolidated financial statements. During fiscal 2016 and 2015, we had net proceeds (repayments) of $28.5 million and $(32.0) million, respectively, in connection with these facilities. As of January 1, 2017 and January 3, 2016, the aggregate carrying amount of these facilities, presented in "Accrued liabilities" and "Other long-term liabilities" on our Consolidated Balance Sheets, was $29.4 million and $36.8 million, respectively (see Note 5).

We also enter into facilities with third-party tax equity investors under which the investors invest in a structure known as a partnership flip. We hold controlling interests in these less-than-wholly-owned entities and therefore fully consolidate these entities. We account for the portion of net assets in the consolidated entities attributable to the investors as noncontrolling interests in our consolidated financial statements. Noncontrolling interests in subsidiaries that are redeemable at the option of the noncontrolling interest holder are classified accordingly as redeemable, between liabilities and equity on the Company's Consolidated Balance Sheets. During fiscal 2016 and 2015, we had net contributions of $127.3 million and $170.6 million, respectively, under these facilities and attributed losses of $74.9 million and $111.5 million, respectively, to the non-controlling interests corresponding principally to certain assets, including tax credits, which were allocated to the non-controlling interests during the periods. As of January 1, 2017 and January 3, 2016, the aggregate carrying amount of these facilities, presented in “Redeemable non-controlling interests in subsidiaries” and “Non-controlling interests in subsidiaries” on our Consolidated Balance Sheets, was $183.1 million and $128.6 million, respectively.

For our power plant and commercial solar projects, non-recourse financing is typically accomplished using an individual solar power system or a series of solar power systems with a common end customer, in each case owned by a specific project entity. We have entered into the following non-recourse financings with respect to our power plant and commercial projects:

In fiscal 2016, we entered into the Construction Revolver credit facility to support the construction of our commercial and small scale utility projects in the United States. During fiscal 2016, we had net proceeds of $9.9 million, in connection with the facility. As of January 1, 2017, the aggregate carrying amount of the Construction Revolver, presented in "Short-term debt" and "Long-term debt" on our Consolidated Balance Sheets, was $10.5 million.

79

Table of Contents



In fiscal 2016, we entered into a long-term credit facility to finance the 125 MW utility-scale Boulder power plant project in Nevada. During fiscal 2016, we had net proceeds of $21.9 million, in connection with the facility. As of January 1, 2017, the aggregate carrying amount of this facility, presented in "Short-term debt" and "Long-term debt" on our Consolidated Balance Sheets, was $28.8 million.

In fiscal 2016, we entered into a short-term credit facility to finance the utility-scale Rio Bravo power plant projects in California, with an aggregate size of approximately 50 MW. During fiscal 2016, in connection with the sale of the project, the Company repaid the full amount outstanding, and as a result, the Company had net proceeds of $114.8 million and net repayments of $117.6 million in connection with the facility. As of January 1, 2017, the aggregate carrying amount of this facility, presented in "Short-term debt" on our Consolidated Balance Sheets, was zero.

In fiscal 2016, we entered into a short-term credit facility to finance the 20 MW utility-scale Wildwood power plant project in California. During fiscal 2016, in connection with the sale of the project, the Company repaid the full amount outstanding, and as a result, the Company had net proceeds of $44.5 million and net repayments of $45.6 million, in connection with the facility. As of January 1, 2017, the aggregate carrying amount of this facility, presented in "Short-term debt" on our Consolidated Balance Sheets, was zero.

In fiscal 2016, we entered into a long-term credit facility to finance several related utility-scale power plant projects in California, including the Stanford and Turlock projects, with an aggregate size of approximately 350 MW. During fiscal 2016, in connection with the sale of the project, the Company repaid the full amount outstanding, and as a result, the Company had net proceeds of $192.2 million and net repayments of $201.6 million, in connection with the facility. As of January 1, 2017, the aggregate carrying amount of this facility, presented in "Short-term debt" and "Long-term debt" on our Consolidated Balance Sheets, was zero.

In fiscal 2016, we entered into a long-term credit facility to finance the 111 MW utility-scale El Pelicano power plant project in Chile. During fiscal 2016, we had net proceeds of $84.6 million in connection with the facility. As of January 1, 2017, the aggregate carrying amount of this facility, presented in "Long-term debt" on our Consolidated Balance Sheets, was $90.5 million.

In fiscal 2015, we entered into a long-term credit facility to finance the 128 MW utility-scale Henrietta power plant in California. During fiscal 2016, in connection with the sale of the project, we repaid the full amount outstanding, and as a result, the Company had net repayments of $216.7 million in connection with the facility. As of January 1, 2017 and January 3, 2016, the aggregate carrying amount of this loan, presented in "Short-term debt" and "Long-term debt" on our Consolidated Balance Sheets, was zero and $216.7 million, respectively.

In fiscal 2015, we entered into a long-term credit facility to finance the 60 MW Hooper utility-scale power plant in Colorado. In the first quarter of fiscal 2016, we repaid the full amount outstanding. During fiscal 2016, we had net repayments of $37.3 million in connection with the facility. As of January 1, 2017 and January 3, 2016, the carrying amount of this facility, presented in "Long-term debt" on our Consolidated Balance Sheets, was zero and $37.3 million, respectively.

In fiscal 2013, we entered into a long-term loan agreement to finance a 5.4 MW utility and power plant operating in Arizona. As of January 1, 2017 and January 3, 2016, the aggregate carrying amount under this loan, presented in "Short-term debt" and "Long-term debt" on our Consolidated Balance Sheets, was $7.6 million and $8.1 million, respectively.

Other debt is further composed of non-recourse project loans in EMEA, which are scheduled to mature through 2028.

See "Item 8. Financial Statements—Notes to Consolidated Financial Statements—Note 6. Leasing" for a discussion of the Company’s sale-leasebacks accounted for under the financing method.

Liquidity

As of January 1, 2017, we had unrestricted cash and cash equivalents of $425.3 million as compared to $954.5 million as of January 3, 2016. Our cash balances are held in numerous locations throughout the world and as of January 1, 2017, we had approximately $149.8 million held outside of the United States. This offshore cash is used to fund operations of our business in the Europe and Asia Pacific regions as well as non-U.S. manufacturing operations, which require local payment for product materials and other expenses.  The amounts held outside of the United States represent the earnings of our foreign subsidiaries which, if repatriated to the United States under current law, would be subject to United States federal and state tax less applicable foreign tax credits. Repatriation of earnings that have not been subjected to U.S. or foreign withholding tax and that

80

Table of Contents


have been indefinitely reinvested outside the U.S. could result in additional United States federal income tax or foreign withholding tax payments in future years.

We expect total capital expenditures related to purchases of property, plant and equipment in the range of $110 million to $130 million in fiscal 2017 in order to increase our manufacturing capacity for our highest efficiency X-Series product platform and our new Performance Series technology, improve our current and next generation solar cell manufacturing technology, and other projects. In addition, we expect to invest a significant amount of capital to develop solar power systems and plants for sale to customers. The development of solar power plants can require long periods of time and substantial initial investments. Our efforts in this area may consist of all stages of development, including land acquisition, permitting, financing, construction, operation and the eventual sale of the projects. We often choose to bear the costs of such efforts prior to the final sale to a customer, which involves significant upfront investments of resources (including, for example, large transmission deposits or other payments, which may be non-refundable), land acquisition, permitting, legal and other costs, and in some cases the actual costs of constructing a project, in advance of the signing of PPAs and EPC contracts and the receipt of any revenue, much of which is not recognized for several additional months or years following contract signing. Any delays in disposition of one or more projects could have a negative impact on our liquidity.

Certain of our customers also require performance bonds issued by a bonding agency or letters of credit issued by financial institutions, which are returned to us upon satisfaction of contractual requirements. If there is a contractual dispute with the customer, the customer may withhold the security or make a draw under such security, which could have an adverse impact on our liquidity. Obtaining letters of credit may require adequate collateral. All letters of credit issued under our 2016 Guaranteed LC Facilities are guaranteed by Total S.A. pursuant to the Credit Support Agreement. Our September 2011 letter of credit facility with Deutsche Bank Trust is fully collateralized by restricted cash, which reduces the amount of cash available for operations. As of January 1, 2017, letters of credit issued under the Deutsche Bank Trust facility amounted to $3.1 million which were fully collateralized with restricted cash on the Consolidated Balance Sheets.

In fiscal 2011, we launched our residential lease program with dealers in the United States, in partnership with a third-party financial institution, which allows customers to obtain SunPower systems under lease agreements up to 20 years, subject to financing availability. We have entered into facilities with financial institutions that will provide financing to support additional residential solar lease projects. Under the terms of certain programs, we receive upfront payments for periods under which the third-party financial institution has agreed to assume collection risk for certain residential leases. Changes in the amount or timing of upfront payments received from the financial institutions may have an impact on our cash position within the next twelve months. The normal collection of monthly rent payments for leases placed in service is not expected to have a material impact on our cash position within the next twelve months. We have entered into multiple facilities with third-party investors under which both parties will invest in entities that hold SunPower solar power systems and leases with residential customers. We determined that we hold a controlling interest in these less-than-wholly-owned entities and have fully consolidated these entities as a result (see "Item 8. Financial Statements—Notes to Consolidated Financial Statements—Note 6. Leasing"). During fiscal 2016, we received $146.3 million in contributions from investors under the related facility agreements. Additionally, during fiscal 2014, 2015 and 2016, we entered into several long-term non-recourse loans to finance solar power systems and leases under our residential lease program. In fiscal 2016, we drew down $116.1 million of proceeds, net of issuance costs, under the loan agreements. The loans have 17- and 18-year terms and as of January 1, 2017, the short-term and long-term balances of the loans were $7.3 million and $276.6 million, respectively. We are actively arranging additional third-party financing for our residential lease program; however, the credit markets are unpredictable, and if they become challenging, we may be unable to arrange additional financing partners for our residential lease program in future periods, which could have a negative impact on our sales. In the unlikely event that we enter into a material number of additional leases without promptly obtaining corresponding third-party financing, our cash and working capital could be negatively affected. Additionally, we have approximately $33.1 million of cash and cash equivalents within our consolidated residential leasing subsidiaries that is used by those subsidiaries for their working capital needs. This cash is typically not available to us to use for general corporate purposes unless certain financial obligations are first settled. In the event that we choose to transfer cash out of these subsidiaries for general corporate purposes in the future, we would first be required to distribute a portion of the cash to lender debt reserves and investors who hold noncontrolling interests in the relevant subsidiaries.

Solar power plant projects often require significant up-front investments. These include payments for preliminary engineering, permitting, legal, and other expenses before we can determine whether a project is feasible. We often make arrangements with third-party financiers to acquire and build solar power systems or to fund project construction using non-recourse project debt. As of January 1, 2017, outstanding amounts related to our project financing totaled $427.9 million.

We believe that our current cash, cash equivalents, cash expected to be generated from operations and funds available under our existing credit facilities will be sufficient to meet our working capital needs and fund our committed capital

81

Table of Contents


expenditures over the next 12 months from the date of the issuance of the financial statements, including the development and construction of solar power systems and plants. As such, we do not believe substantial doubt exists regarding the Company's ability to continue as a going concern. In conjunction with evaluating our ability to continue as a going concern, we have considered our historical ability to work with our vendors to obtain favorable payment terms, when possible, and our ability to reduce manufacturing output to reduce inventory in order to optimize our working capital. We may also choose to explore additional options in connection with our short-term liquidity needs, such as selling raw materials inventory to third parties, liquidating certain investments, discontinuing the development of certain projects, implementing additional restructuring plans, and deferring or canceling uncommitted capital expenditures and other investment or acquisition activities. We expect to be able to supplement our short-term liquidity, if necessary, with access to capital markets and additional credit facilities, including non-recourse debt, made available by various domestic and foreign financial institutions. However, there can be no assurance that our liquidity will be adequate over time or that we will in fact have access to capital markets on reasonable terms or at all, whether to meet operating needs or to refinance debt. A significant portion of our revenue is generated from a limited number of customers and large projects and our inability to execute these projects, or to collect from these customers or for these projects, would have a significant negative impact on our business. Our capital expenditures and use of working capital may be greater than we expect if we decide to make additional investments in the development and construction of solar power plants and sales of power plants and associated cash proceeds are delayed, or if we decide to accelerate increases in our manufacturing capacity internally or through capital contributions to joint ventures. We require project financing in connection with the construction of solar power plants, which financing may not be available on terms acceptable to us. In addition, we could in the future make additional investments or guarantee certain financial obligations of our investments, which could reduce our cash flows, increase our indebtedness and expose us to the credit risk of our joint ventures. See also "Risks Related to Our Sales Channels—A limited number of customers and large projects are expected to continue to comprise a significant portion of our revenues and any decrease in revenues from those customers or projects, payment of liquidated damages, or an increase in related expenses, could have a material adverse effect on our business, results of operations and financial condition," and "Risks Related to Our Liquidity—We may be unable to generate sufficient cash flows or obtain access to external financing necessary to fund our operations and make adequate capital investments as planned due to the general economic environment and the continued market pressure driving down the average selling prices of our solar power products," among other factors in Part I. "Item 1A. Risk Factors".

On February 17, 2016, we entered into an amendment to the credit agreement with Credit Agricole to expand the available borrowings under the revolving credit facility to $300.0 million and to add a $200.0 million letter of credit subfacility, subject to the satisfaction of certain conditions. Proceeds from our revolving credit facility with Credit Agricole may be used for general corporate purposes. Our revolving credit facility with Credit Agricole requires that we maintain certain financial ratios, including the ratio that our debt at the end of each quarter to our EBITDA for the last twelve months, as defined, will not exceed 4.5 to 1. As of January 1, 2017, $295.3 million remained undrawn under our revolving credit facility with Credit Agricole; however we are currently not in compliance with the covenant for the Credit Agricole credit facility that requires the ratio of our debt at the end of each quarter to our EBITDA for the last twelve months, as defined, to not exceed 4.5 to 1. We are not in default with Credit Agricole; however, we may not draw on the facility without collateralizing additional future borrowings with cash. We expect to not be in compliance with the aforementioned financial ratio covenant for the Credit Agricole credit facility for at least the remainder of fiscal 2017, which will affect the availability of borrowings under the line, if not remedied. Additionally, on May 4, 2016, we entered into the Construction Revolver credit facility, under which we may borrow up to $200 million, with a $100 million accordion feature, in support of our commercial and small scale utility projects in the United States until its May 4, 2021 maturity date, subject to certain conditions. As of January 1, 2017, we had $189.5 million available to us under the Construction Revolver credit facility. There are no assurances, however, that we will have sufficient available cash to repay our indebtedness or that we will be able to refinance such indebtedness on similar terms to the expiring indebtedness. If our capital resources are insufficient to satisfy our liquidity requirements, we may seek to sell additional equity securities or debt securities or obtain other debt financing. The current economic environment, however, could limit our ability to raise capital by issuing new equity or debt securities on acceptable terms, and lenders may be unwilling to lend funds on acceptable terms in the amounts that would be required to supplement cash flows to support operations. The sale of additional equity securities or convertible debt securities would result in additional dilution to our stockholders (and the potential for further dilution upon the exercise of warrants or the conversion of convertible debt) and may not be available on favorable terms or at all, particularly in light of the current conditions in the financial and credit markets. Additional debt would result in increased expenses and would likely impose new restrictive covenants which may be similar or different than those restrictions contained in the covenants under our current loan agreements and debentures. In addition, financing arrangements, including project financing for our solar power plants and letters of credit facilities, may not be available to us, or may not be available in amounts or on terms acceptable to us.
 

82

Table of Contents


Contractual Obligations

The following table summarizes our contractual obligations as of January 1, 2017:
 
 
 
 
Payments Due by Fiscal Period
(In thousands)
 
Total
 
2017
 
2018-2019
 
2020-2021
 
Beyond 2021
Convertible debt, including interest1
 
$
1,246,360

 
$
22,750

 
$
341,944

 
$
438,958

 
$
442,708

IFC mortgage loan, including interest2
 
17,526

 
17,526

 

 

 

CEDA loan, including interest3
 
66,338

 
2,550

 
5,100

 
5,100

 
53,588

Other debt, including interest4
 
680,238

 
71,031

 
77,222

 
70,623

 
461,362

Future financing commitments5
 
8,233

 
8,233

 

 

 

Operating lease commitments6
 
130,419

 
15,894

 
29,169

 
24,427

 
60,929

Sale-leaseback financing7
 
187,627

 
27,987

 
23,848

 
22,079

 
113,713

Capital lease commitments8
 
4,510

 
1,032

 
1,509

 
1,192

 
777

Non-cancellable purchase orders9
 
209,372

 
209,372

 

 

 

Purchase commitments under agreements10
 
1,073,537

 
526,734

 
381,955

 
162,848

 
2,000

Deferred purchase consideration in connection with acquisition
 
61,100

 

 
31,100

 
30,000

 

Total
 
$
3,685,260

 
$
903,109

 
$
891,847

 
$
755,227

 
$
1,135,077

1 
Convertible debt, including interest, relates to the aggregate of $1,125.0 million in outstanding principal amount of our senior convertible debentures on January 1, 2017. For the purpose of the table above, we assume that all holders of the outstanding debentures will hold the debentures through the date of maturity, and upon conversion, the values of the senior convertible debentures will be equal to the aggregate principal amount with no premiums.

2 
IFC mortgage loan, including interest, relates to the $17.5 million outstanding principal amount as of January 1, 2017. Under the loan agreement, we are required to repay the amount borrowed, starting 2 years after the date of borrowing, in 10 equal semiannual installments over the following 5 years. We are required to pay interest of LIBOR plus 3% per annum on outstanding borrowings; a front-end fee of 1% on the principal amount of borrowings at the time of borrowing; and a commitment fee of 0.5% per annum on funds available for borrowing and not borrowed.

3 
CEDA loan, including interest, relates to the proceeds of the $30.0 million aggregate principal amount of the Bonds. The Bonds mature on April 1, 2031 and bear interest at a fixed rate of 8.50% through maturity.

4 
Other debt, including interest, primarily relates to non-recourse finance projects and solar power systems and leases under our residential lease program as described in "Item 8. Financial Statements—Notes to Consolidated Financial Statements—Note 9. Commitments and Contingencies."

5 
In connection with purchase and joint venture agreements with non-public companies, we will be required to provide additional financing to such parties of up to $8.2 million, subject to certain conditions.

6 
Operating lease commitments primarily relate to certain solar power systems leased from unaffiliated third parties over minimum lease terms of up to 20 years and various facility lease agreements.

7 
Sale-leaseback financing relates to future minimum lease obligations for solar power systems under sale-leaseback arrangements which were determined to include integral equipment and accounted for under the financing method.

8 
Capital lease commitments primarily relate to certain buildings, manufacturing and equipment under capital leases in Europe for terms of up to 12 years.

9 
Non-cancellable purchase orders relate to purchases of raw materials for inventory and manufacturing equipment from a variety of vendors.

10 
Purchase commitments under agreements relate to arrangements entered into with several suppliers, including some of our non-consolidated investees, for polysilicon, ingots, wafers, and Solar Renewable Energy Credits, among others. These agreements specify future quantities and pricing of products to be supplied by the vendors for periods up to 8 years and there are certain consequences, such as forfeiture of advanced deposits and liquidated damages relating to previous purchases, in the event that we terminate the arrangements. During fiscal 2016, we did not fulfill all of the purchase commitments we were otherwise obligated to take by December 31, 2016, as specified in related contracts with a supplier. As of January 1, 2017, the Company has recorded an offsetting

83

Table of Contents


asset, recorded within "Prepaid expenses and other current assets," and liability, recorded within "Accrued liabilities," totaling $83.9 million. This amount represents the unfulfilled amount as of that date as the Company expects to satisfy the obligation via purchases of inventory in fiscal 2017, within the applicable contractual cure period.

Liabilities Associated with Uncertain Tax Positions

Due to the complexity and uncertainty associated with our tax positions, we cannot make a reasonably reliable estimate of the period in which cash settlement will be made for our liabilities associated with uncertain tax positions in other long-term liabilities. Therefore, they have been excluded from the table above. As of January 1, 2017, total liabilities associated with uncertain tax positions were $47.2 million and are included in "Other long-term liabilities" in our Consolidated Balance Sheets as they are not expected to be paid within the next twelve months.

Off-Balance-Sheet Arrangements

As of January 1, 2017, we did not have any significant off-balance-sheet arrangements, as defined in Item 303(a)(4)(ii) of SEC Regulation S-K.


84

Table of Contents


ITEM 7A: QUANTITATIVE AND QUALITATIVE DISCLOSURE ABOUT MARKET RISK

Foreign Currency Exchange Risk

Our exposure to movements in foreign currency exchange rates is primarily related to sales to European customers that are denominated in Euros. Revenue generated from European customers represented 3%, 8% and 10% of our total revenue in fiscal 2016, 2015 and 2014, respectively. A 10% change in the Euro exchange rate would have impacted our revenue by approximately $7.6 million, $12.2 million and $28.9 million in fiscal 2016, 2015 and 2014, respectively.

In the past, we have experienced an adverse impact on our revenue, gross margin and profitability as a result of foreign currency fluctuations. When foreign currencies appreciate against the U.S. dollar, inventories and expenses denominated in foreign currencies become more expensive. An increase in the value of the U.S. dollar relative to foreign currencies could make our solar power products more expensive for international customers, thus potentially leading to a reduction in demand, our sales and profitability. Furthermore, many of our competitors are foreign companies that could benefit from such a currency fluctuation, making it more difficult for us to compete with those companies.

We currently conduct hedging activities which involve the use of option and forward currency contracts that are designed to address our exposure to changes in the foreign exchange rate between the U.S. dollar and other currencies. As of January 1, 2017, we had outstanding hedge option currency contracts and forward currency contracts with aggregate notional values of $28.3 million and $42.9 million, respectively. As of January 3, 2016, we had outstanding hedge option currency contracts and forward currency contracts with aggregate notional values of zero and $35.7 million, respectively. Because we hedge some of our expected future foreign exchange exposure, if associated revenues do not materialize we could experience a reclassification of ineffective gains or losses into earnings. Such a reclassification could adversely impact our revenue, margins and results of operations. We cannot predict the impact of future exchange rate fluctuations on our business and operating results.

Credit Risk
 
We have certain financial and derivative instruments that subject us to credit risk. These consist primarily of cash and cash equivalents, restricted cash and cash equivalents, investments, accounts receivable, notes receivable, advances to suppliers, foreign currency option contracts, foreign currency forward contracts, bond hedge and warrant transactions. We are exposed to credit losses in the event of nonperformance by the counterparties to our financial and derivative instruments. Our investment policy requires cash and cash equivalents, restricted cash and cash equivalents, and investments to be placed with high-quality financial institutions and limits the amount of credit risk from any one issuer. We additionally perform ongoing credit evaluations of our customers’ financial condition whenever deemed necessary and generally do not require collateral.

We enter into agreements with vendors that specify future quantities and pricing of polysilicon to be supplied for periods up to 10 years. Under certain agreements, we are required to make prepayments to the vendors over the terms of the arrangements. As of January 1, 2017 and January 3, 2016, advances to suppliers totaled $284.8 million and $359.1 million, respectively. Two suppliers accounted for 90% and 10% of total advances to suppliers as of January 1, 2017, and 82% and 16% as of January 3, 2016.

We enter into foreign currency derivative contracts and convertible debenture hedge transactions with high-quality financial institutions and limit the amount of credit exposure to any single counterparty. The foreign currency derivative contracts are limited to a time period of 12 months or less. We regularly evaluate the credit standing of our counterparty financial institutions.

Interest Rate Risk

We are exposed to interest rate risk because many of our customers depend on debt financing to purchase our solar power systems. An increase in interest rates could make it difficult for our customers to obtain the financing necessary to purchase our solar power systems on favorable terms, or at all, and thus lower demand for our solar power products, reduce revenue and adversely impact our operating results. An increase in interest rates could lower a customer's return on investment in a system or make alternative investments more attractive relative to solar power systems, which, in each case, could cause our customers to seek alternative investments that promise higher returns or demand higher returns from our solar power systems, reduce gross margin and adversely impact our operating results. This risk is significant to our business because our sales model is highly sensitive to interest rate fluctuations and the availability of credit, and would be adversely affected by increases in interest rates or liquidity constraints.
 

85

Table of Contents


Our interest expense would increase to the extent interest rates rise in connection with our variable interest rate borrowings. As of January 1, 2017, the outstanding principal balance of our variable interest borrowings was $201.4 million. We do not believe that an immediate 10% increase in interest rates would have a material effect on our financial statements. In addition, lower interest rates would have an adverse impact on our interest income. Our investment portfolio primarily consists of $3.0 million in money market funds as of January 1, 2017 which exposes us to interest rate risk. Due to the relatively short-term nature of our investment portfolio, we do not believe that an immediate 10% increase in interest rates would have a material effect on the fair market value of our money market funds. Since we believe we have the ability to liquidate substantially all of this portfolio, we do not expect our operating results or cash flows to be materially affected to any significant degree by a sudden change in market interest rates on our investment portfolio.

Equity Price Risk Involving Minority Investments in Joint Ventures and Other Non-Public Companies

Our investments held in joint ventures and other non-public companies expose us to equity price risk. As of January 1, 2017 and January 3, 2016, investments of $(6.9) million and $186.4 million, respectively, are accounted for using the equity method, and $39.4 million and $36.4 million, respectively, are accounted for using the cost method. The carrying value of our equity method investments as of January 1, 2017 and January 3, 2016 included the negative balance of $60.6 million and $30.9 million, respectively, of our investment in the 8point3 Group (See "Item 8. Financial Statements—Notes to Consolidated Financial Statements—Note 10. Equity Method Investments"). These strategic investments in third parties are subject to risk of changes in market value, which if determined to be other-than-temporary, could result in realized impairment losses. We generally do not attempt to reduce or eliminate our market exposure in equity and cost method investments. We monitor these investments for impairment and record reductions in the carrying values when necessary. Circumstances that indicate an other-than-temporary decline include the valuation ascribed to the issuing company in subsequent financing rounds, decreases in quoted market prices and declines in operations of the issuer. There can be no assurance that our equity and cost method investments will not face risks of loss in the future.

Interest Rate Risk and Market Price Risk Involving Convertible Debt

The fair market value of our outstanding convertible debentures is subject to interest rate risk, market price risk and other factors due to the convertible feature of the debentures. The fair market value of the debentures will generally increase as interest rates fall and decrease as interest rates rise. In addition, the fair market value of the debentures will generally increase as the market price of our common stock increases and decrease as the market price of our common stock falls. The interest and market value changes affect the fair market value of the debentures, but do not impact our financial position, cash flows or results of operations due to the fixed nature of the debt obligations, except to the extent increases in the value of our common stock may provide the holders of our 4.00% debentures due 2023, 0.875% debentures due 2021, or 0.75% debentures due 2018 the right to convert such debentures into cash in certain instances. The aggregate estimated fair value of our outstanding convertible debentures was $839.2 million as of January 1, 2017. The aggregate estimated fair value of our outstanding convertible debentures was $1,253.2 million as of January 3, 2016. Estimated fair values are based on quoted market prices as reported by an independent pricing source. A 10% increase in quoted market prices would increase the estimated fair value of our then-outstanding debentures to $923.1 million and $1,378.5 million as of January 1, 2017 and January 3, 2016, respectively, and a 10% decrease in the quoted market prices would decrease the estimated fair value of our then-outstanding debentures to $755.3 million and $1,127.9 million as of January 1, 2017 and January 3, 2016, respectively.


86

Table of Contents


ITEM 8. FINANCIAL STATEMENTS AND SUPPLEMENTARY DATA

SUNPOWER CORPORATION

INDEX TO CONSOLIDATED FINANCIAL STATEMENTS

 
Page
 
 
REPORTS OF ERNST & YOUNG LLP, INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM 
 
 
FINANCIAL STATEMENTS
 
CONSOLIDATED BALANCE SHEETS 
CONSOLIDATED STATEMENTS OF OPERATIONS
CONSOLIDATED STATEMENTS OF COMPREHENSIVE INCOME (LOSS)
CONSOLIDATED STATEMENTS OF EQUITY
CONSOLIDATED STATEMENTS OF CASH FLOWS
NOTES TO CONSOLIDATED FINANCIAL STATEMENTS


87

Table of Contents


Report of Independent Registered Public Accounting Firm

The Board of Directors and Shareholders of SunPower Corporation

We have audited the accompanying consolidated balance sheets of SunPower Corporation as of January 1, 2017 and January 3, 2016, and the related consolidated statements of operations, comprehensive income (loss), equity, and cash flows for each of the three years in the period ended January 1, 2017. These financial statements are the responsibility of the Company's management. Our responsibility is to express an opinion on these financial statements based on our audits.

We conducted our audits in accordance with the standards of the Public Company Accounting Oversight Board (United States). Those standards require that we plan and perform the audit to obtain reasonable assurance about whether the financial statements are free of material misstatement. An audit includes examining, on a test basis, evidence supporting the amounts and disclosures in the financial statements. An audit also includes assessing the accounting principles used and significant estimates made by management, as well as evaluating the overall financial statement presentation. We believe that our audits provide a reasonable basis for our opinion.

In our opinion, the financial statements referred to above present fairly, in all material respects, the consolidated financial position of SunPower Corporation at January 1, 2017 and January 3, 2016, and the consolidated results of its operations and its cash flows for each of the three years in the period ended January 1, 2017, in conformity with U.S. generally accepted accounting principles.

We also have audited, in accordance with the standards of the Public Company Accounting Oversight Board (United States), SunPower Corporation's internal control over financial reporting as of January 1, 2017, based on criteria established in Internal Control - Integrated Framework issued by the Committee of Sponsoring Organizations of the Treadway Commission (2013 framework) and our report dated February 17, 2017 expressed an unqualified opinion thereon.


/s/ Ernst & Young LLP

San Jose, California
February 17, 2017




88

Table of Contents


Report of Independent Registered Public Accounting Firm


The Board of Directors and Shareholders of SunPower Corporation

We have audited SunPower Corporation’s internal control over financial reporting as of January 1, 2017, based on criteria established in Internal Control - Integrated Framework issued by the Committee of Sponsoring Organizations of the Treadway Commission (2013 framework) (the COSO criteria). SunPower Corporation’s management is responsible for maintaining effective internal control over financial reporting, and for its assessment of the effectiveness of internal control over financial reporting included in the accompanying Management’s Report on Internal Control over Financial Reporting. Our responsibility is to express an opinion on the company’s internal control over financial reporting based on our audit.
 
We conducted our audit in accordance with the standards of the Public Company Accounting Oversight Board (United States). Those standards require that we plan and perform the audit to obtain reasonable assurance about whether effective internal control over financial reporting was maintained in all material respects. Our audit included obtaining an understanding of internal control over financial reporting, assessing the risk that a material weakness exists, testing and evaluating the design and operating effectiveness of internal control based on the assessed risk, and performing such other procedures as we considered necessary in the circumstances. We believe that our audit provides a reasonable basis for our opinion.
 
A company’s internal control over financial reporting is a process designed to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles. A company’s internal control over financial reporting includes those policies and procedures that (1) pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of the assets of the company; (2) provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with generally accepted accounting principles, and that receipts and expenditures of the company are being made only in accordance with authorizations of management and directors of the company; and (3) provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use, or disposition of the company’s assets that could have a material effect on the financial statements.
 
Because of its inherent limitations, internal control over financial reporting may not prevent or detect misstatements. Also, projections of any evaluation of effectiveness to future periods are subject to the risk that controls may become inadequate because of changes in conditions, or that the degree of compliance with the policies or procedures may deteriorate.

As indicated in the accompanying Management’s Report on Internal Control over Financial Reporting, management’s assessment of and conclusion on the effectiveness of internal control over financial reporting did not include the internal controls of SunPower Corporation’s former AUOSP joint venture (now a wholly-owned subsidiary, SunPower Malaysia Manufacturing Sdn. Bhd.), which is included in the January 1, 2017 consolidated financial statements of SunPower Corporation and constituted 7% of the Company's consolidated total assets as of January 1, 2017. Our audit of internal control over financial reporting of SunPower Corporation also did not include an evaluation of the internal control over financial reporting of SunPower Corporation’s former AUOSP joint venture (now a wholly-owned subsidiary, SunPower Malaysia Manufacturing Sdn. Bhd.).

In our opinion, SunPower Corporation maintained, in all material respects, effective internal control over financial reporting as of January 1, 2017, based on the COSO criteria.
 
We also have audited, in accordance with the standards of the Public Company Accounting Oversight Board (United States), the 2016 consolidated financial statements of SunPower Corporation and our report dated February 17, 2017 expressed an unqualified opinion thereon.


/s/ Ernst & Young LLP

San Jose, California
February 17, 2017


89

Table of Contents


SunPower Corporation
Consolidated Balance Sheets
(In thousands, except share data)
 
January 1, 2017
 
January 3, 2016
Assets
 
 
 
Current assets:
 
 
 
Cash and cash equivalents
$
425,309

 
$
954,528

Restricted cash and cash equivalents, current portion
33,657

 
24,488

Accounts receivable, net1
219,638

 
190,448

Costs and estimated earnings in excess of billings1
32,780

 
38,685

Inventories
401,707

 
382,390

Advances to suppliers, current portion
111,479

 
85,012

Project assets - plants and land, current portion1
374,459

 
479,452

Prepaid expenses and other current assets1
315,670

 
359,517

Total current assets
1,914,699

 
2,514,520

 
 
 
 
Restricted cash and cash equivalents, net of current portion
55,246

 
41,748

Restricted long-term marketable securities
4,971

 
6,475

Property, plant and equipment, net
1,027,066

 
731,230

Solar power systems leased and to be leased, net
621,267

 
531,520

Project assets - plants and land, net of current portion
33,571

 
5,072

Advances to suppliers, net of current portion
173,277

 
274,085

Long-term financing receivables, net
507,333

 
334,791

Goodwill and other intangible assets, net
44,218

 
119,577

Other long-term assets1
185,519

 
297,975

Total assets
$
4,567,167

 
$
4,856,993

 
 
 
 
Liabilities and Equity
 

 
 

Current liabilities:
 

 
 

Accounts payable1
$
540,295

 
$
514,654

Accrued liabilities1
391,226

 
313,497

Billings in excess of costs and estimated earnings
77,140

 
115,739

Short-term debt
71,376

 
21,041

Customer advances, current portion1
10,138

 
33,671

Total current liabilities
1,090,175

 
998,602

 
 
 
 
Long-term debt
451,243

 
478,948

Convertible debt1
1,113,478

 
1,110,960

Customer advances, net of current portion1
298

 
126,183

Other long-term liabilities1
721,032

 
564,557

Total liabilities
3,376,226

 
3,279,250

Commitments and contingencies (Note 9)


 
 
Redeemable noncontrolling interests in subsidiaries
103,621

 
69,104

Equity:
 

 
 

Preferred stock, $0.001 par value; 10,000,000 shares authorized; none issued and outstanding as of both January 1, 2017 and January 3, 2016

 

Common stock, $0.001 par value, 367,500,000 shares authorized; 148,079,718 shares issued, and 138,510,325 outstanding as of January 1, 2017; 145,242,705 shares issued, and 136,712,339 outstanding as of January 3, 2016
139


137

Additional paid-in capital
2,410,395

 
2,359,917

Accumulated deficit
(1,218,681
)
 
(747,617
)
Accumulated other comprehensive loss
(7,238
)
 
(8,023
)
Treasury stock, at cost; 9,569,393 shares of common stock as of January 1, 2017; 8,530,366 shares of common stock as of January 3, 2016
(176,783
)
 
(155,265
)
Total stockholders' equity
1,007,832

 
1,449,149

Noncontrolling interests in subsidiaries
79,488

 
59,490

Total equity
1,087,320

 
1,508,639

Total liabilities and equity
$
4,567,167

 
$
4,856,993

1 
The Company has related-party balances for transactions made with Total S.A. and its affiliates as well as unconsolidated entities in which the Company has a direct equity investment. These related-party balances are recorded within the "Accounts Receivable, net," "Costs and estimated earnings in excess of billings," "Project assets - plants and land, current portion," "Prepaid expenses and other current assets," "Other long-term assets," "Accounts payable," "Accrued Liabilities," and "Convertible debt, net of current portion," financial statement line items in the Consolidated Balance Sheets (see Note 2, Note 7, Note 10, Note 11, and Note 12).


The accompanying notes are an integral part of these consolidated financial statements.

90

Table of Contents


SunPower Corporation
Consolidated Statements of Operations
(In thousands, except per share data)
 
 
Fiscal Year
 
 
January 1, 2017
 
January 3, 2016
 
December 28, 2014

 
 
 
 
 
 
Revenue1
 
 
 
 
 
 
Solar power systems, components, and other
 
$
2,294,608

 
$
1,389,660

 
$
2,897,305

Residential leasing
 
264,954

 
186,813

 
129,960


 
$
2,559,562

 
$
1,576,473

 
$
3,027,265

Cost of revenue1
 
 
 
 
 
 
Solar power systems, components, and other
 
2,173,364

 
1,192,535

 
2,315,894

Residential leasing
 
196,232

 
139,292

 
86,244


 
2,369,596

 
1,331,827

 
2,402,138

Gross margin
 
189,966

 
244,646

 
625,127

Operating expenses:
 
 
 
 
 
 
Research and development1
 
116,130

 
99,063

 
73,343

Sales, general and administrative1
 
329,061

 
345,486

 
288,321

Restructuring charges
 
207,189

 
6,391

 
12,223

Total operating expenses
 
652,380

 
450,940

 
373,887

Operating income (loss)
 
(462,414
)
 
(206,294
)
 
251,240

Other income (expense), net:
 
 
 
 
 
 
Interest income
 
2,652

 
2,120

 
2,583

Interest expense1
 
(60,735
)
 
(43,796
)
 
(69,658
)
Gain on settlement of preexisting relationships in connection with acquisition2
 
203,252

 

 

Loss on equity method investment in connection with acquisition2
 
(90,946
)
 

 

Goodwill impairment
 
(147,365
)
 

 

Other, net
 
(9,039
)
 
5,659

 
449

Other expense, net
 
(102,181
)
 
(36,017
)
 
(66,626
)
Income (loss) before income taxes and equity in earnings of unconsolidated investees
 
(564,595
)
 
(242,311
)
 
184,614

 Provision for income taxes
 
(7,319
)
 
(66,694
)
 
(8,760
)
Equity in earnings of unconsolidated investees
 
28,070

 
9,569

 
7,241

Net income (loss)
 
(543,844
)
 
(299,436
)
 
183,095

Net loss attributable to noncontrolling interests and redeemable noncontrolling interests
 
72,780

 
112,417

 
62,799

Net income (loss) attributable to stockholders
 
$
(471,064
)
 
$
(187,019
)
 
$
245,894

 
 
 
 
 
 
 
Net income (loss) per share attributable to stockholders:
 
 
 
 
 
 
Basic
 
$
(3.41
)
 
$
(1.39
)
 
$
1.91

Diluted
 
$
(3.41
)
 
$
(1.39
)
 
$
1.55

Weighted-average shares:
 
 
 
 
 
 
Basic
 
137,985

 
134,884

 
128,635

Diluted
 
137,985

 
134,884

 
162,751

1 
The Company has related-party transactions with Total S.A. and its affiliates as well as unconsolidated entities in which the Company has a direct equity investment. These related-party transactions are recorded within the "Revenue: Solar power systems and components," "Cost of revenue: Solar power systems and components," "Operating expenses: Research and development," "Operating expenses: Sales, general and administrative," and "Other income (expense), net: Interest expense" financial statement line items in the Consolidated Statements of Operations (see Note 2 and Note 10).

2 
See Note 3.

The accompanying notes are an integral part of these consolidated financial statements.

91

Table of Contents


SunPower Corporation
Consolidated Statements of Comprehensive Income (Loss)
(In thousands)

 
 
Fiscal Year
 
 
January 1, 2017
 
January 3, 2016
 
December 28, 2014
Net income (loss)
 
$
(543,844
)
 
$
(299,436
)
 
$
183,095

Components of comprehensive income (loss):
 
 
 
 
 
 
Translation adjustment
 
(1,085
)
 
(2,452
)
 
(4,946
)
Net change in derivatives (Note 12)
 
(4,739
)
 
7,385

 
(638
)
Net gain (loss) on long-term pension liability adjustment

 
6,283

 
823

 
(2,878
)
Income taxes
 
326

 
(324
)
 
(675
)
Net change in accumulated other comprehensive income (loss)
 
785

 
5,432

 
(9,137
)
Total comprehensive income (loss)
 
(543,059
)
 
(294,004
)
 
173,958

Comprehensive loss attributable to noncontrolling interests and redeemable noncontrolling interests
 
72,780

 
112,417

 
62,799

Comprehensive income (loss) attributable to stockholders
 
$
(470,279
)
 
$
(181,587
)
 
$
236,757


The accompanying notes are an integral part of these consolidated financial statements.


92

Table of Contents


SunPower Corporation
Consolidated Statements of Equity
(In thousands)

 
 
 
 
Common Stock
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
Redeemable Noncontrolling Interests
 
Shares
 
Value
 
Additional
Paid-in
Capital
 
Treasury
Stock
 
Accumulated Other
Comprehensive Income (Loss)
 
Retained Earnings(Accumulated Deficit)
 
Total
Stockholders’
Equity
 
Noncontrolling Interests
 
Total Equity
Balances at December 29, 2013
 
$

 
121,536

 
$
122

 
$
1,980,778

 
$
(53,937
)
 
$
(4,318
)
 
$
(806,492
)
 
$
1,116,153

 
$
37,630

 
$
1,153,783

Net income (loss)
 
(27,089
)
 

 

 

 

 

 
245,894

 
245,894

 
(35,710
)
 
210,184

Other comprehensive loss
 

 

 

 

 

 
(9,137
)
 

 
(9,137
)
 

 
(9,137
)
Issuance of common stock upon exercise of options
 

 
106

 

 
1,052

 

 

 

 
1,052

 

 
1,052

Issuance of restricted stock to employees, net of cancellations
 

 
4,431

 
2

 
(2
)
 

 

 

 

 

 

Issuance of common stock upon conversion of convertible debt
 

 
7,131

 
7

 
188,256

 

 

 

 
188,263

 

 
188,263

Settlement of the 4.75% Bond hedge
 

 

 

 
68,842

 

 

 

 
68,842

 

 
68,842

Settlement of the 4.75% Warrants
 

 

 

 
(81,077
)
 

 

 

 
(81,077
)
 

 
(81,077
)
Stock-based compensation expense
 

 

 

 
55,592

 

 

 

 
55,592

 

 
55,592

Tax benefit from convertible debt interest deduction
 

 

 

 
3,761

 

 

 

 
3,761

 

 
3,761

Tax benefit from stock-based compensation
 

 

 

 
2,379

 

 

 

 
2,379

 

 
2,379

Contributions from noncontrolling interests and redeemable noncontrolling interests
 
34,102

 

 

 

 

 

 

 

 
66,581

 
66,581

Distributions to noncontrolling interests and redeemable noncontrolling interests
 
(2,438
)
 

 

 

 

 

 

 

 
(2,655
)
 
(2,655
)
Purchases of treasury stock
 

 
(1,738
)
 

 

 
(57,548
)
 

 

 
(57,548
)
 

 
(57,548
)
Transfer of redeemable noncontrolling interests
 
23,991

 

 

 

 

 

 

 

 
(23,991
)
 
(23,991
)
Balances at December 28, 2014
 
$
28,566

 
131,466

 
$
131

 
$
2,219,581

 
$
(111,485
)
 
$
(13,455
)
 
$
(560,598
)
 
$
1,534,174

 
$
41,855

 
$
1,576,029

Net loss
 
(13,689
)
 

 

 

 

 

 
(187,019
)
 
(187,019
)
 
(98,728
)
 
(285,747
)
Other comprehensive income
 

 

 

 

 

 
5,432

 

 
5,432

 

 
5,432

Issuance of common stock upon exercise of options
 

 
58

 

 
514

 

 

 

 
514

 

 
514

Issuance of restricted stock to employees, net of cancellations
 

 
3,560

 
3

 
(3
)
 

 

 

 

 

 

Settlement of the 4.5% Warrants
 

 
3,008

 
3

 
(577
)
 

 

 

 
(574
)
 

 
(574
)
Stock-based compensation expense
 

 

 

 
61,481

 

 

 

 
61,481

 

 
61,481

Tax benefit from convertible debt interest deduction
 

 

 

 
39,546

 

 

 

 
39,546

 

 
39,546

Tax benefit from stock-based compensation
 

 

 

 
39,375

 

 

 

 
39,375

 

 
39,375

Contributions from noncontrolling interests
 
57,064

 

 

 

 

 

 

 

 
123,817

 
123,817

Distributions to noncontrolling interests
 
(2,837
)
 

 

 

 

 

 

 

 
(7,454
)
 
(7,454
)
Purchases of treasury stock
 

 
(1,381
)
 

 

 
(43,780
)
 

 

 
(43,780
)
 

 
(43,780
)
Balances at January 3, 2016
 
$
69,104

 
136,711

 
$
137

 
$
2,359,917

 
$
(155,265
)
 
$
(8,023
)
 
$
(747,617
)
 
$
1,449,149

 
$
59,490

 
$
1,508,639

Net income (loss)
 
(75,817
)
 

 

 

 

 

 
(471,064
)
 
(471,064
)
 
3,036

 
(468,028
)
Other comprehensive loss
 

 

 

 

 

 
785

 

 
785

 

 
785

Issuance of restricted stock to employees, net of cancellations
 

 
2,836

 
3

 

 

 

 

 
3

 

 
3

Stock-based compensation expense
 

 

 

 
56,110

 

 

 

 
56,110

 

 
56,110

Tax benefit from convertible debt interest deduction
 

 

 

 
(2,822
)
 

 

 

 
(2,822
)
 

 
(2,822
)
Tax benefit from stock-based compensation
 

 

 

 
(2,810
)
 

 

 

 
(2,810
)
 

 
(2,810
)
Contributions from noncontrolling interests
 
117,120

 

 

 

 

 

 

 

 
29,215

 
29,215

Distributions to noncontrolling interests
 
(6,786
)
 

 

 

 

 

 

 

 
(12,253
)
 
(12,253
)
Purchases of treasury stock
 

 
(1,039
)
 
(1
)
 

 
(21,518
)
 

 

 
(21,519
)
 

 
(21,519
)
Balances at January 1, 2017
 
$
103,621

 
138,508

 
$
139

 
$
2,410,395

 
$
(176,783
)
 
$
(7,238
)
 
$
(1,218,681
)
 
$
1,007,832

 
$
79,488

 
$
1,087,320


The accompanying notes are an integral part of these consolidated financial statements.

93

Table of Contents


SunPower Corporation
Consolidated Statements of Cash Flows
(In thousands)
 
 
Fiscal Year
 
 
January 1, 2017
 
January 3, 2016
 
December 28, 2014
Cash flows from operating activities:
 
 
 
 
 
 
Net income (loss)
 
$
(543,844
)
 
$
(299,436
)
 
$
183,095

Adjustments to reconcile net loss to net cash used in operating activities, net of effect of acquisitions:
 
 
 
 
 
 
Depreciation and amortization
 
174,209

 
138,007

 
108,795

Stock-based compensation
 
61,498

 
58,960

 
55,592

Non-cash interest expense
 
1,057

 
6,184

 
21,585

Non-cash restructuring charges
 
166,717

 

 

Gain on settlement of preexisting relationships in connection with acquisition
 
(203,252
)
 

 

Loss on equity method investment in connection with acquisition
 
90,946

 

 

Goodwill impairment
 
147,365

 

 

Dividend from 8point3 Energy Partners LP
 
6,949

 



Equity in earnings of unconsolidated investees
 
(28,070
)
 
(9,569
)
 
(7,241
)
Excess tax benefit from stock-based compensation
 
(2,810
)
 
(39,375
)
 
(2,379
)
Deferred income taxes
 
(6,611
)
 
50,238

 
6,120

Gain on sale of residential lease portfolio to 8point3 Energy Partners LP
 

 
(27,915
)
 

Other, net
 
4,793

 
2,589

 
5,278

Changes in operating assets and liabilities, net of effect of acquisitions:
 
 
 
 
 
 
Accounts receivable
 
(33,466
)
 
311,743

 
(31,505
)
Costs and estimated earnings in excess of billings
 
6,198

 
148,426

 
(155,300
)
Inventories
 
(70,448
)
 
(237,764
)
 
(1,247
)
Project assets
 
33,248

 
(763,065
)
 
(68,247
)
Prepaid expenses and other assets
 
48,758

 
(80,105
)
 
203,654

Long-term financing receivables, net
 
(172,542
)
 
(142,973
)
 
(94,314
)
Advances to suppliers
 
74,341

 
50,560

 
(26,343
)
Accounts payable and other accrued liabilities
 
(12,146
)
 
97,433

 
59,508

Billings in excess of costs and estimated earnings
 
(38,204
)
 
30,661

 
(225,210
)
Customer advances
 
(16,969
)
 
(20,830
)
 
(23,481
)
Net cash provided by (used in) operating activities
 
(312,283
)
 
(726,231
)
 
8,360

Cash flows from investing activities:
 
 
 
 
 
 
Increase in restricted cash and cash equivalents
 
(22,667
)
 
(23,174
)
 
(11,562
)
Purchases of property, plant and equipment
 
(187,094
)
 
(230,051
)
 
(102,505
)
Cash paid for solar power systems, leased and to be leased
 
(84,289
)
 
(88,376
)
 
(50,974
)
Cash paid for solar power systems
 
(38,746
)
 
(10,007
)
 
(13,457
)
Proceeds from sales or maturities of marketable securities
 
6,210

 

 
1,380

Proceeds from (payments to) 8point3 Energy Partners LP
 
(9,838
)
 
539,791

 

Purchases of marketable securities
 
(4,955
)
 

 
(30
)
Cash paid for acquisitions, net of cash acquired
 
(24,003
)
 
(64,756
)
 
(35,078
)
Cash paid for investments in unconsolidated investees
 
(11,547
)
 
(4,092
)
 
(97,013
)
Cash paid for intangibles
 
(521
)
 
(9,936
)
 

Net cash provided by (used in) investing activities
 
(377,450
)
 
109,399

 
(309,239
)
Cash flows from financing activities:
 
 
 
 
 
 
Proceeds from issuance of convertible debt, net of issuance costs
 

 
416,305

 
395,275

Cash paid for repurchase of convertible debt
 

 
(324,352
)
 
(42,250
)
Proceeds from settlement of 4.75% Bond Hedge
 

 

 
68,842

Payments to settle 4.75% Warrants
 

 

 
(81,077
)
Proceeds from settlement of 4.50% Bond Hedge
 

 
74,628

 
131

Payments to settle 4.50% Warrants
 

 
(574
)
 

Cash paid for acquisitions
 
(5,714
)
 



Proceeds from bank loans and other debt
 
113,645

 

 

Repayment of bank loans and other debt
 
(143,601
)
 
(16,088
)
 
(16,852
)
Proceeds from issuance of non-recourse residential financing, net of issuance costs
 
183,990

 
100,108

 
81,926

Repayment of non-recourse residential financing
 
(37,932
)
 
(41,503
)
 
(15,930
)
Contributions from noncontrolling interests and redeemable noncontrolling interests attributable to residential projects
 
146,334

 
180,881

 
100,683

Distributions to noncontrolling interests and redeemable noncontrolling interests attributable to residential projects
 
(19,039
)
 
(10,291
)
 
(5,093
)
Proceeds from issuance of non-recourse power plant and commercial financing, net of issuance costs
 
738,822

 
441,775

 
112,137

Assumption of project loan by customer
 

 

 
(40,672
)
Repayment of non-recourse power plant and commercial financing
 
(795,209
)
 
(238,744
)
 
(4,437
)
Proceeds from 8point3 Energy Partners LP attributable to operating leases and unguaranteed sales-type lease residual values
 

 
29,300

 

Contributions from noncontrolling interests attributable to real estate projects
 

 
12,410

 
 
Proceeds from exercise of stock options
 

 
517

 
1,052

Excess tax benefit from stock-based compensation
 

 
39,375

 
2,379

Purchases of stock for tax withholding obligations on vested restricted stock
 
(21,517
)
 
(43,780
)
 
(57,548
)
Net cash provided by financing activities
 
159,779

 
619,967

 
498,566

Effect of exchange rate changes on cash and cash equivalents
 
735

 
(4,782
)
 
(4,023
)
Net decrease in cash and cash equivalents
 
(529,219
)
 
(1,647
)
 
193,664

Cash and cash equivalents, beginning of period
 
954,528

 
956,175

 
762,511

Cash and cash equivalents, end of period
 
$
425,309

 
$
954,528

 
$
956,175

 
 
 
 
 
 
 
Non-cash transactions:
 
 
 
 
 
 
Assignment of residential lease receivables to third parties
 
$
4,290

 
$
3,315

 
$
8,023

Costs of solar power systems, leased and to be leased, sourced from existing inventory
 
$
57,422

 
$
66,604

 
$
41,204

Costs of solar power systems, leased and to be leased, funded by liabilities
 
$
3,026

 
$
10,972

 
$
3,786

Costs of solar power systems under sale-leaseback financing arrangements, sourced from project assets
 
$
27,971

 
$
6,076

 
$
28,259

Property, plant and equipment acquisitions funded by liabilities
 
$
43,817

 
$
28,950

 
$
11,461

Net reclassification of cash proceeds offset by project assets in connection with the deconsolidation of assets sold to the 8point3 Group
 
$
45,862

 
$
102,333

 
$

Issuance of common stock upon conversion of convertible debt
 
$

 
$

 
$
188,263

Exchange of receivables for an investment in an unconsolidated investee
 
$
2,890

 
$

 
$

Sale of residential lease portfolio in exchange for non-controlling equity interests in the 8point3 Group
 
$

 
$
68,273

 
$

Acquisition funded by liabilities
 
$
103,354

 
$

 
$

Supplemental cash flow information:
 
 
 
 
 
 
Cash paid for interest, net of amount capitalized
 
$
35,770

 
$
34,909

 
$
39,857

Cash paid for income taxes
 
$
35,414

 
$
29,509

 
$
8,765


The accompanying notes are an integral part of these consolidated financial statements.

94

Table of Contents


Note 1. THE COMPANY AND SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES

The Company
 
SunPower Corporation (together with its subsidiaries, the "Company" or "SunPower") is a leading global energy company that delivers complete solar solutions to residential, commercial, and power plant customers worldwide through an array of hardware, software, and financing options and through utility-scale solar power system construction and development capabilities, operations and maintenance ("O&M") services, and "Smart Energy" solutions. SunPower's Smart Energy initiative is designed to add layers of intelligent control to homes, buildings and grids—all personalized through easy-to-use customer interfaces. Of all the solar cells commercially available to the mass market, the Company believes its solar cells have the highest conversion efficiency, a measurement of the amount of sunlight converted by the solar cell into electricity. SunPower Corporation is a majority owned subsidiary of Total Energies Nouvelles Activités USA ("Total"), a subsidiary of Total S.A. ("Total S.A.") (see Note 2).
    
The Company's President and Chief Executive Officer, as the chief operating decision maker ("CODM"), has organized the Company, manages resource allocations and measures performance of the Company's activities among three end-customer segments: (i) Residential Segment, (ii) Commercial Segment and (iii) Power Plant Segment. The Residential and Commercial Segments combined are referred to as Distributed Generation.

The Company’s Residential Segment refers to sales of solar energy solutions to residential end customers through a variety of means, including cash sales and long-term leases directly to end customers, sales to resellers, including the Company's third-party global dealer network, and sales of the Company's O&M services.  The Company’s Commercial Segment refers to sales of solar energy solutions to commercial and public entity end customers through a variety of means, including direct sales of turn-key engineering, procurement and construction ("EPC") services, sales to the Company's third-party global dealer network, sales of energy under power purchase agreements ("PPAs"), and sales of the Company's O&M services. The Power Plant Segment refers to the Company's large-scale solar products and systems business, which includes power plant project development and project sales, EPC services for power plant construction, power plant O&M services and component sales for power plants developed by third parties, sometimes on a multi-year, firm commitment basis. 

Basis of Presentation and Preparation
    
Principles of Consolidation

The consolidated financial statements are prepared in accordance with accounting principles generally accepted in the United States of America ("United States" or "U.S.") and include the accounts of the Company, all of its subsidiaries and special purpose entities, as appropriate under consolidation accounting guidelines. Intercompany transactions and balances have been eliminated in consolidation. The assets of the special purpose entities that the Company establishes in connection with certain project financing arrangements for customers are not designed to be available to service the general liabilities and obligations of the Company.

Reclassifications

Certain prior period balances have been reclassified to conform to the current period presentation in the Company's consolidated financial statements and the accompanying notes. Such reclassifications had no effect on previously reported results of operations or accumulated deficit.

Fiscal Years

The Company has a 52-to-53-week fiscal year that ends on the Sunday closest to December 31. Accordingly, every fifth or sixth year will be a 53-week fiscal year. The current fiscal year, fiscal 2016, is a 52-week fiscal year, fiscal year 2015 was a 53-week fiscal year and had a 14-week fourth fiscal quarter, while fiscal year 2014 was a 52-week fiscal year. Fiscal 2016 ended on January 1, 2017, fiscal 2015 ended on January 3, 2016, and fiscal 2014 ended on December 28, 2014.

Management Estimates

The preparation of the consolidated financial statements in conformity with U.S. generally accepted accounting principles ("U.S. GAAP") requires management to make estimates and assumptions that affect the amounts reported in the consolidated financial statements and accompanying notes. Significant estimates in these consolidated financial statements include percentage-of-completion for construction projects; allowances for doubtful accounts receivable and sales returns;

95

Table of Contents


inventory and project asset write-downs; stock-based compensation; estimates for valuation assumptions including discount rates, future cash flows and economic useful lives of property, plant and equipment, goodwill, valuations for business combinations, other intangible assets, investments, and other long-term assets; the fair value and residual value of solar power systems; fair value of financial instruments; valuation of contingencies and certain accrued liabilities such as accrued warranty; and income taxes and tax valuation allowances and indemnities. Actual results could materially differ from those estimates.

Summary of Significant Accounting Policies

Fair Value of Financial Instruments

The fair value of a financial instrument is the price that would be received to sell an asset or paid to transfer a liability in an orderly transaction between market participants at the measurement date. The carrying values of cash and cash equivalents, accounts receivable, and accounts payable approximate their respective fair values due to their short-term maturities. Investments in available-for-sale securities are carried at fair value based on quoted market prices or estimated based on market conditions and risks existing at each balance sheet date. Derivative financial instruments are carried at fair value based on quoted market prices for financial instruments with similar characteristics. Unrealized gains and losses of the Company’s available-for-sale securities and the effective portion of derivative financial instruments are excluded from earnings and reported as a component of "Accumulated other comprehensive loss" in the Consolidated Balance Sheets. Additionally, the Company assesses whether an other-than-temporary impairment loss on its available-for-sale securities has occurred due to declines in fair value or other market conditions. Declines in fair value that are considered other-than-temporary and the ineffective portion of derivatives financial instruments are included in "Other, net" in the Consolidated Statements of Operations.

Comprehensive Income (Loss)

Comprehensive income (loss) is defined as the change in equity during a period from non-owner sources. The Company’s comprehensive income (loss) for each period presented is comprised of (i) the Company’s net income (loss); (ii) foreign currency translation adjustment of the Company’s foreign subsidiaries whose assets and liabilities are translated from their respective functional currencies at exchange rates in effect at the balance sheet date, and revenues and expenses are translated at average exchange rates prevailing during the applicable period; and (iii) changes in unrealized gains or losses, net of tax, for the effective portion of derivatives designated as cash flow hedges (see Note 12) and available-for-sale securities carried at their fair value.

Cash Equivalents

Highly liquid investments with original or remaining maturities of ninety days or less at the date of purchase are considered cash equivalents.

Cash in Restricted Accounts

The Company maintains cash and cash equivalents in restricted accounts pursuant to various letters of credit, surety bonds, loan agreements, and other agreements in the normal course of business. The Company also holds debt securities, consisting of Philippine government bonds, which are classified as "Restricted long-term marketable securities" on the Company's Consolidated Balance Sheets as they are maintained as collateral for present and future business transactions within the country (see Note 5).

Short-Term and Long-Term Investments

The Company invests in money market funds and debt securities. In general, investments with original maturities of greater than ninety days and remaining maturities of one year or less are classified as short-term investments, and investments with maturities of more than one year are classified as long-term investments. Investments with maturities beyond one year may be classified as short-term based on their highly liquid nature and because such investments represent the investment of cash that is available for current operations. Despite the long-term maturities, the Company has the ability and intent, if necessary, to liquidate any of these investments in order to meet the Company’s working capital needs within its normal operating cycles. The Company has classified these investments as available-for-sale securities.

Inventories


96

Table of Contents


Inventories are accounted for on a first-in-first-out basis and are valued at the lower of cost or net realizable value. The Company evaluates the realizability of its inventories, including purchase commitments under fixed-price long-term supply agreements, based on assumptions about expected demand and market conditions. The Company’s assumption of expected demand is developed based on its analysis of bookings, sales backlog, sales pipeline, market forecast, and competitive intelligence. The Company’s assumption of expected demand is compared to available inventory, production capacity, future polysilicon purchase commitments, available third-party inventory, and growth plans. The Company’s factory production plans, which drive materials requirement planning, are established based on its assumptions of expected demand. The Company responds to reductions in expected demand by temporarily reducing manufacturing output and adjusting expected valuation assumptions as necessary. In addition, expected demand by geography has changed historically due to changes in the availability and size of government mandates and economic incentives.

The Company evaluates the terms of its long-term inventory purchase agreements with suppliers, including joint ventures, for the procurement of polysilicon, ingots, wafers, and solar cells and establishes accruals for estimated losses on adverse purchase commitments as necessary, such as lower of cost or net realizable value adjustments, forfeiture of advanced deposits and liquidated damages. Obligations related to non-cancellable purchase orders for inventories match current and forecasted sales orders that will consume these ordered materials and actual consumption of these ordered materials are compared to expected demand regularly. The Company anticipates total obligations related to long-term supply agreements for inventories will be realized because quantities are less than management's expected demand for its solar power products for the foreseeable future and because the raw materials subject to these long-term supply agreements are not subject to spoilage or other factors that would deteriorate its usability; however, if raw materials inventory balances temporarily exceed near-term demand, the Company may elect to sell such inventory to third parties to optimize working capital needs. In addition, because the purchase prices required by the Company's long-term polysilicon agreements are significantly higher than current market prices for similar materials, if the Company is not able to profitably utilize this material in its operations or elect to sell near-term excess, the Company may incur additional losses. Other market conditions that could affect the realizable value of the Company's inventories and are periodically evaluated by management include historical inventory turnover ratio, anticipated sales price, new product development schedules, the effect new products might have on the sale of existing products, product obsolescence, customer concentrations, the current market price of polysilicon as compared to the price in the Company's fixed-price arrangements, and product merchantability, among other factors. If, based on assumptions about expected demand and market conditions, the Company determines that the cost of inventories exceeds its net realizable value or inventory is excess or obsolete, or the Company enters into arrangements with third parties for the sale of raw materials that do not allow it to recover its current contractually committed price for such raw materials, the Company records a write-down or accrual equal to the difference between the cost of inventories and the estimated net realizable value, which may be material. If actual market conditions are more favorable, the Company may have higher gross margin when products that have been previously written down are sold in the normal course of business (see Note 5).

Solar Power Systems Leased and to be Leased

Solar power systems leased to residential customers under operating leases are stated at cost, less accumulated depreciation and are amortized to their estimated residual value over the life of the lease term of up to 20 years.

Solar power systems to be leased represents systems that are under installation or which have not been interconnected, which will be depreciated as solar power systems leased to customers when the respective systems are completed, interconnected and subsequently leased to residential customers under operating leases.

Initial direct costs for operating leases are capitalized and amortized over the term of the related customer lease agreements.

Financing Receivables

Leases are classified as either operating or sales-type leases in accordance with the relevant accounting guidelines. Financing receivables are generated by solar power systems leased to residential customers under sales-type leases. Financing receivables represents gross minimum lease payments to be received from customers over a period commensurate with the remaining lease term of up to 20 years and the systems estimated residual value, net of unearned income and allowance for estimated losses. Initial direct costs for sales-type leases are recognized as cost of sales when the solar power systems are placed in service.

Due to the homogeneous nature of its leasing transactions, SunPower manages its financing receivables on an aggregate basis when assessing credit risk. SunPower also considers the credit risk profile for its lease customers to be homogeneous due to the criteria the Company uses to approve customers for its residential leasing program, which among other

97

Table of Contents


things, requires a minimum "fair" FICO credit quality. Accordingly, the Company does not regularly categorize its financing receivables by credit risk.

The Company recognizes an allowance for losses on financing receivables in an amount equal to the probable losses net of recoveries. SunPower maintains reserve percentages on past-due receivable aging buckets and bases such percentages on several factors, including consideration of historical credit losses and information derived from industry benchmarking. To date, the allowance for losses has not comprised a material portion of the Company’s financing receivables.

Property, Plant and Equipment

Property, plant and equipment are stated at cost, less accumulated depreciation. Depreciation, excluding solar power systems leased to residential customers and those associated with sale-leaseback transactions under the financing method, is computed using the straight-line method over the estimated useful lives of the assets as presented below. Solar power systems leased to residential customers and those associated with sale-leaseback transactions under the financing method are depreciated using the straight-line method to their estimated residual values over the lease terms of up to 20 years. Leasehold improvements are amortized over the shorter of the estimated useful lives of the assets or the remaining term of the lease. Repairs and maintenance costs are expensed as incurred.
 
Useful Lives
in Years
Buildings
20 to 30
Leasehold improvements
1 to 20
Manufacturing equipment
7 to 15
Computer equipment
2 to 7
Solar power systems
30
Furniture and fixtures
3 to 5

Interest Capitalization

The interest cost associated with major development and construction projects is capitalized and included in the cost of the property, plant and equipment or project assets. Interest capitalization ceases once a project is substantially complete or no longer undergoing construction activities to prepare it for its intended use. When no debt is specifically identified as being incurred in connection with a construction project, the Company capitalizes interest on amounts expended on the project at the Company’s weighted average cost of borrowed money.

Long-Lived Assets

The Company evaluates its long-lived assets, including property, plant and equipment, solar power systems leased and to be leased, and other intangible assets with finite lives, for impairment whenever events or changes in circumstances indicate that the carrying value of such assets may not be recoverable. Factors considered important that could result in an impairment review include significant under-performance relative to expected historical or projected future operating results, significant changes in the manner of use of acquired assets, and significant negative industry or economic trends. The Company's impairment evaluation of long-lived assets includes an analysis of estimated future undiscounted net cash flows expected to be generated by the assets over their remaining estimated useful lives. If the Company's estimate of future undiscounted net cash flows is insufficient to recover the carrying value of the assets over the remaining estimated useful lives, it records an impairment loss in the amount by which the carrying value of the assets exceeds the fair value. Fair value is generally measured based on either quoted market prices, if available, or discounted cash flow analysis.

Project Assets - Plant and Land

Project assets consist primarily of capitalized costs relating to solar power system projects in various stages of development that the Company incurs prior to the sale of the solar power system to a third-party. These costs include costs for land and costs for developing and constructing a solar power system. Development costs can include legal, consulting, permitting, and other similar costs. Once the Company enters into a definitive sales agreement, it reclassifies these project asset costs to deferred project costs within "Prepaid expenses and other current assets" in its Consolidated Balance Sheet until the Company has met the criteria to recognize the sale of the project asset or solar power project as revenue. The Company releases

98

Table of Contents


these project costs to cost of revenue as each respective project asset or solar power system is sold to a customer, since the project is constructed for a customer (matching the underlying revenue recognition method).

The Company evaluates the realizability of project assets whenever events or changes in circumstances indicate that the carrying amount may not be recoverable. The Company considers the project to be recoverable if it is anticipated to be sellable for a profit once it is either fully developed or fully constructed or if costs incurred to date may be recovered via other means, such as a sale prior to the completion of the development cycle. The Company examines a number of factors to determine if the project will be profitable, including whether there are any environmental, ecological, permitting, or regulatory conditions that have changed for the project since the start of development. In addition, the company must anticipate market conditions, such as the future cost of energy and changes in the factors that its future customers use to value its project assets in sale arrangements, including the internal rate of return that customers expect. Changes in such conditions could cause the cost of the project to increase or the selling price of the project to decrease. Due to the development, construction, and sale timeframe of the Company's larger solar projects, it classifies project assets which are not expected to be sold within the next 12 months as "Project assets - plants and land, net of current portion" on the Consolidated Balance Sheets. Once specific milestones have been achieved, the Company determines if the sale of the project assets will occur within the next 12 months from a given balance sheet date and, if so, it then reclassifies the project assets as current.

Product Warranties

The Company generally provides a 25-year standard warranty for the solar panels that it manufactures for defects in materials and workmanship. The warranty provides that the Company will repair or replace any defective solar panels during the warranty period. In addition, the Company passes through to customers long-term warranties from the original equipment manufacturers of certain system components, such as inverters. Warranties of 25 years from solar panel suppliers are standard in the solar industry, while certain system components carry warranty periods ranging from five to 20 years.

In addition, the Company generally warrants its workmanship on installed systems for periods ranging up to 25 years and also provides a separate system output performance warranty to customers that have subscribed to the Company’s post-installation monitoring and maintenance services which expires upon termination of the post-installation monitoring and maintenance services related to the system. The warrantied system output performance level varies by system depending on the characteristics of the system and the negotiated agreement with the customer, and the level declines over time to account for the expected degradation of the system. Actual system output is typically measured annually for purposes of determining whether warrantied performance levels have been met. The warranty excludes system output shortfalls attributable to force majeure events, customer curtailment, irregular weather, and other similar factors. In the event that the system output falls below the warrantied performance level during the applicable warranty period, and provided that the shortfall is not caused by a factor that is excluded from the performance warranty, the warranty provides that the Company will pay the customer a liquidated damage based on the value of the shortfall of energy produced relative to the applicable warrantied performance level.

The Company maintains reserves to cover the expected costs that could result from these warranties. The Company’s expected costs are generally in the form of product replacement or repair. Warranty reserves are based on the Company’s best estimate of such costs and are recognized as a cost of revenue. The Company continuously monitors product returns for warranty failures and maintains a reserve for the related warranty expenses based on various factors including historical warranty claims, results of accelerated lab testing, field monitoring, vendor reliability estimates, and data on industry averages for similar products. Due to the potential for variability in these underlying factors, the difference between the Company’s estimated costs and its actual costs could be material to the Company’s consolidated financial statements. If actual product failure rates or the frequency or severity of reported claims differ from the Company’s estimates or if there are delays in the Company’s responsiveness to outages, the Company may be required to revise its estimated warranty liability. Historically, warranty costs have been within management’s expectations (see Note 9).

Revenue Recognition

Solar Power Components

The Company sells its solar panels and balance of system components primarily to dealers, system integrators and distributors, and recognizes revenue, net of accruals for estimated sales returns, when persuasive evidence of an arrangement exists, delivery of the product has occurred, title and risk of loss has passed to the customer, the sales price is fixed or determinable, collectability of the resulting receivable is reasonably assured, and the risks and rewards of ownership have passed to the customer. Other than standard warranty obligations, there are no rights of return and there are no significant post-shipment obligations, including installation, training or customer acceptance clauses with any of the Company's customers that

99

Table of Contents


could have an impact on revenue recognition. The Company's revenue recognition policy is consistent across all geographic areas.
The provision for estimated sales returns on product sales is recorded in the same period the related revenues are recorded. These estimates are based on historical sales returns, analysis of credit memo data, and other known factors. Actual returns could differ from these estimates.

Construction Contracts

Revenue is also composed of EPC projects which are governed by customer contracts that require the Company to deliver functioning solar power systems and are generally completed within three to twelve months from commencement of construction. Construction on large projects may be completed within eighteen to thirty-six months, depending on the size and location. The Company recognizes revenue from fixed price construction contracts, which do not include land or land rights, using the percentage-of-completion method of accounting. Under this method, revenue arising from fixed-price construction contracts is recognized as work is performed based on the percentage of incurred costs to estimated total forecasted costs.

Incurred costs used in the Company’s percentage-of-completion calculation include all direct material, labor and subcontract costs, and those indirect costs related to contract performance, such as indirect labor, supplies, and tools. Project material costs are included in incurred costs when the project materials have been installed by being permanently attached or fitted to the solar power system as required by the project’s engineering design.

In addition to an EPC deliverable, many arrangements also include multiple deliverables such as post-installation systems monitoring and maintenance. For contracts with separately priced monitoring and maintenance, the Company recognizes revenue related to such separately priced elements over the contract period. For contracts including monitoring and maintenance not separately priced, the Company determined that post-installation systems monitoring and maintenance qualify as separate units of accounting. Such post-installation monitoring and maintenance are deferred at the time the contract is executed based on the best estimate of selling price on a standalone basis and are recognized to revenue over the contractual term. The remaining EPC revenue is recognized on a percentage-of-completion basis.

In addition, when arrangements include contingent revenue clauses, such as customer termination or put rights for non-performance, the Company defers the contingent revenue if there is a reasonable possibility that such rights or contingencies may be triggered. In certain limited cases, the Company could be required to buy back a customer’s system at fair value on specified future dates if certain minimum performance thresholds are not met for periods of up to two years. To date, no such repurchase obligations have been required.

Provisions for estimated losses on uncompleted contracts, if any, are recognized in the period in which the loss first becomes probable and reasonably estimable. Contracts may include profit incentives such as milestone bonuses. These profit incentives are included in the contract value when their realization is reasonably assured.

Development Projects

The Company develops and sells solar power plants which generally include the sale or lease of related real estate. Revenue recognition for these solar power plants require adherence to specific guidance for real estate sales, which provides that if the Company executes a sale of land in conjunction with an EPC contract requiring the future development of the property, it recognizes revenue and the corresponding costs under the full accrual method when all of the following requirements are met: the sale is consummated, the buyer's initial and any continuing investments are adequate, the resulting receivables are not subject to subordination, the future costs to develop the property can be reasonably estimated, it has transferred the customary risk and rewards of ownership to the buyer, and it does not have prohibited continuing involvement with the property or the buyer. In general, a sale is consummated upon the execution of an agreement documenting the terms of the sale and receipt of a minimum initial payment by the buyer to substantiate the transfer of risk to the buyer. Depending on the value of the initial and continuing investment of the buyer, and provided the recovery of the costs of the solar power plant are assured if the buyer defaults, it may defer revenue and profit during construction by aligning its revenue recognition and release of deferred project costs to cost of sales with the receipt of payment from the buyer. At the time the Company has unconditionally received payment from the buyer, revenue is recognized and deferred project costs are released to cost of sales at the same rate of profit estimated throughout the construction of the project. Further, in situations where we have a noncontrolling equity interest in the buyer, we may defer all or a portion of our revenue or profit in accordance with specific guidance for partial sales of real estate.


100

Table of Contents


The Company has determined that its standard product and workmanship warranties do not represent prohibited forms of continuing involvement that would otherwise preclude revenue recognition as these warranties do not result in the retention of substantial risks or rewards of ownership or result in a seller guarantee as described in real estate accounting guidance. Similarly, the Company has determined that when it provides post-installation monitoring and maintenance services and associated system output performance warranties to customers of projects that include the sale or lease of real estate, these are not forms of prohibited continuing involvement since the terms and conditions of the post-installation monitoring and maintenance services are commensurate with market rates, control over the right to terminate the post-installation monitoring and maintenance contract and associated system output performance warranties rests with the customer since the customer has the right to terminate for convenience, and the terms and conditions for the system output performance warranties do not result in any additional services or efforts by the Company or in the retention of ownership risks outside of the Company’s control.

Residential Leases

The Company offers a solar lease program, in partnership with third-party financial institutions, which allows its residential customers to obtain SunPower systems under lease agreements for terms of up to 20 years. Leases are classified as either operating or sales-type leases in accordance with the relevant accounting guidelines.

For those systems classified as sales-type leases, the net present value of the minimum lease payments, net of executory costs, is recognized as revenue when the lease is placed in service. This net present value as well as the net present value of the residual value of the lease at termination are recorded as financing receivables in the Consolidated Balance Sheets. The difference between the initial net amounts and the gross amounts are amortized to revenue over the lease term using the interest method. The residual values of our solar systems are determined at the inception of the lease applying an estimated system fair value at the end of the lease term.

For those systems classified as operating leases, rental revenue is recognized, net of executory costs, on a straight-line basis over the term of the lease.

Shipping and Handling Costs

The Company records costs related to shipping and handling in cost of revenue.

Stock-Based Compensation
    
The Company measures and records compensation expense for all stock-based payment awards based on estimated fair values. The Company provides stock-based awards to its employees, executive officers, and directors through various equity compensation plans including its employee stock option and restricted stock plans. The fair value of restricted stock units is based on the market price of the Company's common stock on the date of grant. The Company has not granted stock options since fiscal 2008.

The Company estimates forfeitures at the date of grant. The Company's estimate of forfeitures is based on its historical activity, which it believes is indicative of expected forfeitures. In subsequent periods if the actual rate of forfeitures differs from the Company's estimate, the forfeiture rates are required to be revised, as necessary. Changes in the estimated forfeiture rates can have a significant effect on stock-based compensation expense since the effect of adjusting the rate is recognized in the period the forfeiture estimate is changed.

The Company also grants performance share units to executive officers and certain employees that require it to estimate expected achievement of performance targets over the performance period. This estimate involves judgment regarding future expectations of various financial performance measures. If there are changes in the Company's estimate of the level of financial performance measures expected to be achieved, the related stock-based compensation expense may be significantly increased or reduced in the period that its estimate changes.

Advertising Costs

Advertising costs are expensed as incurred. Advertising expense totaled approximately $24.9 million, $23.4 million and $11.9 million, in fiscal 2016, 2015, and 2014, respectively.

Research and Development Expense


101

Table of Contents


Research and development expense consists primarily of salaries and related personnel costs, depreciation and the cost of solar cell and solar panel materials and services used for the development of products, including experiments and testing. All research and development costs are expensed as incurred. Research and development expense is reported net of contributions under the R&D Agreement with Total and contracts with governmental agencies because such contracts are considered collaborative arrangements.

Translation of Foreign Currency

The Company and certain of its subsidiaries use their respective local currency as their functional currency. Accordingly, foreign currency assets and liabilities are translated using exchange rates in effect at the end of the period. Aggregate exchange gains and losses arising from the translation of foreign assets and liabilities are included in “Accumulated other comprehensive loss” in the Consolidated Balance Sheets. Foreign subsidiaries that use the U.S. dollar as their functional currency remeasure monetary assets and liabilities using exchange rates in effect at the end of the period. Exchange gains and losses arising from the remeasurement of monetary assets and liabilities are included in "Other, net" in the Consolidated Statements of Operations. Non-monetary assets and liabilities are carried at their historical values.

The Company includes gains or losses from foreign currency transactions in "Other, net" in the Consolidated Statements of Operations with the other hedging activities described in Note 12.

Concentration of Credit Risk

The Company is exposed to credit losses in the event of nonperformance by the counterparties to its financial and derivative instruments. Financial and derivative instruments that potentially subject the Company to concentrations of credit risk are primarily cash and cash equivalents, restricted cash and cash equivalents, investments, accounts receivable, notes receivable, advances to suppliers, foreign currency option contracts, foreign currency forward contracts, bond hedge and warrant transactions, and purchased options. The Company’s investment policy requires cash and cash equivalents, restricted cash and cash equivalents, and investments to be placed with high-quality financial institutions and to limit the amount of credit risk from any one issuer. Similarly, the Company enters into foreign currency derivative contracts and convertible debenture hedge transactions with high-quality financial institutions and limits the amount of credit exposure to any one counterparty. The foreign currency derivative contracts are limited to a time period of less than 15 months, while the bond hedge and warrant transactions expired in fiscal 2015. The Company regularly evaluates the credit standing of its counterparty financial institutions.

The Company performs ongoing credit evaluations of its customers’ financial condition whenever deemed necessary and generally does not require collateral. The Company maintains an allowance for doubtful accounts based on the expected collectability of all accounts receivable, which takes into consideration an analysis of historical bad debts, specific customer creditworthiness and current economic trends. Qualified customers under our residential lease program are generally required to have a minimum credit score. We believe that our concentration of credit risk is limited because of our large number of customers, credit quality of the customer base, small account balances for most of these customers, and customer geographic diversification. As of January 1, 2017 and January 3, 2016 the Company had no customers that accounted for 10% of accounts receivable. In addition, one customer accounted for approximately 10% of the Company's "Costs and estimated earnings in excess of billings" balance as of January 1, 2017 on the Consolidated Balance Sheets as compared to one customer that accounted for approximately 59% of the balance as of January 3, 2016.

The Company has entered into agreements with vendors that specify future quantities and pricing of polysilicon to be supplied for remaining periods of four years. The purchase prices required by these polysilicon supply agreements are significantly higher than current market prices for similar materials. Under certain agreements, the Company was required to make prepayments to the vendors over the terms of the arrangements.

Income Taxes

Deferred tax assets and liabilities are recognized for temporary differences between financial statement and income tax bases of assets and liabilities. Valuation allowances are provided against deferred tax assets when management cannot conclude that it is more likely than not that some portion or all deferred tax assets will be realized.

As applicable, interest and penalties on tax contingencies are included in "Provision for income taxes" in the Consolidated Statements of Operations and such amounts were not material for any periods presented. In addition, foreign exchange gains (losses) may result from estimated tax liabilities, which are expected to be settled in currencies other than the U.S. dollar.

102

Table of Contents



Investments in Equity Interests

Investments in entities in which the Company can exercise significant influence, but does not own a majority equity interest or otherwise control, are accounted for under the equity method. The Company records its share of the results of these entities as "Equity in earnings of unconsolidated investees" on the Consolidated Statements of Operations. The Company monitors its investments for other-than-temporary impairment by considering factors such as current economic and market conditions and the operating performance of the entities and records reductions in carrying values when necessary. The fair value of privately held investments is estimated using the best available information as of the valuation date, including current earnings trends, undiscounted cash flows, and other company specific information, including recent financing rounds (see Notes 5 and 7).

Noncontrolling Interests

Noncontrolling interests represents the portion of net assets in consolidated subsidiaries that are not attributable, directly or indirectly, to the Company. Beginning in the first quarter of fiscal 2013, the Company has entered into facilities with third-party investors under which the investors are determined to hold noncontrolling interests in entities fully consolidated by the Company. The net assets of the shared entities are attributed to the controlling and noncontrolling interests based on the terms of the governing contractual arrangements. The Company further determined the hypothetical liquidation at book value method ("HLBV Method") to be the appropriate method for attributing net assets to the controlling and noncontrolling interests as this method most closely mirrors the economics of the governing contractual arrangements. Under the HLBV Method, the Company allocates recorded income (loss) to each investor based on the change, during the reporting period, of the amount of net assets each investor is entitled to under the governing contractual arrangements in a liquidation scenario.

Business Combinations

The Company records all acquired assets and liabilities, including goodwill, other intangible assets, and in-process research and development, at fair value. The initial recording of goodwill, other intangible assets, and in-process research and development requires certain estimates and assumptions concerning the determination of the fair values and useful lives. The judgments made in the context of the purchase price allocation can materially impact the Company's future results of operations. Accordingly, for significant acquisitions, the Company obtains assistance from third-party valuation specialists. The valuations calculated from estimates are based on information available at the acquisition date (see Notes 3 and 4). The Company charges acquisition related costs that are not part of the consideration to general and administrative expense as they are incurred. These costs typically include transaction and integration costs, such as legal, accounting, and other professional fees.

The Company initially records receipts of net assets or equity interests between entities under common control at their carrying amounts in the accounts of the transferring entity. Financial statements and financial information presented for prior years are retrospectively adjusted to effect the transfer as of the first date for which the entities were under common control. If the carrying amounts of the assets and liabilities transferred differ from the historical cost of the parent of the entities under common control then amounts recognized in the Company's financial statements reflect the transferred assets and liabilities at the historical cost of the parent of the entities under common control. Financial statements and financial information presented for prior years are also retrospectively adjusted to furnish comparative information as though the assets and liabilities had been transferred at that date.

Recent Accounting Pronouncements

In January 2017, the Financial Accounting Standards Board (“FASB”) issued an update to the standards to simplify the subsequent measurement of goodwill by removing the second step of the two-step impairment test. The new guidance is effective for the Company no later than the first quarter of fiscal 2020 and requires a prospective approach to adoption. Early adoption is permitted. The Company is evaluating the potential impact of this standard on its consolidated financial statements and disclosures.

In January 2017, the FASB issued an update to the standards to clarify the definition of a business to assist entities with evaluating whether transactions should be accounted for as acquisitions (or disposals) of assets or businesses. The new guidance is effective for the Company no later than the first quarter of fiscal 2018 and requires a prospective approach to adoption. Early adoption is permitted. The Company is evaluating the potential impact of this standard on its consolidated financial statements and disclosures.


103

Table of Contents


In November 2016, the FASB issued an update to the standards to require management to present their Statement of Cash Flows including amounts generally described as restricted cash or restricted cash equivalents with cash and cash equivalents when reconciling the beginning-of-period and end-of-period total amounts shown on the Statement of Cash Flows. The new guidance is effective for the Company no later than the first quarter of fiscal 2018 and requires a retrospective approach to adoption. Early adoption is permitted. The Company is evaluating the potential impact of this standard on its consolidated financial statements and disclosures.

In October 2016, the FASB issued an update to the standards to amend how a reporting entity considers indirect interests held by related parties under common control when evaluating whether it is the primary beneficiary of a VIE. The new guidance is effective for the Company no later than the first quarter of fiscal 2017 and requires a retrospective approach to adoption. Early adoption is permitted. The Company is evaluating the potential impact of this standard on its consolidated financial statements and disclosures.

In October 2016, the FASB issued an update to the standards to require entities to recognize the income tax consequences of an intra-entity transfer of an asset other than inventory when the transfer occurs. The new guidance is effective for the Company no later than the first quarter of fiscal 2018. Early adoption is permitted beginning in the first quarter of fiscal 2017 and requires a modified retrospective approach to adoption. The Company is evaluating the potential impact of this standard on its consolidated financial statements and disclosures.

In August 2016, the FASB issued an update to the standards to reduce diversity in practice in how certain transactions are presented and classified in the statement of cash flows. The new guidance is effective for the Company no later than the first quarter of fiscal 2018. Early adoption is permitted. The Company is evaluating the potential impact of this standard on its consolidated financial statements and disclosures.

In June 2016, the FASB issued an update to the standards to amend the methodology for measuring credit losses on financial instruments and the timing of when such losses are recorded. The new guidance is effective for the Company no later than the first quarter of fiscal 2020. Early adoption is permitted beginning in the first quarter of fiscal 2019. The Company is evaluating the potential impact of this standard on its consolidated financial statements and disclosures.

In March 2016, the FASB issued an update to the standards to simplify the accounting for employee share-based payment transactions, including the income tax consequences, classification of awards as either equity or liabilities, and classification on the statement of cash flows. The new guidance is effective for the Company no later than the first quarter of fiscal 2017. Early adoption is permitted. The Company is evaluating the potential impact of this standard on its consolidated financial statements and disclosures.

In February 2016, the FASB issued an update to the standards to require lessees to recognize a lease liability and a right-of-use asset for all leases (lease terms of more than 12 months) at the commencement date. The new guidance is effective for the Company no later than the first quarter of fiscal 2019 and requires a modified retrospective approach to adoption.  Early adoption is permitted.  The Company is evaluating the potential impact of this standard on its consolidated financial statements and disclosures.

In January 2016, the FASB issued an update to the standards to require equity investments to be measured at fair value with changes in the fair value recognized through net income (other than those accounted for under the equity method of accounting or those that result in consolidation of the investee). The new guidance is effective for the Company no later than the first quarter of fiscal 2018 and upon adoption, an entity should apply the amendments by means of a cumulative-effect adjustment to the balance sheet at the beginning of the first reporting period in which the guidance is effective. Early adoption is permitted for the accounting guidance on financial liabilities under the fair value option. The Company is evaluating the potential impact of this standard on its consolidated financial statements and disclosures.

In July 2015, the FASB issued an update to the standards to simplify the measurement of inventory.  The updated standard more closely aligns the measurement of inventory with that of International Financial Reporting Standards (“IFRS”) and amends the measurement standard from lower of cost or market to lower of cost or net realizable value.  The new guidance is effective for the Company no later than the first quarter of fiscal 2017 and requires a prospective approach to adoption.  The Company elected early adoption of the updated accounting standard, effective in the second quarter of fiscal 2016. The adoption of this updated accounting standard did not result in a significant impact to the Company’s consolidated financial statements.

In February 2015, the FASB issued a new standard that modifies existing consolidation guidance for reporting organizations that are required to evaluate whether they should consolidate certain legal entities. The Company adopted the

104

Table of Contents


new accounting standard, effective in the first quarter of fiscal 2016. Adoption of the new accounting standard did not have a material impact to the Company's consolidated financial statements.

In August 2014, the FASB issued an update to the standards to require management to evaluate whether there are conditions and events that raise substantial doubt about the Company’s ability to continue as a going concern within one year after the date the financial statements are issued, and to provide related disclosures. The Company adopted the new accounting standard, effective in the fourth quarter of fiscal 2016. The Company concluded that its current cash, cash equivalents, cash expected to be generated from operations and funds available under existing credit facilities will be sufficient to meet working capital needs and fund committed capital expenditures for the period required to be evaluated. While the Company believes its assumptions inherent in this conclusion are reasonable, the Company also believes that it has viable additional options available to support short-term liquidity needs if necessary. Adoption of the new accounting standard did not have a material impact to the Company's consolidated financial statements, however may increase the disclosure requirements regarding the Company’s evaluation of going concern.

In May 2014, the FASB issued a new revenue recognition standard based on the principle that revenue is recognized to depict the transfer of goods or services to customers in an amount that reflects the consideration to which the entity expects to be entitled in exchange for those goods and services.  The FASB has issued several updates to the standard which i) clarify the application of the principal versus agent guidance; ii) clarify the guidance relating to performance obligations and licensing; and iii) clarify assessment of the collectability criterion, presentation of sales taxes, measurement date for non-cash consideration and completed contracts at transaction; and iv) clarify narrow aspects of ASC 606 or corrects unintended application of the guidance. The new revenue recognition standard, amended by the updates, becomes effective for the Company in the first quarter of fiscal 2018 and is to be applied retrospectively using one of two prescribed methods. Early adoption is permitted. The Company currently plans to adopt effective January 1, 2018 using the full retrospective approach; however, a final decision regarding the adoption method has not been made at this time. The Company’s final determination will depend on a number of factors such as the process of finalizing the impact to the Company’s financial results and from additional disclosure requirements.

The Company has made significant progress with its evaluation of the impact of the new standard on its accounting policies, processes, and with updating its systems to fulfill the accounting and disclosure requirements under the new standard. The Company has assigned sufficient internal resources and also retained a third party service provider to assist with its implementation.

The Company expects the adoption of ASC 606 to primarily affect our Power Plants and Commercial segments.  Sales of solar power systems that include the sale or lease of related real estate, which occur under both segments, are currently accounted for under ASC 360-20. ASC 360-20 requires us to evaluate whether such arrangements have any forms of continuing involvement that may affect the revenue or profit recognition of the transactions, including arrangements with prohibited forms of continuing involvement requiring us to reduce the potential profit on a project sale by our maximum exposure to loss.  We anticipate that ASC 606, which supersedes the real estate sales guidance under ASC 360-20, will result in the earlier recognition of revenue and profit. In addition, the Company’s investment in the 8point3 Group currently has a negative carrying value of $60.6 million primarily as a result of profit deferred under ASC 360-20. Under ASC 606, the Company expects that a material amount of this deferred profit will have been recognized prior to January 1, 2018, and as a result the Company’s carrying value in the 8point3 Group will materially increase upon adoption. The Company expects that revenue recognition for our other sales arrangements, including the sales of components, sales and construction of solar systems, and operations and maintenance services, will remain materially consistent.

The Company continues to assess the potential impacts of the new standard, including the areas described above, and anticipates that this standard will have a material impact on its consolidated financial statements. However, the Company does not know or cannot reasonably estimate quantitative information, beyond that discussed above, related to the impact of the new standard on the financial statements at this time.

Other than as described above, there has been no issued accounting guidance not yet adopted by the Company that it believes is material or potentially material to its consolidated financial statements.

Note 2. TRANSACTIONS WITH TOTAL AND TOTAL S.A.

In June 2011, Total completed a cash tender offer to acquire 60% of the Company's then outstanding shares of common stock at a price of $23.25 per share, for a total cost of approximately $1.4 billion. In December 2011, the Company entered into a Private Placement Agreement with Total, under which Total purchased, and the Company issued and sold, 18.6 million shares of the Company's common stock for a purchase price of $8.80 per share, thereby increasing Total's ownership to

105

Table of Contents


approximately 66% of the Company's outstanding common stock as of that date. As of January 1, 2017, through the increase of the Company's total outstanding common stock due to the exercise of warrants and issuance of restricted and performance stock units, Total's ownership of the Company's outstanding common stock has decreased to approximately 57%.

Amended and Restated Credit Support Agreement

In June 2016, the Company and Total S.A. entered into an Amended and Restated Credit Support Agreement (the "Credit Support Agreement") which amended and restated the Credit Support Agreement dated April 28, 2011 by and between the Company and Total S.A., as amended. Under the Credit Support Agreement, Total S.A. agreed to enter into one or more guarantee agreements (each a "Guaranty") with banks providing letter of credit facilities to the Company. At any time until December 31, 2018, Total S.A. will, at the Company's request, guarantee the payment to the applicable issuing bank of the Company's obligation to reimburse a draw on a letter of credit and pay interest thereon in accordance with the letter of credit facility between such bank and the Company. Such letters of credit must be issued no later than December 31, 2018 and expire no later than March 31, 2020. Total is required to issue and enter into a Guaranty requested by the Company, subject to certain terms and conditions. In addition, Total will not be required to enter into the Guaranty if, after giving effect to the Company’s request for a Guaranty, the sum of (a) the aggregate amount available to be drawn under all guaranteed letter of credit facilities, (b) the amount of letters of credit available to be issued under any guaranteed facility, and (c) the aggregate amount of draws (including accrued but unpaid interest) on any letters of credit issued under any guaranteed facility that have not yet been reimbursed by the Company, would exceed $500 million in the aggregate. Such maximum amounts of credit support available to the Company can be reduced upon the occurrence of specified events.

In consideration for the commitments of Total S.A. pursuant to the Credit Support Agreement, the Company is required to pay Total S.A. a guaranty fee for each letter of credit that is the subject of a Guaranty under the Credit Support Agreement and was outstanding for all or part of the preceding calendar quarter. The Credit Support Agreement will terminate following December 31, 2018, after the later of the satisfaction of all obligations thereunder and the termination or expiration of each Guaranty provided thereunder.

Affiliation Agreement

The Company and Total have entered into an Affiliation Agreement that governs the relationship between Total and the Company (the "Affiliation Agreement"). Until the expiration of a standstill period specified in the Affiliation Agreement (the "Standstill Period"), and subject to certain exceptions, Total, Total S.A., any of their respective affiliates and certain other related parties (collectively the "Total Group") may not effect, seek, or enter into discussions with any third-party regarding any transaction that would result in the Total Group beneficially owning shares of the Company in excess of certain thresholds, or request the Company or the Company's independent directors, officers or employees, to amend or waive any of the standstill restrictions applicable to the Total Group.

The Affiliation Agreement imposes certain limitations on the Total Group's ability to seek to effect a tender offer or merger to acquire 100% of the outstanding voting power of the Company and imposes certain limitations on the Total Group's ability to transfer 40% or more of the outstanding shares or voting power of the Company to a single person or group that is not a direct or indirect subsidiary of Total S.A. During the Standstill Period, no member of the Total Group may, among other things, solicit proxies or become a participant in an election contest relating to the election of directors to the Company's Board of Directors.

The Affiliation Agreement provides Total with the right to maintain its percentage ownership in connection with any new securities issued by the Company, and Total may also purchase shares on the open market or in private transactions with disinterested stockholders, subject in each case to certain restrictions.

The Affiliation Agreement also imposes certain restrictions with respect to the Company's and its Board of Directors' ability to take certain actions, including specifying certain actions that require approval by the directors other than the directors appointed by Total and other actions that require stockholder approval by Total.

Research & Collaboration Agreement

Total and the Company have entered into a Research & Collaboration Agreement (the "R&D Agreement") that establishes a framework under which the parties engage in long-term research and development collaboration ("R&D Collaboration"). The R&D Collaboration encompasses a number of different projects, with a focus on advancing the Company's technology position in the crystalline silicon domain, as well as ensuring the Company's industrial competitiveness. The R&D Agreement enables a joint committee to identify, plan and manage the R&D Collaboration.

106

Table of Contents



Upfront Warrant

In February 2012, the Company issued a warrant (the "Upfront Warrant") to Total S.A. to purchase 9,531,677 shares of the Company's common stock with an exercise price of $7.8685, subject to adjustment for customary anti-dilution and other events. The Upfront Warrant, which is governed by the Private Placement Agreement and a Compensation and Funding Agreement entered into in February 2012, is exercisable at any time for seven years after its issuance, provided that, so long as at least $25.0 million in aggregate of the Company's convertible debt remains outstanding, such exercise will not cause any "person," including Total S.A., to, directly or indirectly, including through one or more wholly-owned subsidiaries, become the "beneficial owner" (as such terms are defined in Rule 13d-3 and Rule 13d-5 under the Securities Exchange Act of 1934, as amended), of more than 74.99% of the voting power of the Company's common stock at such time, a circumstance which would trigger the repurchase or conversion of the Company's existing convertible debt.

0.75% Debentures Due 2018

In May 2013, the Company issued $300.0 million in principal amount of its 0.75% senior convertible debentures due 2018 (the "0.75% debentures due 2018"). $200.0 million in aggregate principal amount of the 0.75% debentures due 2018 were acquired by Total. The 0.75% debentures due 2018 are convertible into shares of the Company's common stock at any time based on an initial conversion price equal to $24.95 per share, which provides Total the right to acquire up to 8,017,420 shares of the Company's common stock. The applicable conversion rate may adjust in certain circumstances, including a fundamental change, as described in the indenture governing the 0.75% debentures due 2018.

0.875% Debentures Due 2021

In June 2014, the Company issued $400.0 million in principal amount of its 0.875% senior convertible debentures due 2021 (the "0.875% debentures due 2021"). An aggregate principal amount of $250.0 million of the 0.875% debentures due 2021 were acquired by Total. The 0.875% debentures due 2021 are convertible into shares of the Company's common stock at any time based on an initial conversion price equal to $48.76 per share, which provides Total the right to acquire up to 5,126,775 shares of the Company's common stock. The applicable conversion rate may adjust in certain circumstances, including a fundamental change, as described in the indenture governing the 0.875% debentures due 2021.

4.00% Debentures Due 2023

In December 2015, the Company issued $425.0 million in principal amount of its 4.00% senior convertible debentures due 2023 (the "4.00% debentures due 2023"). An aggregate principal amount of $100.0 million of the 4.00% debentures due 2023 were acquired by Total. The 4.00% debentures due 2023 are convertible into shares of the Company's common stock at any time based on an initial conversion price equal to $30.53 per share, which provides Total the right to acquire up to 3,275,680 shares of the Company's common stock. The applicable conversion rate may adjust in certain circumstances, including a fundamental change, as described in the indenture governing the 4.00% debentures due 2023.

Joint Projects with Total and its Affiliates:

The Company enters into various EPC and O&M agreements relating to solar projects, including EPC and O&M services agreements relating to projects owned or partially owned by Total and its affiliates. As of January 1, 2017, the Company had $2.0 million of "Costs and estimated earnings in excess of billings" on its Consolidated Balance Sheets related to projects in which Total and its affiliates have a direct or indirect material interest.

During fiscal 2016, in connection with a co-development project between SunPower and Total, the Company made a $7.0 million payment to Total in exchange for Total's ownership interest in the co-development project.

Related-Party Transactions with Total and its Affiliates:

107

Table of Contents


 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Revenue:
 
 
 
 
 
 
EPC, O&M, and components revenue under joint projects
 
$
64,719

 
$
56,772

 
$
155,568

Research and development expense:
 
 
 
 
 
 
Offsetting contributions received under the R&D Agreement
 
$
(557
)
 
$
(1,620
)
 
$
(1,612
)
Interest expense:
 
 
 
 
 
 
Guarantee fees incurred under the Credit Support Agreement
 
$
7,130

 
$
11,227

 
$
12,035

Fees incurred under the Compensation and Funding Agreement
 
$

 
$

 
$
1,200

Interest expense incurred on the 0.75% debentures due 2018
 
$
1,500

 
$
1,500

 
$
1,604

Interest expense incurred on the 0.875% debentures due 2021
 
$
2,188

 
$
2,188

 
$
1,209

Interest expense incurred on the 4.00% debentures due 2023
 
$
4,000

 
$
167

 
$


Note 3. BUSINESS COMBINATIONS

AUOSP

On September 29, 2016, the Company completed the acquisition of AUO SunPower Sdn. Bhd. (“AUOSP”) pursuant to a Stock Purchase Agreement (the “Stock Purchase Agreement”) entered into between SunPower Technology, Ltd. (“SPTL”), a wholly-owned subsidiary of the Company, and AU Optronics Singapore Pte. Ltd. (“AUO”). AUOSP was a joint venture of SPTL and AUO for the purpose of manufacturing solar cells. Prior to the acquisition, SPTL and AUO each owned 50% of the shares of AUOSP. Pursuant to the Stock Purchase Agreement, SPTL purchased all of the shares of AUOSP held by AUO for a total purchase price of $170.1 million in cash, payable in installments as set forth in the Stock Purchase Agreement, to obtain 100% of the voting equity interest in AUOSP. As a result, AUOSP became a consolidated subsidiary of the Company and the results of operations of AUOSP have been included in the Consolidated Statement of Operations of the Company since September 29, 2016.

Simultaneously with the entry into the Stock Purchase Agreement, SunPower Systems Sarl (“SPSW”) and AU Optronics Corporation (“AUO Corp”), the ultimate parent of AUO, entered into a Module Supply Agreement whereby AUO Corp agreed to purchase on commercial terms 100MW of SunPower’s E-Series solar modules, with the purchase price having been prepaid in full by AUO Corp prior to the closing of the acquisition. As a result, the Company accounted for its purchase price consideration in accordance with the substance of the combined transactions, which resulted in consideration of $91.1 million in cash to be paid according to the following installment schedule: (i) $30.0 million in cash paid on the closing date; (ii) $1.1 million in cash to be paid on the second anniversary of the closing date; (iii) $30.0 million in cash to be paid on the third anniversary of the closing date; and (iv) $30.0 million in cash to be paid on the fourth anniversary of the closing date, as well as the 100MW of modules to be delivered during fiscal 2017 and 2018. The total purchase price consideration, including the estimated fair value of the modules and discounted to present value as of September 29, 2016, was $130.6 million.

Prior to the acquisition date, the Company accounted for its 50% interest in AUOSP as an equity method investment (see Note 10). The Company engaged a third-party valuation expert to assist in determining the fair value of AUOSP's assets, liabilities, and equity interests. The acquisition-date fair value of the previous equity interest, computed as the Company's 50% interest in the net asset value of AUOSP, as determined using the income approach and with assistance from the third-party valuation expert, was $120.5 million and is included in the measurement of the consideration transferred. The Company recognized a loss of $90.9 million as a result of remeasuring its prior equity interest in AUOSP held before the business combination. The loss is included in the "Other income (expense), net" section of the Consolidated Statements of Operations.

As a result of the acquisition, the Company obtained full control of a solar cell manufacturing facility, from which it expects to achieve significant synergies. Also in connection with the Stock Purchase Agreement and Module Supply Agreement, the Company, SPTL, SunPower Philippines Manufacturing Limited, a wholly owned subsidiary of the Company, and SPSW entered into an agreement (the “Settlement Agreement”) with AUO, AUO Corp, and AUOSP to settle all claims, demands, damages, actions, causes of action, or suits between them, including but not limited to the arbitration before the ICC International Court of Arbitration (see Note 9).

Prior to the acquisition, AUOSP sold its solar cells to both SPSW and AUO, with the significant majority of sales to SPSW. Sales to AUO, with the exception of the Module Supply agreement discussed above, ceased in connection with the

108

Table of Contents


acquisition. As the sales to SPSW would be intercompany transactions upon consolidation, and the sales to AUO are not continuing business, the Company determined that the pro-forma effects to the Company’s Statements of Operations of consolidating AUOSP from December 29, 2014 were not material.

Preexisting Relationships

Prior to the acquisition, the Company had several preexisting relationships with AUOSP. In connection with the original joint venture agreement, the Company and AUO had also entered into licensing and joint development, supply, and other ancillary transaction agreements. Through the Licensing and Technology Transfer Agreement, the Company and AUO licensed to AUOSP, on a non-exclusive, royalty-free basis, certain background intellectual property related to solar cell manufacturing (in the case of the Company) and manufacturing processes (in the case of AUO). Under the seven-year Supply Agreement with AUOSP, the Company was committed to purchase 80% of AUOSP's total annual output on cost-plus pricing terms, allocated on a monthly basis to the Company. The Company and AUO had the right to reallocate supplies from time to time under a written agreement. In fiscal 2010, the Company and AUOSP entered into an agreement under which the Company would resell to AUOSP, under contractually fixed terms for quantity and price, polysilicon purchased from a third-party supplier. Under the agreement, AUOSP would provide prepayments to the Company related to such polysilicon, which prepayment would then be made by the Company to the third-party supplier.

In connection with the transactions contemplated under the Stock Purchase Agreement, the Company (and certain of its affiliates), AUO (and certain of its affiliates), and AUOSP terminated certain agreements, including (a) the Joint Venture Agreement by and among SPTL, AUO, AUO Corp, and AUOSP, dated as of May 27, 2010 and as amended from time to time, (b) the Supply Agreement for solar cells by and among SPSW, AUO, and AUOSP, dated as of July 5, 2010, and (c) the License and Technology Transfer Agreement by and among SPTL, AUO, and AUOSP, dated as of July 5, 2010.

As a result of the acquisition and the settlement of the preexisting agreements, the Company recognized a net gain of $203.3 million, which was recognized separately from the business combination and is included in the "Other income (expense), net" section of the Consolidated Statements of Operations. The gain was comprised of three primary components: first, a $133.0 million gain related to the elimination of a customer advance liability without return of any proceeds by the Company that was previously recognized in the Company’s books associated with the prepayment by AUOSP under the polysilicon purchase contract with the Company. The fair value of this prepayment on AUOSP’s opening balance sheet was determined to be zero and accordingly the offsetting balance on the Company’s balance sheet was written off. Second, an $87.2 million gain associated with the termination of the polysilicon purchase contract between AUOSP and the Company, as the contract required AUOSP to purchase polysilicon at above-market prices. These amounts were partially offset by a $16.9 million loss associated with the termination of the cell supply contract, as the contract required the Company to purchase cells at above-market prices.

Purchase Price Allocation 

The Company accounted for this acquisition using the acquisition method. The Company allocated the purchase price to the acquired assets and liabilities based on their estimated fair values at the acquisition date as summarized in the following table.

(In thousands)
 
 
Net tangible assets acquired
 
$
161,432

Goodwill
 
89,600

Total allocable consideration
 
$
251,032


The fair value of the net tangible assets acquired on September 29, 2016 is presented in the following table:

109

Table of Contents


(In thousands)
 
 
Cash and cash equivalents
 
$
5,997

Inventories
 
9,072

Prepaid expenses and other current assets:
 


Cell supply agreement*
 
16,928

Related party receivables*
 
22,875

Other receivables
 
23,956

Other prepaid expenses
 
2,711

Property, plant, and equipment
 
285,589

Other long-term assets
 
342

Total assets acquired
 
$
367,470

 
 
 
Accounts payable
 
$
41,186

Accrued liabilities:
 


Polysilicon supply agreement*
 
87,198

Related party payables*
 
14,333

Employee compensation and employee benefits
 
4,017

Other accrued liabilities
 
760

Short-term debt
 
58,248

Other long-term liabilities
 
296

Total liabilities assumed
 
$
206,038

 
 
 
Net tangible assets acquired
 
$
161,432

*Amount eliminated upon consolidation with the Company.

Goodwill 

As noted above, $89.6 million had been allocated to goodwill within all three Segments during the year ended January 1, 2017 (see Note 4). Goodwill represents the excess of the purchase price of an acquired business over the fair value of the underlying net tangible and other intangible assets and is not deductible for tax purposes. Among the factors that contributed to a purchase price in excess of the fair value of the net tangible and other intangible assets was the acquisition of an assembled workforce, synergies in technologies, skill sets, operations, and organizational cultures. In connection with the Company’s overall goodwill impairment evaluation as discussed further in Note 4, this goodwill was subsequently impaired during the year ending January 1, 2017, and no further goodwill related to the acquisition remained on the Company’s Consolidated Balance Sheet as of January 1, 2017.

Note 4. GOODWILL AND OTHER INTANGIBLE ASSETS

Goodwill

The following table presents the changes in the carrying amount of goodwill under the Company's reportable business segments:
(In thousands)
 
Residential
 
Commercial
 
Power Plant
 
Total
As of January 3, 2016
 
$
32,180

 
$
10,314

 
$
15,641

 
$
58,135

Goodwill arising from business combinations
 
17,771

 
23,316

 
48,513

 
89,600

Goodwill impairment
 
(49,951
)
 
(33,260
)
 
(64,154
)
 
(147,365
)
Adjustments to goodwill
 

 
(370
)
 

 
(370
)
As of January 1, 2017
 
$

 
$

 
$

 
$



110

Table of Contents


Goodwill is tested for impairment at least annually, or more frequently if certain indicators are present. If goodwill is determined more likely than not to be impaired upon an initial assessment of qualitative factors, a two-step valuation and accounting process is used to test for goodwill impairment. The first step is to determine if there is an indication of impairment by comparing the estimated fair value of each reporting unit to its carrying value, including existing goodwill. Goodwill is considered impaired if the carrying value of a reporting unit exceeds the estimated fair value. Upon an indication of impairment, a second step is performed to determine the amount of the impairment by comparing the implied fair value of the reporting unit's goodwill with its carrying value.

The Company conducts its annual impairment test of goodwill as of the first day of the fourth fiscal quarter of each year, or on an interim basis if circumstances warrant. Impairment of goodwill is tested at the Company's reporting unit level. Management determined that the Residential Segment, the Commercial Segment, and the Power Plant Segment are the reporting units. In estimating the fair value of the reporting units, the Company makes estimates and judgments about its future cash flows using an income approach defined as Level 3 inputs under fair value measurement standards. The income approach, specifically a discounted cash flow analysis, included assumptions for, among others, forecasted revenue, gross margin, operating income, working capital cash flow, perpetual growth rates and long-term discount rates, all of which require significant judgment by management. The sum of the fair values of the Company's reporting units are also compared to the Company's total external market capitalization to validate the appropriateness of its assumptions and such reporting unit values are adjusted, if appropriate. These assumptions also consider the current industry environment and outlook, and the resulting impact on the Company's expectations for the performance of its business.

Due to market circumstances that occurred during the third quarter of fiscal 2016, including a decline in the Company's stock price which resulted in the market capitalization of the Company being below its book value, the Company determined that an interim goodwill impairment evaluation was necessary. Based on the interim impairment test as of October 2, 2016, the Company determined that the carrying value of all reporting units exceeded their fair value. As a result, the Company performed an evaluation of the second step of the impairment analysis for the reporting units discussed above. The Company's calculation of the implied fair value of goodwill included significant assumptions for, among others, the fair values of recognized assets and liabilities and of unrecognized intangible assets, all of which require significant judgment by management. The Company calculated that the implied fair value of goodwill for all reporting units was zero and therefore recorded a goodwill impairment loss of $147.4 million, representing all of the goodwill associated with these reporting units.

Other Intangible Assets

The following tables present details of the Company's acquired other intangible assets:
(In thousands)
 
Gross
 
Accumulated
Amortization
 
Net
As of January 1, 2017
 
 
 
 
 
 
Patents and purchased technology
 
$
48,640

 
$
(15,529
)
 
$
33,111

Project pipeline assets
 
9,446

 
(1,804
)
 
7,642

Purchased in-process research and development
 
3,700

 
(485
)
 
3,215

Other
 
1,000

 
(750
)
 
250

 
 
$
62,786

 
$
(18,568
)
 
$
44,218

 
 
 
 
 
 
 
As of January 3, 2016
 
 
 
 
 
 
Patents and purchased technology
 
$
53,499

 
$
(5,328
)
 
$
48,171

Project pipeline assets
 
9,446

 

 
9,446

Purchased in-process research and development
 
3,700

 

 
3,700

Other
 
500

 
(375
)
 
125

 
 
$
67,145

 
$
(5,703
)
 
$
61,442


Aggregate amortization expense for intangible assets totaled $13.0 million, $5.1 million and $0.6 million for fiscal 2016, 2015 and 2014, respectively. Aggregate impairment loss for intangible assets amounted to 4.7 million for fiscal 2016.

As of January 1, 2017, the estimated future amortization expense related to intangible assets with finite useful lives is as follows:

111

Table of Contents


(In thousands)
 
Amount
Fiscal Year
 
 
2017
 
$
12,315

2018
 
14,405

2019
 
9,961

2020
 
6,315

 
 
$
42,996



Note 5. BALANCE SHEET COMPONENTS
 
 
As of
(In thousands)
 
January 1, 2017
 
January 3, 2016
Accounts receivable, net:
 
 
 
 
Accounts receivable, gross1,2
 
$
242,451

 
$
207,860

Less: allowance for doubtful accounts
 
(20,380
)
 
(15,505
)
Less: allowance for sales returns
 
(2,433
)
 
(1,907
)
 
 
$
219,638

 
$
190,448

1 
Includes short-term financing receivables associated with solar power systems leased of $19.3 million and $12.5 million as of January 1, 2017 and January 3, 2016, respectively (see Note 6).

2 
Includes short-term retainage of $8.8 million and $11.8 million as of January 1, 2017 and January 3, 2016, respectively. Retainage refers to the earned, but unbilled, portion of a construction and development project for which payment is deferred by the customer until certain contractual milestones are met.

(In thousands)

 
Balance at Beginning of Period
 
Charges (Releases) to Expenses / Revenues
 
Deductions
 
Balance at End of Period
Allowance for doubtful accounts:
 
 
 
 
 
 
 
 
   Year ended January 1, 2017
 
$
15,505

 
$
7,319

 
$
(2,445
)
 
$
20,379

   Year ended January 3, 2016
 
18,152

 
1,163

 
(3,810
)
 
15,505

   Year ended December 28, 2014
 
26,463

 
(1,023
)
 
(7,288
)
 
18,152

Allowance for sales returns:
 
 
 
 
 
 
 
 
   Year ended January 1, 2017
 
1,907

 
526

 

 
2,433

   Year ended January 3, 2016
 
1,145

 
762

 

 
1,907

   Year ended December 28, 2014
 
2,095

 
(950
)
 

 
1,145

Valuation allowance for deferred tax assets:
 
 
 
 
 
 
 
 
   Year ended January 1, 2017
 
268,671

 
228,565

 

 
497,236

   Year ended January 3, 2016
 
118,748

 
149,923

 

 
268,671

   Year ended December 28, 2014
 
90,571

 
28,177

 

 
118,748




As of
(In thousands)

January 1, 2017

January 3, 2016
Inventories:




Raw materials

$
136,906


$
124,297

Work-in-process

184,967


131,258

Finished goods

79,834


126,835

 

$
401,707


$
382,390



112

Table of Contents


 
 
As of
(In thousands)
 
January 1, 2017
 
January 3, 2016
Prepaid expenses and other current assets:
 
 
 
 
Deferred project costs
 
$
68,338

 
$
67,479

VAT receivables, current portion
 
14,260

 
14,697

Deferred costs for solar power systems to be leased
 
28,705

 
40,988

Derivative financial instruments
 
4,802

 
8,734

Prepaid inventory
 
83,943

 
50,615

Other receivables
 
85,834

 
78,824

Prepaid taxes
 
5,468

 
71,529

Other prepaid expenses
 
24,260

 
26,651

Other current assets
 
60

 

 
 
$
315,670

 
$
359,517


 
 
As of
(In thousands)
 
January 1, 2017
 
January 3, 2016
Project assets - plants and land:
 
 
 
 
Project assets — plants
 
$
389,103

 
$
479,108

Project assets — land
 
18,927

 
5,416

 
 
$
408,030

 
$
484,524

Project assets - plants and land, current portion
 
$
374,459

 
$
479,452

Project assets - plants and land, net of current portion
 
$
33,571

 
$
5,072


 
 
As of
(In thousands)
 
January 1, 2017
 
January 3, 2016
Property, plant and equipment, net:
 
 
 
 
Manufacturing equipment1
 
$
403,808

 
$
556,963

Land and buildings
 
130,080

 
32,090

Leasehold improvements
 
280,620

 
244,098

Solar power systems2
 
207,277

 
141,075

Computer equipment
 
185,518

 
103,443

Furniture and fixtures
 
12,591

 
10,640

Construction-in-process
 
39,849

 
247,511

 
 
1,259,743

 
1,335,820

Less: accumulated depreciation
 
(232,677
)
 
(604,590
)
 
 
$
1,027,066

 
$
731,230

1 
The Company's mortgage loan agreement with International Finance Corporation ("IFC") is collateralized by certain manufacturing equipment with a net book value of $14.3 million and $85.1 million as of January 1, 2017 and January 3, 2016, respectively.

2 
Includes $177.1 million and $110.4 million of solar power systems associated with sale-leaseback transactions under the financing method as of January 1, 2017 and January 3, 2016, respectively, which are depreciated using the straight-line method to their estimated residual values over the lease terms of up to 20 years (see Note 6).

113

Table of Contents


 
 
As of
(In thousands)
 
January 1, 2017
 
January 3, 2016
Property, plant and equipment, net by geography1:
 
 
 
 
Philippines
 
$
373,286

 
$
460,420

Malaysia
 
275,980

 

United States
 
276,053

 
201,419

Mexico
 
81,419

 
44,164

Europe
 
20,154

 
22,962

Other
 
174

 
2,265

 
 
$
1,027,066

 
$
731,230

1 
Property, plant and equipment, net by geography is based on the physical location of the assets.

 
 
As of
(In thousands)
 
January 1, 2017
 
January 3, 2016
Other long-term assets:
 
 
 
 
Equity method investments1
 
$
(6,931
)
 
$
186,405

Derivative financial instruments
 
11,429

 

Cost method investments
 
39,423

 
36,369

Other
 
141,598

 
75,201

 
 
$
185,519

 
$
297,975

1 
Includes the carrying value of the Company's investment in the 8point3 Group, which had a negative value of $60.6 million and $30.9 million as of January 1, 2017 and January 3, 2016, respectively (see Note 10).

 
 
As of
(In thousands)
 
January 1, 2017
 
January 3, 2016
Accrued liabilities:
 
 
 
 
Employee compensation and employee benefits
 
$
43,370

 
$
59,476

Deferred revenue
 
27,649

 
19,887

Short-term residential lease financing
 

 
7,395

Interest payable
 
15,329

 
8,165

Short-term warranty reserves
 
4,894

 
16,639

Restructuring reserve
 
18,001

 
1,823

VAT payables
 
4,743

 
4,225

Derivative financial instruments
 
2,023

 
2,316

Inventory payable
 
83,943

 
50,615

Liability due to 8point3 Energy Partners
 

 
9,952

Proceeds from 8point3 Energy Partners attributable to projects prior to Commercial Operation Date ("COD")
 
3,665

 

Contributions from noncontrolling interests attributable to projects prior to COD
 
93,875

 

Taxes payable
 
25,602

 
36,824

Liability due to AU Optronics
 
31,714

 

Other
 
36,418

 
96,180

 
 
$
391,226

 
$
313,497



114

Table of Contents


 
 
As of
(In thousands)
 
January 1, 2017
 
January 3, 2016
Other long-term liabilities:
 
 
 
 

Deferred revenue
 
$
188,932

 
$
179,779

Long-term warranty reserves
 
156,315

 
147,488

Long-term sale-leaseback financing
 
204,879

 
125,286

Long-term residential lease financing with 8point3 Energy Partners
 
29,370

 
29,389

Unrecognized tax benefits
 
47,203

 
43,297

Long-term pension liability
 
3,381

 
12,014

Derivative financial instruments
 
448

 
1,033

Long-term liability due to AU Optronics
 
71,639

 

Other
 
18,865

 
26,271

 
 
$
721,032

 
$
564,557


 
 
As of
(In thousands)
 
January 1, 2017
 
January 3, 2016
Accumulated other comprehensive loss:
 
 
 
 

Cumulative translation adjustment
 
$
(12,249
)
 
$
(11,164
)
Net unrealized gain on derivatives
 
1,203

 
5,942

Net gain (loss) on long-term pension liability adjustment
 
4,228

 
(2,055
)
Deferred taxes
 
(420
)
 
(746
)
 
 
$
(7,238
)
 
$
(8,023
)

Note 6. LEASING

Residential Lease Program

The Company offers a solar lease program, which provides U.S. residential customers with SunPower systems under 20-year lease agreements that include system maintenance and warranty coverage. Leases are classified as either operating or sales-type leases in accordance with the relevant accounting guidelines.

Operating Leases

The following table summarizes "Solar power systems leased and to be leased, net" under operating leases on the Company's Consolidated Balance Sheets as of January 1, 2017 and January 3, 2016:
 
 
As of
(In thousands)
 
January 1, 2017
 
January 3, 2016
Solar power systems leased and to be leased, net1,2:
 
 
 
 
Solar power systems leased
 
$
666,700

 
$
543,358

Solar power systems to be leased
 
25,367

 
34,319

 
 
692,067

 
577,677

Less: accumulated depreciation
 
(70,800
)
 
(46,157
)
 
 
$
621,267

 
$
531,520

1 
Solar power systems leased and to be leased, net are physically located exclusively in the United States.

2 
As of January 1, 2017 and January 3, 2016, the Company had pledged solar assets with an aggregate book value of $13.1 million and zero, respectively, to third-party investors as security for the Company's contractual obligations.

The following table presents the Company's minimum future rental receipts on operating leases placed in service as of January 1, 2017:

115

Table of Contents


(In thousands)
 
Fiscal 2017
 
Fiscal 2018
 
Fiscal 2019
 
Fiscal 2020
 
Fiscal 2021
 
Thereafter
 
Total
Minimum future rentals on operating leases placed in service1
 
24,459

 
24,286

 
24,333

 
24,383

 
24,433

 
330,379

 
$
452,273

1 
Minimum future rentals on operating leases placed in service does not include contingent rentals that may be received from customers under agreements that include performance-based incentives nor does it include rent receivables on operating leases sold to the 8point3 Group.

Sales-Type Leases

As of January 1, 2017 and January 3, 2016, the Company's net investment in sales-type leases presented in "Accounts receivable, net" and "Long-term financing receivables, net" on the Company's Consolidated Balance Sheets was as follows:
 
 
As of
(In thousands)
 
January 1, 2017
 
January 3, 2016
Financing receivables1:
 
 
 
 
Minimum lease payments receivable2
 
$
560,582

 
$
366,759

Unguaranteed residual value
 
70,636

 
50,722

Unearned income
 
(104,624
)
 
(70,155
)
Net financing receivables
 
$
526,594

 
$
347,326

Current
 
$
19,261

 
$
12,535

Long-term
 
$
507,333

 
$
334,791

1 
As of January 1, 2017 and January 3, 2016, the Company had pledged financing receivables of $18.6 million and zero, respectively, to third-party investors as security for the Company's contractual obligations.

2 
Net of allowance for doubtful accounts amounting to $4.9 million and $2.6 million, as of January 1, 2017 and January 3, 2016, respectively.

As of January 1, 2017, future maturities of net financing receivables for sales-type leases are as follows:
(In thousands)
 
Fiscal 2017
 
Fiscal 2018
 
Fiscal 2019
 
Fiscal 2020
 
Fiscal 2021
 
Thereafter
 
Total
Scheduled maturities of minimum lease payments receivable1
 
28,769

 
28,285

 
28,530

 
28,783

 
29,041

 
417,174

 
$
560,582

1 
Minimum future rentals on sales-type leases placed in service does not include contingent rentals that may be received from customers under agreements that include performance-based incentives.

Sale-Leaseback Arrangements

The Company enters into sale-leaseback arrangements under which solar power systems are sold to third parties and subsequently leased back by the Company over minimum lease terms of up to 25 years. Separately, the Company enters into PPAs with end customers, who host the leased solar power systems and buy the electricity directly from the Company under PPAs with terms of up to 25 years. At the end of the lease term, the Company has the option to purchase the systems at fair value or may be required to remove the systems and return them to the third parties.

The Company has classified its sale-leaseback arrangements of solar power systems not involving integral equipment as operating leases. The deferred profit on the sale of these systems is recognized over the term of the lease. As of January 1, 2017, future minimum lease obligations associated with these systems were $78.2 million, which will be recognized over the minimum lease terms. Future minimum payments to be received from customers under PPAs associated with the solar power systems under sale-leaseback arrangements classified as operating leases will be recognized over the lease terms of up to 20 years and are contingent upon the amounts of energy produced by the solar power systems.

The Company enters into certain sale-leaseback arrangements under which the systems subject to the sale-leaseback arrangements have been determined to be integral equipment as defined under the accounting guidance for such transactions. The Company has continuing involvement with the solar power systems throughout the lease due to purchase option rights in the arrangements. As a result of such continuing involvement, the Company accounts for each of these transactions as a

116

Table of Contents


financing. Under the financing method, the proceeds received from the sale of the solar power systems are recorded by the Company as financing liabilities. The financing liabilities are subsequently reduced by the Company's payments to lease back the solar power systems, less interest expense calculated based on the Company's incremental borrowing rate adjusted to the rate required to prevent negative amortization. The solar power systems under the sale-leaseback arrangements remain on the Company's balance sheet and are classified within "Property, plant and equipment, net" (see Note 5). As of January 1, 2017, future minimum lease obligations for the sale-leaseback arrangements accounted for under the financing method were $187.6 million, which will be recognized over the lease terms of up to 25 years. During fiscal 2016 and 2015, the Company had net financing proceeds of $94.8 million and 15.0 million, respectively, in connection with these sale-leaseback arrangements. As of January 1, 2017 and January 3, 2016, the carrying amount of the sale-leaseback financing liabilities, presented in "Other long-term liabilities" on the Company's Consolidated Balance Sheets, was $204.9 million and $125.3 million, respectively (see Note 5).

Note 7. FAIR VALUE MEASUREMENTS

Fair value is estimated by applying the following hierarchy, which prioritizes the inputs used to measure fair value into three levels and bases the categorization within the hierarchy upon the lowest level of input that is available and significant to the fair value measurement (observable inputs are the preferred basis of valuation):

Level 1 — Quoted prices in active markets for identical assets or liabilities.
Level 2 — Measurements are inputs that are observable for assets or liabilities, either directly or indirectly, other than quoted prices included within Level 1.
Level 3 — Prices or valuations that require management inputs that are both significant to the fair value measurement and unobservable.

Assets and Liabilities Measured at Fair Value on a Recurring Basis

The Company measures certain assets and liabilities at fair value on a recurring basis. There were no transfers between fair value measurement levels during any presented period. The Company did not have any assets or liabilities measured at fair value on a recurring basis requiring Level 3 inputs as of January 1, 2017 or January 3, 2016.

The following table summarizes the Company's assets and liabilities measured and recorded at fair value on a recurring basis as of January 1, 2017 and January 3, 2016:
 
 
January 1, 2017
 
January 3, 2016
(In thousands)
 
Total
 
Level 1
 
Level 2
 
Total
 
Level 1
 
Level 2
Assets
 
 
 
 
 
 
 
 
 
 
 
 
Cash and cash equivalents1:
 
 
 
 
 
 
 
 
 
 
 
 
Money market funds
 
$
3,002

 
$
3,002

 
$

 
$
540,000

 
$
540,000

 
$

Prepaid expenses and other current assets:
 
 
 
 
 
 
 
 
 
 
 
 
Derivative financial instruments (Note 12)
 
4,802

 

 
4,802

 
8,734

 

 
8,734

Other long-term assets:
 
 
 
 
 
 
 
 
 
 
 
 
Derivative financial instruments (Note 12)
 
11,429

 

 
11,429

 

 

 

Total assets
 
$
19,233

 
$
3,002

 
$
16,231

 
$
548,734

 
$
540,000


$
8,734

Liabilities
 
 
 
 
 
 
 
 
 
 
 
 
Accrued liabilities:
 
 
 
 
 
 
 
 
 
 
 
 
Derivative financial instruments (Note 12)
 
2,023

 

 
2,023

 
2,316

 

 
2,316

Other long-term liabilities:
 
 
 
 
 
 
 
 
 
 
 
 
Derivative financial instruments (Note 12)
 
448

 

 
448

 
1,033

 

 
1,033

Total liabilities
 
$
2,471

 
$

 
$
2,471

 
$
3,349

 
$

 
$
3,349

1 
The Company's cash equivalents consist of money market fund instruments and commercial paper that are classified as available-for-sale and are highly liquid investments with original maturities of 90 days or less. The Company's money market fund instruments are

117

Table of Contents


categorized within Level 1 of the fair value hierarchy because they are valued using quoted market prices for identical instruments in active markets.

Other financial instruments, including the Company's accounts receivable, accounts payable and accrued liabilities, are carried at cost, which generally approximates fair value due to the short-term nature of these instruments.

Assets and Liabilities Measured at Fair Value on a Non-Recurring Basis

The Company measures certain investments and non-financial assets (including property, plant and equipment, and other intangible assets) at fair value on a non-recurring basis in periods after initial measurement in circumstances when the fair value of such asset is impaired below its recorded cost. Information regarding the Company's goodwill and intangible asset balances are disclosed in Note 4. As of January 1, 2017, the Company's Fab 2 manufacturing facility was measured at fair value, determined using a combination of the cost and market approaches in conjunction with a third-party appraiser. While certain inputs used when applying the market approach, such as market prices of assets with comparable features, were observable, the application of the cost approach required the Company to develop certain of its own assumptions, such as the remaining useful life of the facility. Thus, although a combination of Level 2 and Level 3 inputs were utilized to determine the estimated fair value, the Fab 2 manufacturing facility was classified as a Level 3 fair value measurement based on the lowest level of significant inputs. As of January 3, 2016, there were no such items recorded at fair value.

Held-to-Maturity Debt Securities

The Company's debt securities, classified as held-to-maturity, are Philippine government bonds that the Company maintains as collateral for business transactions within the Philippines. These bonds have various maturity dates and are classified as "Restricted long-term marketable securities" on the Company's Consolidated Balance Sheets. As of January 1, 2017 and January 3, 2016 these bonds had a carrying value of $5.0 million and $6.5 million, respectively. The Company records such held-to-maturity investments at amortized cost based on its ability and intent to hold the securities until maturity. The Company monitors for changes in circumstances and events that would affect its ability and intent to hold such securities until the recorded amortized costs are recovered. No other-than-temporary impairment loss was incurred during any presented period. The held-to-maturity debt securities were categorized in Level 2 of the fair value hierarchy.

Equity and Cost Method Investments

The Company holds equity investments in non-consolidated entities that are accounted for under both the equity and cost method. The Company monitors these investments, which are included in "Other long-term assets" in its Consolidated Balance Sheets, for impairment and records reductions in the carrying values when necessary. Circumstances that indicate an other-than-temporary decline include Level 2 and Level 3 measurements such as the valuation ascribed to the issuing company in subsequent financing rounds, decreases in quoted market prices, and declines in the results of operations of the issuer.

As of January 1, 2017 and January 3, 2016, the Company had $(6.9) million and $186.4 million, respectively, in investments accounted for under the equity method (see Note 10). As of January 1, 2017 and January 3, 2016, the Company had $39.4 million and $36.4 million respectively, in investments accounted for under the cost method.

Note 8. RESTRUCTURING

December 2016 Restructuring Plan

On December 2, 2016, the Company adopted, and the Company began implementing, a restructuring plan to reduce costs and focus on improving cash flow while positioning the Company to succeed in the next phase of industry growth. As part of the plan, the Board of Directors approved the closure of the Company’s Philippine-based Fab 2 manufacturing facility. In connection with the plan, which is expected to be completed by the end of fiscal 2017, the Company expects approximately 2,500 employees to be affected, primarily in the Philippines, representing approximately 25% of the Company’s global workforce. The Company expects to incur restructuring charges in connection with the plan totaling approximately $225 million to $275 million, consisting primarily of asset impairments, severance benefits, lease and related termination costs, and other associated costs. The Company expects approximately 30% of such total restructuring charges to be cash. The actual timing and costs of the plan may differ from the Company’s current expectations and estimates.

August 2016 Restructuring Plan


118

Table of Contents


On August 9, 2016, the Company adopted and began implementing initiatives to realign the Company’s downstream investments, optimize the Company’s supply chain and reduce operating expenses, in response to expected near-term challenges primarily relating to the Company’s Power Plant Segment. In connection with the realignment, which is expected to be completed by the end of fiscal 2017, the Company expects approximately 1,200 employees to be affected, primarily in the Philippines, representing approximately 15% of the Company’s global workforce at the time. The Company expects to incur restructuring charges totaling approximately $35 million to $45 million, consisting primarily of severance benefits, asset impairments, lease and related termination costs, and other associated costs. The Company expects more than 50% of total charges to be cash. The actual timing and costs of the plan may differ from the Company’s current expectations and estimates due to a number of factors, including uncertainties related to required consultations with employee representatives as well as other local labor law requirements and mandatory processes in the relevant jurisdictions.

Legacy Restructuring Plans

During prior fiscal years, the Company implemented approved restructuring plans, related to all segments, to align with changes in the global solar market which included the consolidation of the Company's Philippine manufacturing operations as well as actions to accelerate operating cost reduction and improve overall operating efficiency. These restructuring activities were substantially complete as of January 1, 2017; however, the Company expects to continue to incur costs as it finalizes previous estimates and actions in connection with these plans, primarily due to other costs, such as legal services.

The following table summarizes the restructuring charges recognized in the Company's Consolidated Statements of Operations:
 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
 
Cumulative To Date
December 2016 Plan:
 
 
 
 
 
 
 
 
Non-cash impairment charges
 
$
148,791

 
$

 
$

 
$
148,791

Severance and benefits
 
$
15,901

 
$

 
$

 
$
15,901

Other costs1
 
$
7,819

 
$

 
$

 
$
7,819

 
 
$
172,511

 
$

 
$

 
$
172,511

August 2016 Plan:
 
 
 
 
 
 
 
 
Non-cash impairment charges
 
$
17,926

 
$

 
$

 
$
17,926

Severance and benefits
 
15,591

 

 

 
15,591

Lease and related termination costs
 
557

 

 

 
557

Other costs1
 
$
364

 
$

 
$

 
364

 
 
$
34,438

 
$

 
$

 
$
34,438

Legacy Restructuring Plans:
 
 
 
 
 
 
 
 
Non-cash impairment charges
 
$

 
$
5

 
$
719

 
$
61,320

Severance and benefits
 
350

 
2,710

 
10,535

 
61,949

Lease and related termination costs
 
(171
)
 
1,210

 
244

 
6,813

Other costs1
 
62

 
2,466

 
725

 
13,599

 
 
$
241

 
$
6,391

 
$
12,223

 
$
143,681

Total restructuring charges
 
$
207,190

 
$
6,391

 
$
12,223

 
$
350,630

1Other costs primarily represent associated legal services and costs of relocating employees.


The following table summarizes the restructuring reserve activity during the fiscal year ended January 1, 2017:

119

Table of Contents


 
 
Fiscal Year
(In thousands)
 
2015
 
Charges (Benefits)
 
Payments
 
2016
December 2016 Plan:
 
 
 
 
 
 
 
 
Non-cash impairment charges
 
$

 
$
148,791

 
$

 
$

Severance and benefits
 
$

 
$
15,901

 
$
(7,790
)
 
$
8,111

Lease and related termination costs
 
$

 
$

 
$

 
$

Other costs1
 
$

 
$
7,819

 
$
(1,887
)
 
$
5,932

 
 
$

 
$
172,511

 
$
(9,677
)
 
$
14,043

August 2016 Plan:
 
 
 
 
 
 
 
 
Non-cash impairment charges
 
$

 
$
17,926

 
$

 
$

Severance and benefits
 

 
15,591

 
(12,143
)
 
3,448

Lease and related termination costs
 

 
557

 
(557
)
 

Other costs1
 

 
364

 
(278
)
 
86

 
 
$

 
34,438

 
$
(12,978
)
 
3,534

Legacy Restructuring Plans:
 
 
 
 
 
 
 
 
Non-cash impairment charges
 
$

 
$

 
$

 
$

Severance and benefits
 
395

 
350

 
(446
)
 
299

Lease and related termination costs
 
743

 
(171
)
 
(520
)
 
52

Other costs1
 
685

 
62

 
(674
)
 
73

 
 
1,823

 
241

 
(1,640
)
 
424

Total restructuring liability
 
$
1,823

 
$
207,190

 
$
(24,295
)
 
$
18,001

1 
Other costs primarily represent associated legal services and costs of relocating employees.

Note 9. COMMITMENTS AND CONTINGENCIES

Facility and Equipment Lease Commitments

The Company leases certain facilities under non-cancellable operating leases from unaffiliated third parties. As of January 1, 2017, future minimum lease payments for facilities under operating leases were $52.2 million, to be paid over the remaining contractual terms of up to 8 years. The Company also leases certain buildings, machinery and equipment under non-cancellable capital leases. As of January 1, 2017, future minimum lease payments for assets under capital leases were $4.5 million, to be paid over the remaining contractual terms of up to 7 years.

Purchase Commitments
 
The Company purchases raw materials for inventory and manufacturing equipment from a variety of vendors. During the normal course of business, in order to manage manufacturing lead times and help assure adequate supply, the Company enters into agreements with contract manufacturers and suppliers that either allow them to procure goods and services based on specifications defined by the Company, or that establish parameters defining the Company's requirements. In certain instances, these agreements allow the Company the option to cancel, reschedule or adjust the Company's requirements based on its business needs before firm orders are placed. Consequently, not all of the Company's disclosed purchase commitments arising from these agreements are firm, non-cancellable, and unconditional commitments.

The Company also has agreements with several suppliers, including some of its non-consolidated investees, for the procurement of polysilicon, ingots, wafers, and Solar Renewable Energy Credits, among others, which specify future quantities and pricing of products to be supplied by the vendors for periods up to 8 years and provide for certain consequences, such as forfeiture of advanced deposits and liquidated damages relating to previous purchases, in the event that the Company terminates the arrangements.

Future purchase obligations under non-cancellable purchase orders and long-term supply agreements as of January 1, 2017 are as follows:

120

Table of Contents


(In thousands)
 
Fiscal 2017
 
Fiscal 2018
 
Fiscal 2019
 
Fiscal 2020
 
Fiscal 2021
 
Thereafter
 
Total12
Future purchase obligations
 
736,106

 
206,261

 
175,694

 
161,848

 
1,000

 
2,000

 
$
1,282,909

1 
Total future purchase obligations were composed of $209.4 million related to non-cancellable purchase orders and $1.1 billion related to long-term supply agreements.
2 
During fiscal 2016, the Company did not fulfill all of the purchase commitments it was otherwise obligated to take by December 31, 2016, as specified in related contracts with a supplier. As of January 1, 2017, the Company has recorded an offsetting asset, recorded within "Prepaid expenses and other current assets," and liability, recorded within "Accrued liabilities," totaling $83.9 million. This amount represents the unfulfilled amount as of that date as the Company expects to satisfy the obligation via purchases of inventory in fiscal 2017, within the applicable contractual cure period.

The Company expects that all obligations related to non-cancellable purchase orders for manufacturing equipment will be recovered through future cash flows of the solar cell manufacturing lines and solar panel assembly lines when such long-lived assets are placed in service. Factors considered important that could result in an impairment review include significant under-performance relative to expected historical or projected future operating results, significant changes in the manner of use of acquired assets, and significant negative industry or economic trends. Obligations related to non-cancellable purchase orders for inventories match current and forecasted sales orders that will consume these ordered materials and actual consumption of these ordered materials are compared to expected demand regularly. The Company anticipates total obligations related to long-term supply agreements for inventories, which in the case of polysilicon are at purchase prices significantly above current market prices for similar materials, will be recovered because quantities are less than management's expected demand for its solar power products over the next several years. The terms of the long-term supply agreements are reviewed by management and the Company assesses the need for any accruals for estimated losses on adverse purchase commitments, such as lower of cost or net realizable value adjustments that will not be recovered by future sales prices, forfeiture of advanced deposits and liquidated damages, as necessary.

Advances to Suppliers

As noted above, the Company has entered into agreements with various vendors, some of which are structured as "take or pay" contracts, that specify future quantities and pricing of products to be supplied. Certain agreements also provide for penalties or forfeiture of advanced deposits in the event the Company terminates the arrangements. Under certain agreements, the Company was required to make prepayments to the vendors over the terms of the arrangements. As of January 1, 2017 and January 3, 2016, advances to suppliers totaled $284.8 million and $359.1 million, respectively, of which $111.5 million and $85.0 million, respectively, is classified as short-term in the Company's Consolidated Balance Sheets. Two suppliers accounted for 90% and 10% of total advances to suppliers, respectively, as of January 1, 2017, and 82% and 16%, respectively, as of January 3, 2016.

Advances from Customers

The Company has entered into other agreements with customers who have made advance payments for solar power products and systems. These advances will be applied as shipments of product occur or upon completion of certain project milestones. The estimated utilization of advances from customers as of January 1, 2017 is as follows:
(In thousands)
 
Fiscal 2017
 
Fiscal 2018
 
Fiscal 2019
 
Fiscal 2020
 
Fiscal 2021
 
Thereafter
 
Total
Estimated utilization of advances from customers
 
9,256

 
1,180

 

 

 

 

 
$
10,436


In fiscal 2010, the Company and its then joint venture, AUO SunPower Sdn. Bhd. ("AUOSP"), entered into an agreement under which the Company resold to AUOSP polysilicon purchased from a third-party supplier. In the third quarter of fiscal 2016, the Company terminated this agreement in connection with its acquisition and subsequent consolidation of AUOSP (See Note 3). Prior to the termination of the agreement, advance payments provided by AUOSP related to such polysilicon were then made by the Company to the third-party supplier. These advance payments were applied as a credit against AUOSP’s polysilicon purchases from the Company. Such polysilicon was used by AUOSP to manufacture solar cells that were sold to the Company on a "cost-plus" basis. The outstanding advance payments received from AUOSP are no longer included in the table above as the amounts are now eliminated as intercompany transactions in the purchase accounting for the acquisition and accordingly, as of January 1, 2017, the Company did not have a balance for advance payments received from

121

Table of Contents


AUOSP on its Consolidated Balance Sheets. As of January 3, 2016, advance payments received from AUOSP totaled $148.9 million, of which $22.7 million was classified as short-term in the Company's Consolidated Balance Sheets, based on projected product shipment dates.

Product Warranties

The following table summarizes accrued warranty activity for fiscal 2016, 2015 and 2014, respectively:
 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Balance at the beginning of the period
 
$
164,127

 
$
154,648

 
$
149,372

Accruals for warranties issued during the period
 
14,575

 
25,561

 
24,942

Settlements and adjustments during the period
 
(17,493
)
 
(16,082
)
 
(19,666
)
Balance at the end of the period
 
$
161,209

 
$
164,127

 
$
154,648


Contingent Obligations

Project agreements entered into with the Company's Commercial and Power Plant customers often require the Company to undertake obligations including: (i) system output performance warranties; (ii) system maintenance; (iii) penalty payments or customer termination rights if the system the Company is constructing is not commissioned within specified timeframes or other milestones are not achieved; and (iv) system put-rights whereby the Company could be required to buy back a customer's system at fair value on specified future dates if certain minimum performance thresholds are not met for specified periods. Historically, the Company's systems have performed significantly above the performance warranty thresholds, and there have been no cases in which the Company has had to buy back a system.

Future Financing Commitments

The Company is required to provide certain funding under agreements with unconsolidated investees, subject to certain conditions (see Note 10). As of January 1, 2017, the Company has future financing obligations related to these agreements through fiscal 2017 totaling $8.2 million.

Liabilities Associated with Uncertain Tax Positions
 
Total liabilities associated with uncertain tax positions were $47.2 million and $43.3 million as of January 1, 2017 and January 3, 2016, respectively. These amounts are included in "Other long-term liabilities" in the Company's Consolidated Balance Sheets in their respective periods as they are not expected to be paid within the next 12 months. Due to the complexity and uncertainty associated with its tax positions, the Company cannot make a reasonably reliable estimate of the period in which cash settlement, if any, would be made for its liabilities associated with uncertain tax positions in other long-term liabilities.

Indemnifications
 
The Company is a party to a variety of agreements under which it may be obligated to indemnify the counterparty with respect to certain matters. Typically, these obligations arise in connection with contracts and license agreements or the sale of assets, under which the Company customarily agrees to hold the other party harmless against losses arising from a breach of warranties, representations and covenants related to such matters as title to assets sold, negligent acts, damage to property, validity of certain intellectual property rights, non-infringement of third-party rights, and certain tax related matters including indemnification to customers under §48(c) solar commercial investment tax credit ("ITC") and U.S. Treasury Department ("Treasury Department") grant payments under Section 1603 of the American Recovery and Reinvestment Act (each a "Cash Grant"). In each of these circumstances, payment by the Company is typically subject to the other party making a claim to the Company that is contemplated by and valid under the indemnification provisions of the particular contract, which provisions are typically contract-specific, as well as bringing the claim under the procedures specified in the particular contract. These procedures usually allow the Company to challenge the other party's claims or, in case of breach of intellectual property representations or covenants, to control the defense or settlement of any third party claims brought against the other party. Further, the Company's obligations under these agreements may be limited in terms of activity (typically to replace or correct the products or terminate the agreement with a refund to the other party), duration and/or amounts. In some instances, the Company may have recourse against third parties and/or insurance covering certain payments made by the Company.


122

Table of Contents


In certain circumstances, the Company has provided indemnification to customers and investors under which the Company is contractually obligated to compensate these parties for losses they may suffer as a result of reductions in benefits received under ITC and Treasury Cash Grant programs. The Company applies for ITC and Cash Grant incentives based on guidance provided by the Internal Revenue Service ("IRS") and the Treasury Department, which include assumptions regarding the fair value of the qualified solar power systems, among others.  Certain of the Company’s development agreements, sale-leaseback arrangements, and financing arrangements with tax equity investors, incorporate assumptions regarding the future level of incentives to be received, which in some instances may be claimed directly by the Company's customers and investors. Generally, such obligations would arise as a result of reductions to the value of the underlying solar power systems as assessed by the IRS. At each balance sheet date, the Company assesses and recognizes, when applicable, the potential exposure from these obligations based on all the information available at that time, including any audits undertaken by the IRS. The maximum potential future payments that the Company could have to make under this obligation would depend on the difference between the eligible basis claimed on the tax filing for the solar energy systems sold or transferred to indemnified parties and the values that the IRS may redetermine as the eligible basis for the systems for purposes of claiming ITCs or U.S. Treasury grants. The Company uses the eligible basis for tax filing purposes determined with the assistance of independent third-party appraisals to determine the ITCs that are passed-through to and claimed by the indemnified parties. Since the Company cannot determine future revisions to Treasury Department guidelines governing system values, how the IRS will evaluate system values used in claiming ITCs, or U.S. Treasury grants, or how its customers and investors have utilized or will utilize these benefits in their own filings, the Company is unable to reliably estimate the maximum potential future payments that it could have to make under the Company’s contractual investor obligation as of each reporting date.

Defined Benefit Pension Plans

The Company maintains defined benefit pension plans for the majority of its non-U.S. employees. Benefits under these plans are generally based on an employee’s years of service and compensation. Funding requirements are determined on an individual country and plan basis and are subject to local country practices and market circumstances. The funded status of the pension plans, which represents the difference between the benefit obligation and fair value of plan assets, is calculated on a plan-by-plan basis. The benefit obligation and related funded status are determined using assumptions as of the end of each fiscal year. The Company recognizes the overfunded or underfunded status of its pension plans as an asset or liability on its Consolidated Balance Sheets. As of January 1, 2017 and January 3, 2016, the underfunded status of the Company’s pension plans, presented in "Other long-term liabilities" on the Company’s Consolidated Balance Sheets, was $3.4 million and $12.0 million, respectively. The impact of transition assets and obligations and actuarial gains and losses are recorded in "Accumulated other comprehensive loss", and are generally amortized as a component of net periodic cost over the average remaining service period of participating employees. Total other comprehensive gain related to the Company’s benefit plans was $6.3 million for the year ended January 1, 2017.

Legal Matters

Tax Benefit Indemnification Litigation

On March 19, 2014, a lawsuit was filed by NRG Solar LLC, now known as NRG Renew LLC (“NRG”), against SunPower Corporation, Systems, a wholly-owned subsidiary of the Company (“SunPower Systems”), in the Superior Court of Contra Costa County, California.  The complaint asserts that, according to the indemnification provisions in the contract pertaining to SunPower Systems’ sale of a large California solar project to NRG, SunPower Systems owes NRG $75.0 million in connection with certain tax benefits associated with the project that were approved by the Treasury Department for an amount that was less than expected. The Company does not believe that the facts support NRG’s claim under the operative indemnification provisions and is vigorously contesting the claim.  Additionally, SunPower Systems filed a cross-complaint against NRG seeking damages in excess of $7.5 million for breach of contract and related claims arising from NRG’s failure to fulfill its obligations under the contract, including its obligation to take “reasonable, available steps” to engage the Treasury Department.  The Company is currently unable to determine if the resolution of this matter will have a material effect on the Company's consolidated financial statements. 

Class Action and Derivative Suits

On August 16, 2016 and August 26, 2016, two securities class action lawsuits were filed against the Company and certain of its officers and directors (the "Defendants") in the United States District Court for the Northern District of California on behalf of a class consisting of those who acquired the Company's securities from February 17, 2016 through August 9, 2016 (the "Class Period"). The substantially identical complaints allege violations of Sections 10(b) and 20(a) of the Exchange Act,

123

Table of Contents


15 U.S.C. §§78j(b) and 78t(a) and SEC Rule 10b-5, 17 C.F.R. §240.10b-5. The complaints were filed following the issuance of the Company's August 9, 2016 earnings release and revised guidance and generally allege that throughout the Class Period, Defendants made materially false and/or misleading statements and failed to disclose material adverse facts about the Company’s business, operations, and prospects. On December 9, 2016, the court consolidated the cases and appointed a lead plaintiff.

Four shareholder derivative actions have been filed in federal court, purporting to be brought on the Company's behalf against certain of the Company's current and former officers and directors based on the same events alleged in the securities class action lawsuits described above. The Company is named as a nominal defendant. The plaintiffs assert claims for alleged breaches of fiduciary duties, unjust enrichment, and waste of corporate assets for the period February 2016 through the present and generally allege that the defendants made or caused the Company to make materially false and/or misleading statements and failed to disclose material adverse facts about the Company’s business, operations, and prospects. The plaintiffs also claim that the alleged conduct is a breach of the Company's Code of Business Conduct and Ethics, and that defendants, including members of the Company's Audit Committee, breached their fiduciary duties by failing to ensure the adequacy of the Company's internal controls, and by causing or allowing the Company to disseminate false and misleading statements in the Company’s SEC filings and other disclosures. The securities class action lawsuits and the federal derivative actions have all been related by the Court and assigned to one judge.

Shareholder derivative actions purporting to be brought on the Company’s behalf were brought in the Superior Court of California for the County of Santa Clara against certain of the Company’s current and former officers and directors based on the same events alleged in the securities class action and federal derivative lawsuits described above, and alleging breaches of fiduciary duties.

The Company is currently unable to determine if the resolution of these matters will have a material adverse effect on the Company's financial position, liquidity, or results of operations.

First Philec Arbitration

On January 28, 2015, an arbitral tribunal of the International Court of Arbitration of the International Chamber of Commerce issued a first partial award in the matter of an arbitration between First Philippine Electric Corporation ("FPEC") and First Philippine Solar Corporation ("FPSC") against SunPower Philippines Manufacturing, Ltd. ("SPML"), our wholly-owned subsidiary. FPSC was a joint venture of FPEC and SPML for the purpose of slicing silicon wafers from ingots. The tribunal found SPML in breach of its obligations under its supply agreement with FPSC, and in breach of its joint venture agreement with FPEC. In its first partial award, the tribunal ordered that (i) SPML must purchase FPEC’s interests in FPSC for an aggregate of $30.3 million, and (ii) after completing the purchase of FPEC’s controlling interest in FPSC, SPML must pay FPSC damages in the amount of $25.2 million. The arbitral tribunal issued its second partial award dated July 14, 2015, which ordered that (i) the price payable by SPML to FPEC for its interests in FPSC be reduced from $30.3 million to $23.2 million, (ii) FPEC’s request for interest is refused, and (iii) the payment and transfer of shares between FPEC and SPML is to take place in accordance with the procedure agreed between the parties. The tribunal issued its final award dated September 30, 2015, which ordered that (i) each side should bear its own costs and attorneys' fees, and (ii) the arbitration costs should be split between the parties evenly.

SPML had filed a challenge to both the first and second partial awards, as well as the final award, with the High Court in Hong Kong. SPML had also filed applications to the Court in the Philippines to: (i) prevent FPSC or FPEC from enforcing the awards pending the outcome of the challenge in Hong Kong; and (ii) gain access to FPSC’s books and records. The application for access was granted, and the application to prevent enforcement of the award had not been ruled on as of the time the proceedings were discontinued as a result of the settlement described below.

On July 22, 2016, SPML entered into an agreement (the “Compromise Agreement”) with FPEC and FPSC to settle all claims, counterclaims, disputes, and proceedings between FPEC and FPSC on the one hand, and SPML on the other hand. All legal proceedings that are pending between the parties in Hong Kong and in the Philippines have been discontinued, terminated and dismissed. Pursuant to the terms of the Compromise Agreement, on July 22, 2016, SPML paid a total of $50.5 million to FPSC and FPEC in settlement of all claims between the parties. Also pursuant to the Compromise Agreement, SPML transferred all of its shares in FPSC to FPEC.

AUO Arbitration

On April 17, 2015, SunPower Technology Ltd. ("SPTL"), a wholly-owned subsidiary, commenced an arbitration before the ICC International Court of Arbitration against AUO and AU Optronics Corporation, the ultimate parent company of AUO

124

Table of Contents


("AUO Corp.," and together with AUO, the “AUO Group”), for breaches of the AUOSP Joint Venture Agreement and associated agreements (the "JVA").  SPTL’s claim alleged that, among other things, the AUO Group had sold solar modules containing cells manufactured by AUOSP in violation of provisions in the JVA that set geographical restrictions on sales activities as well as provisions that restrict each party’s use of the other’s confidential information. SPTL sought approximately $23.0 million in damages, as well as the right to purchase AUO's shares in AUOSP at 70% of “fair market value” determined as provided under the JVA.

On June 23, 2015, the AUO Group filed and served its formal Memorial of Claim and Counterclaims against SPTL and the Company (collectively, the "SunPower Group").  In its counterclaim, the AUO Group alleged breach of contract, breach of covenant of good faith and fair dealing, several tort causes of action, and improper use of the AUO Group’s proprietary manufacturing expertise.  The AUO Group sought $20.0 million in lost profits and $48.0 million in disgorgement from the SunPower Group, and an order requiring SPTL to purchase AUO’s shares in AUOSP at 150% of “fair market value” determined as provided under the JVA.

On September 19, 2016, the SunPower Group entered into a full and final settlement agreement (the “Settlement Agreement”) with the AUO Group to settle all claims, demands, damages, actions, causes of action, or suits between them, including but not limited to the arbitration before the ICC International Court of Arbitration. Pursuant to the Settlement Agreement, SunPower acquired AUO's shares in AUOSP on September 29, 2016 in accordance with the Stock Purchase Agreement (see Note 3). No monetary amounts specifically related to the arbitration were exchanged between the parties as a result of the Settlement Agreement.

Other Litigation

The Company is also a party to various other litigation matters and claims that arise from time to time in the ordinary course of its business. While the Company believes that the ultimate outcome of such matters will not have a material adverse effect on the Company, their outcomes are not determinable and negative outcomes may adversely affect the Company's financial position, liquidity, or results of operations.

Note 10. EQUITY METHOD INVESTMENTS

As of January 1, 2017 and January 3, 2016, the Company's carrying value of its equity method investments totaled $(6.9) million and $186.4 million, respectively, and is classified as "Other long-term assets" in its Consolidated Balance Sheets. These balances include the carrying value of the Company's investment in the 8point3 Group, which had a negative value of $60.6 million and $30.9 million as of January 1, 2017 and January 3, 2016, respectively (see below). The Company's share of its earnings (loss) from equity method investments is reflected as "Equity in earnings of unconsolidated investees" in its Consolidated Statements of Operations.

Equity Investment and Joint Venture with AUOSP

In fiscal 2010, the Company, AUO and AUO Corp. formed the joint venture AUOSP. On September 29, 2016, the Company completed its acquisition of AUOSP pursuant to the Stock Purchase agreement, under which the Company acquired 100% of the voting equity interest in AUOSP (see Note 3). Prior to the acquisition, the Company and AUO each owned 50% of the equity in AUOSP. AUOSP owns a solar cell manufacturing facility in Malaysia and manufactures solar cells and, prior to the acquisition, sold them on a "cost-plus" basis to the Company and AUO.

In connection with the joint venture agreement, the Company and AUO also entered into licensing and joint development, supply, and other ancillary transaction agreements. Through the licensing agreement, the Company and AUO licensed to AUOSP, on a non-exclusive, royalty-free basis, certain background intellectual property related to solar cell manufacturing (in the case of the Company) and manufacturing processes (in the case of AUO). Under the seven-year supply agreement with AUOSP, renewable by the Company for one-year periods thereafter, the Company was committed to purchase 80% of AUOSP's total annual output allocated on a monthly basis to the Company. The Company and AUO had the right to reallocate supplies from time to time under a written agreement. In fiscal 2010, the Company and AUOSP entered into an agreement under which the Company would resell to AUOSP polysilicon purchased from a third-party supplier and AUOSP would provide prepayments to the Company related to such polysilicon, which prepayment would then be made by the Company to the third-party supplier. In connection with the transactions contemplated under the Stock Purchase Agreement, the Company and AUOSP terminated certain agreements, including the agreements described in this paragraph (see Note 3).

Prior to the acquisition, the Company had concluded that it was not the primary beneficiary of AUOSP since, although the Company and AUO were both obligated to absorb losses or had the right to receive benefits, the Company alone did not

125

Table of Contents


have the power to direct the activities of AUOSP that most significantly impacted its economic performance. In making this determination, the Company considered the shared power arrangement, including equal board governance for significant decisions, elective appointment, and the fact that both parties contributed to the activities that most significantly impacted the joint venture's economic performance. Prior to the acquisition, the Company accounted for its investment in AUOSP using the equity method as a result of the shared power arrangement. As a result of the acquisition, AUOSP became a consolidated subsidiary of the Company and the results of operations of AUOSP have been included in the Consolidated Statement of Operations of the Company since September 29, 2016. Up until the acquisition date of September 29, 2016, the Company's maximum exposure to loss as a result of its equity investment in AUOSP was limited to the carrying value of the investment. As of January 1, 2017 and January 3, 2016, the Company's investment in AUOSP had a carrying value of zero and $202.3 million, respectively.

Equity Investment in Huaxia CPV (Inner Mongolia) Power Co., Ltd. ("CCPV")

In December 2012, the Company entered into an agreement with Tianjin Zhonghuan Semiconductor Co. Ltd., Inner Mongolia Power Group Co. Ltd. and Hohhot Jinqiao City Development Company Co., Ltd. to form CCPV, a jointly owned entity to manufacture and deploy the Company's LCPV concentrator technology in Inner Mongolia and other regions in China. CCPV is based in Hohhot, Inner Mongolia. The establishment of the entity was subject to approval of the Chinese government, which was received in the fourth quarter of fiscal 2013. In December 2013, the Company made a $16.4 million equity investment in CCPV, for a 25% equity ownership.

The Company has concluded that it is not the primary beneficiary of CCPV since, although the Company is obligated to absorb losses and has the right to receive benefits, the Company alone does not have the power to direct the activities of CCPV that most significantly impact its economic performance. The Company accounts for its investment in CCPV using the equity method since the Company is able to exercise significant influence over CCPV due to its board position.

Equity Investment in Diamond Energy Pty Ltd. ("Diamond Energy")

In October 2012, the Company made a $3.0 million equity investment in Diamond Energy, an alternative energy project developer and clean electricity retailer headquartered in Melbourne, Australia, in exchange for a 25% equity ownership.

The Company has concluded that it is not the primary beneficiary of Diamond Energy since, although the Company is obligated to absorb losses and has the right to receive benefits, the Company alone does not have the power to direct the activities of Diamond that most significantly impact its economic performance. The Company accounts for its investment in Diamond using the equity method since the Company is able to exercise significant influence over Diamond due to its board position.

Equity Investment in 8point3 Energy Partners

In June 2015, 8point3 Energy Partners, a joint YieldCo vehicle formed by the Company and First Solar, Inc. ("First Solar" and, together with the Company, the "Sponsors") to own, operate and acquire solar energy generation assets, consummated its initial public offering ("IPO") and its Class A shares are now listed on the NASDAQ Global Select Market under the trading symbol “CAFD”.

Immediately after the IPO, the Company contributed a portfolio of solar generation assets (the "SPWR Projects") to 8point3 Operating Company, LLC ("OpCo"), 8point3 Energy Partners' primary operating subsidiary. In exchange for the SPWR Projects, the Company received cash proceeds of $371 million as well as equity interests in several 8point3 Energy Partners affiliated entities: primarily common and subordinated units representing a 40.7% stake in OpCo (since reduced to 36.5% via a secondary issuance of shares in fiscal 2016) and a 50.0% economic and management stake in 8point3 Holding Company, LLC (“Holdings”), the parent company of the general partner of 8point3 Energy Partners and the owner of incentive distribution rights (“IDRs”) in OpCo. Holdings, OpCo, 8point3 Energy Partners and their respective subsidiaries are referred to herein as the “8point3 Group.” Additionally, pursuant to a Right of First Offer Agreement between the Company and OpCo, the 8point3 Group has rights of first offer on interests in an additional portfolio of the Company’s solar energy projects that are currently contracted or are expected to be contracted before being sold by the Company to other parties (the “ROFO Projects”). In connection with the IPO, the Company also entered into O&M, asset management and management services agreements with the 8point3 Group. The services the Company provides under these agreements are priced consistently with market rates for such services and the agreements are terminable by the 8point3 Group for convenience.

The Company has concluded that it is not the primary beneficiary of the 8point3 Group or any of its individual subsidiaries since, although the Sponsors are both obligated to absorb losses or have the right to receive benefits, the Company

126

Table of Contents


alone does not have the power to direct the activities of the 8point3 Group that most significantly impact its economic performance. In making this determination the Company considered, among other factors, the equal division between the Sponsors of management rights in the 8point3 Group and the corresponding equal influence over its significant decisions, the role and influence of the independent directors on the board of directors of the general partner of 8point3 Energy Partners, and how both Sponsors contribute to the activities that most significantly impact the 8point3 Group's economic performance. The Company accounts for its investment in the 8point3 Group using the equity method because the Company determined that, notwithstanding the division of management and ownership interests between the Sponsors, the Company exercises significant influence over the operations of the 8point3 Group.

Future quarterly distributions from OpCo are subject to certain forbearance and subordination periods. During the forbearance period, the Sponsors agreed to forego any distributions declared on their common and subordinated units. The forbearance period ended during fiscal 2016 and the OpCo units held by the Company were entitled to distributions beginning in the fourth fiscal quarter of 2016. During the quarter ended January 1, 2017, the Company received $6.9 million in dividend distributions from the 8point3 Group.

During the subordination period, holders of the subordinated units are not entitled to receive any distributions until the common units have received their minimum quarterly distribution plus any arrearages in the payment of minimum distributions from prior quarters. Approximately 70% of the Company’s OpCo units are subject to subordination. The subordination period will end after OpCo has earned and paid minimum quarterly distributions for three years ending on or after August 31, 2018 and there are no outstanding arrearages on common units. Notwithstanding the foregoing, the subordination period could end after OpCo has earned and paid 150% of minimum quarterly distributions, plus the related distribution on the incentive distribution rights, for one year ending on or after August 31, 2016 and there are no outstanding arrearages on common units. At the end of the subordination period, all subordinated units will convert to common units on a one-for-one basis. The Company also, through its interests in Holdings, holds IDRs in OpCo, which represent rights to incremental distributions after certain distribution thresholds are met.

In June 2015, OpCo entered into a $525.0 million senior secured credit facility, consisting of a $300.0 million term loan facility, a $25.0 million delayed draw term loan facility, and a $200.0 million revolving credit facility (the “8point3 Credit Facility”). Proceeds from the term loan were used to make initial distributions to the Sponsors. The 8point3 Credit Facility is secured by a pledge of the Sponsors’ equity interests in OpCo. On September 30, 2016, OpCo entered into an amendment and joinder agreement under its existing senior secured credit facility, pursuant to which OpCo obtained a new $250.0 million incremental term loan facility, increasing the maximum borrowing capacity under the credit facility to $775.0 million.

Under relevant guidance for leasing transactions, the Company treated the portion of the sale of the residential lease portfolio originally sold to the 8point3 Group in connection with the IPO transaction, composed of operating leases and unguaranteed sales-type lease residual values, as a borrowing and reflected the cash proceeds attributable to this portion of the residential lease portfolio as liabilities recorded within “Accrued liabilities” and “Other long-term liabilities” in the Consolidated Balance Sheets (see Note 5). As of January 1, 2017 and January 3, 2016 the operating leases and the unguaranteed sales-type lease residual values which were sold to the 8point3 Group had an aggregate carrying value of $74 million and $78 million, respectively, on the Company's Consolidated Balance Sheets.

During fiscal 2016, the Company sold several ROFO Projects to 8point3 Energy Partners, including a noncontrolling interest in the 128 MW Henrietta utility-scale power plant in California (the "Henrietta Project") and controlling interests in the 60 MW Hooper utility-scale power plant in Colorado and several commercial projects. The Company accounted for these sales as partial sales of real estate and recognized revenue equal to total project costs when such projects reached their commercial operation date. No profit on these sales was recognized, as unconditional cash proceeds did not exceed total project costs, and such derecognition resulted in a net $45.9 million reduction in the carrying value of the Company’s investments in the 8point3 Group. Some of the commercial projects have not yet reached their commercial operation date and therefore, the Company continues to record these projects on its Consolidated Balance Sheet as of January 1, 2017. The net cash proceeds from the sales of these projects to the 8point3 Group as well as related proceeds from tax equity investors were classified as operating cash inflows in the Consolidated Statement of Cash Flows. In addition to the treatment above with respect to the transactions with the 8point3 Group, the sale of the controlling interest in the Henrietta project in the third quarter of fiscal 2016 was accounted for as a partial sale of real estate pursuant to which the Company recognized revenue equal to the sales value.

As of January 1, 2017 and January 3, 2016, the Company's investment in the 8point3 Group had a negative carrying value of $60.6 million and $30.9 million, respectively, resulting from the continued deferral of profit recognition for projects sold to the 8point3 Group that included the sale or lease of real estate. The Company owns approximately 29 million shares in OpCo as well as exchange rights to convert these shares on a 1:1 basis to the publicly traded Class A shares of 8point3 Energy

127

Table of Contents


Partners. Based on the closing stock price of Class A shares as of December 30, 2016, the final trading day prior to the end of the Company’s fiscal year, the Company’s investment in OpCo has a market value of $374.9 million.

Equity Investments in Project Entities

The Company has from time to time maintained noncontrolling interests in project entities, which may be accounted for as either cost or equity method investments depending on the magnitude of the Company’s investment and whether the Company exercises significant influence over the investee. The Company’s involvement in these entities primarily takes two forms: first, the Company may take a noncontrolling interest in an early-stage project and maintain that investment over the development cycle, often in situations in which the Company’s products are also sold to the entity under separate agreements. Second, the Company may retain a noncontrolling interest in a development project after a controlling interest is sold to a third party. In either form, the Company may maintain its investment for all or part of the operational life of the project or may seek to subsequently dispose of its investment. As of January 1, 2017, the Company’s investments in such projects have a carrying value of $45.5 million, of which $41.2 million is accounted for under the equity method and the remainder under the cost method. The majority of this balance relates to the Boulder Solar Project, which is a ROFO project that may be sold to the 8point3 Group in the future. As of January 3, 2016, the Company’s investments in such projects have a carrying value of $4.4 million, of which none is accounted for under the equity method and all under the cost method.
 
Summarized Financial Statements

The following table presents summarized financial statements for significant investees accounted for by the equity method, based on the investees' fiscal years and on information provided to the Company by the investee:

 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Summarized statements of operations information:
 
 
 
 
 
 
Revenue
 
$
61,197

 
$
480,106

 
$
463,275

Cost of sales and operating expenses
 
38,716

 
457,392

 
437,207

Net income
 
30,432

 
38,770

 
22,769

Net income attributable to the entity
 
156,793

 
140,969

 
22,769


 
 
Fiscal Year
(In thousands)

 
2016
 
2015
Summarized balance sheet information
 
 
 
 
Current assets
 
$
35,407

 
$
204,055

Long-term assets
 
1,299,656

 
1,488,418

Current liabilities
 
26,606

 
273,144

Long-term liabilities
 
398,192

 
315,574

Noncontrolling interests and redeemable noncontrolling interests
 
58,658

 
101,520


Related-Party Transactions with Investees:
 
 
As of
(In thousands)
 
January 1, 2017
 
January 3, 2016
Accounts receivable
 
$
3,397

 
$
32,389

Other long-term assets
 
$
723

 
$
1,455

Accounts payable
 
$

 
$
42,080

Accrued liabilities
 
$
3,665

 
$
9,952

Customer advances
 
$
57

 
$
710

Other long-term liabilities
 
$
29,370

 
$
29,389


128

Table of Contents


 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Payments made to investees for products/services
 
$
337,831

 
$
444,121

 
$
462,596

Revenues and fees received from investees for products/services1
 
$
317,314

 
$
47,019

 
$

1 
Includes a portion of proceeds received from tax equity investors in connection with 8point3 transactions.

Cost Method Investment in Tendril Networks, Inc.

In November 2014, the Company purchased $20.0 million of preferred stock constituting a minority stake in Tendril Networks, Inc. ("Tendril"), accounted for under the cost method because the preferred stock was deemed not to be in-substance common stock. In connection with the investment, the Company acquired warrants to purchase up to approximately 14 million shares of Tendril common stock exercisable through November 23, 2024. The number of shares of Tendril common stock that may be purchased pursuant to the warrants is subject to the Company's and Tendril's achievement of certain financial and operational milestones and other conditions.

In connection with the initial investment in Tendril, the Company also entered into commercial agreements with Tendril under a Master Services Agreement and related Statements of Work. Under these commercial agreements, Tendril will use up to $13.0 million of the Company's initial investment to develop, jointly with the Company, certain solar software solution products.

Note 11. DEBT AND CREDIT SOURCES

The following table summarizes the Company's outstanding debt on its Consolidated Balance Sheets:
 
 
January 1, 2017
 
January 3, 2016
(In thousands)
 
Face Value
 
Short-term
 
Long-term
 
Total
 
Face Value
 
Short-term
 
Long-term
 
Total
Convertible debt:
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
4.00% debentures due 2023
 
$
425,000

 
$

 
$
417,473

 
$
417,473

 
$
425,000

 
$

 
$
416,369

 
$
416,369

0.875% debentures due 2021
 
400,000

 

 
397,079

 
397,079

 
400,000

 

 
396,424

 
396,424

0.75% debentures due 2018
 
300,000

 

 
298,926

 
298,926

 
300,000

 

 
298,167

 
298,167

IFC mortgage loan
 
17,500

 
17,121

 

 
17,121

 
32,500

 
14,994

 
16,778

 
31,772

CEDA loan
 
30,000

 

 
28,191

 
28,191

 
30,000

 

 
27,778

 
27,778

Non-recourse financing and other debt1
 
477,594

 
52,892

 
419,905

 
472,797

 
435,963

 
4,642

 
429,981

 
434,623

 
 
$
1,650,094

 
$
70,013

 
$
1,561,574

 
$
1,631,587

 
$
1,623,463

 
$
19,636

 
$
1,585,497

 
$
1,605,133

1 
Other debt excludes payments related to capital leases, which are disclosed in Note 9.

As of January 1, 2017, the aggregate future contractual maturities of the Company's outstanding debt, at face value, were as follows:
(In thousands)
 
Fiscal 2017
 
Fiscal 2018
 
Fiscal 2019
 
Fiscal 2020
 
Fiscal 2021
 
Thereafter
 
Total
Aggregate future maturities of outstanding debt
 
69,799

 
324,725

 
13,825

 
16,432

 
417,531

 
807,782

 
$
1,650,094


Convertible Debt


129

Table of Contents


The following table summarizes the Company's outstanding convertible debt:
 
 
January 1, 2017
 
January 3, 2016
(In thousands)
 
Carrying Value
 
Face Value
 
Fair Value1
 
Carrying Value
 
Face Value
 
Fair Value1
Convertible debt:
 
 
 
 
 
 
 
 
 
 
 
 
4.00% debentures due 2023
 
$
417,473

 
$
425,000

 
$
301,555

 
$
416,369

 
$
425,000

 
$
515,903

0.875% debentures due 2021
 
397,079

 
400,000

 
266,996

 
396,424

 
400,000

 
340,500

0.75% debentures due 2018
 
298,926

 
300,000

 
270,627

 
298,167

 
300,000

 
396,792

 
 
$
1,113,478

 
$
1,125,000

 
$
839,178

 
$
1,110,960

 
$
1,125,000

 
$
1,253,195

1 
The fair value of the convertible debt was determined using Level 2 inputs based on quarterly market prices as reported by an independent pricing source.

The Company's outstanding convertible debentures are senior, unsecured obligations of the Company, ranking equally with all existing and future senior unsecured indebtedness of the Company.

4.00% Debentures Due 2023

In December 2015, the Company issued $425.0 million in principal amount of its 4.00% debentures due 2023. Interest is payable semi-annually, beginning on July 15, 2016. Holders may exercise their right to convert the debentures at any time into shares of the Company's common stock at an initial conversion price approximately equal to $30.53 per share, subject to adjustment in certain circumstances. If not earlier repurchased or converted, the 4.00% debentures due 2023 mature on January 15, 2023.

0.875% Debentures Due 2021

In June 2014, the Company issued $400.0 million in principal amount of its 0.875% debentures due 2021. Interest is payable semi-annually, beginning on December 1, 2014. Holders may exercise their right to convert the debentures at any time into shares of the Company's common stock at an initial conversion price approximately equal to $48.76 per share, subject to adjustment in certain circumstances. If not earlier repurchased or converted, the 0.875% debentures due 2021 mature on June 1, 2021.

0.75% Debentures Due 2018

In May 2013, the Company issued $300.0 million in principal amount of its 0.75% debentures due 2018. Interest is payable semi-annually, beginning on December 1, 2013. Holders may exercise their right to convert the debentures at any time into shares of the Company's common stock at an initial conversion price approximately equal to $24.95 per share, subject to adjustment in certain circumstances. If not earlier repurchased or converted, the 0.75% debentures due 2018 mature on June 1, 2018.

4.50% Debentures Due 2015

In 2010, the Company issued $250.0 million in principal amount of its 4.50% senior cash convertible debentures ("4.50% debentures due 2015"). Interest was payable semi-annually, beginning on September 15, 2010. The 4.50% debentures due 2015 were convertible only into cash, and not into shares of the Company's common stock (or any other securities) at a conversion price of $22.53 per share. The 4.50% debentures due 2015 matured on March 15, 2015. During March 2015, the Company paid holders an aggregate of $324.3 million in cash in connection with the settlement of the outstanding 4.50% debentures due 2015. No 4.50% debentures due 2015 remained outstanding after the maturity date.

The embedded cash conversion option was a derivative instrument (derivative liability) that was required to be separated from the 4.50% debentures due 2015. The fair value of the derivative liability is classified within "Other long-term liabilities" on the Company's Consolidated Balance Sheets. Changes in the fair value of the derivative liability were reported in the Company's Consolidated Statements of Operations until the 4.50% debentures due 2015 matured in March 2015.

During fiscal 2015, the Company recognized a non-cash loss of $52.0 million, recorded in "Other, net" in the Company's Consolidated Statements of Operations to recognize the change in fair value prior to the expiration of the embedded cash conversion option. During fiscal 2014, the Company recognized a non-cash loss of $58.5 million, recorded in "Other, net" in

130

Table of Contents


the Company's Consolidated Statement of Operations related to the change in fair value of the embedded cash conversion option.

In fiscal 2016, 2015 and 2014, the Company recognized zero, $4.3 million, and $19.8 million of non-cash interest expense, respectively, related to the amortization of the debt discount on the 4.50% debentures.

Call Spread Overlay with Respect to 4.50% Debentures

Concurrently with the issuance of the 4.50% debentures due 2015, the Company entered into privately-negotiated convertible debenture hedge transactions (collectively, the "4.50% Bond Hedge") and warrant transactions (collectively, the "4.50% Warrants" and together with the 4.50% Bond Hedge, the “CSO2015” transactions), with certain of the initial purchasers of the 4.50% debentures due 2015 or their affiliates. The CSO2015 transactions represented a call spread overlay with respect to the 4.50% debentures due 2015, whereby the cost of the 4.50% Bond Hedge purchased by the Company to cover the cash outlay upon conversion of the debentures was reduced by the sales prices of the 4.50% Warrants. The transactions effectively reduced the Company's potential payout over the principal amount on the 4.50% debentures due 2015 upon conversion of the 4.50% debentures due 2015.

Under the terms of the 4.50% Bond Hedge, the Company bought options to acquire, at an exercise price of $22.53 per share, subject to customary adjustments for anti-dilution and other events, cash in an amount equal to the market value of up to 11.1 million shares of the Company's common stock.

Each 4.50% Bond Hedge was a separate transaction, entered into by the Company with each counterparty, and was not part of the terms of the 4.50% debentures due 2015. The 4.50% Bond Hedge, which was indexed to the Company's common stock, was a derivative instrument that required mark-to-market accounting treatment due to the cash settlement features until the 4.50% Bond Hedge settled in March 2015. During March 2015, the Company exercised its rights under the 4.50% Bond Hedge, resulting in a payment to the Company of $74.6 million.

During fiscal 2015, the Company recognized a non-cash gain of $52.0 million, recorded in "Other, net" in the Company's Consolidated Statements of Operations related to recognize the change in fair value before settlement of the 4.50% Bond Hedge. During fiscal 2014, the Company recognized a non-cash gain of $58.5 million, recorded in "Other, net" in the Company's Consolidated Statement of Operations related to the change in fair value of the 4.50% Bond Hedge.

In connection with the 4.50% Warrants, the Company entered into warrant confirmations (collectively, and as amended from time to time, the “2015 Warrant Confirms”) with Deutsche Bank AG, London Branch, Bank of America, N.A., Barclays Bank PLC and Credit Suisse International providing for the acquisition, subject to anti-dilution adjustments, of up to approximately 11.1 million shares of the Company's common stock via net share settlement. Each 4.50% Warrant transaction was a separate transaction, entered into by the Company with each counterparty, and was not part of the terms of the 4.50% debentures due 2015.

During the second quarter of fiscal 2015, the Company entered into separate partial unwind agreements with each of Deutsche Bank AG, London Branch; Bank of America, N.A.; Barclays Bank PLC; and Credit Suisse International in order to reduce the number of warrants issued pursuant to the 2015 Warrant Confirms. Pursuant to the terms of these partial unwind agreements, the Company issued an aggregate of approximately 3.0 million shares of common stock to settle all of the warrants under the 2015 Warrant Confirms. Accordingly, as of January 1, 2017, no 4.50% Warrants remained outstanding.

Other Debt and Credit Sources

Mortgage Loan Agreement with IFC

In May 2010, the Company entered into a mortgage loan agreement with IFC. Under the loan agreement, the Company borrowed $75.0 million and is required to repay the amount borrowed starting two years after the date of borrowing, in 10 equal semi-annual installments. The Company is required to pay interest of LIBOR plus 3% per annum on outstanding borrowings; a front-end fee of 1% on the principal amount of borrowings at the time of borrowing; and a commitment fee of 0.5% per annum on funds available for borrowing and not borrowed. The Company may prepay all or a part of the outstanding principal, subject to a 1% prepayment premium. The Company has pledged certain assets as collateral supporting its repayment obligations (see Note 5). As of both January 1, 2017 and January 3, 2016, the Company had restricted cash and cash equivalents of $9.2 million related to the IFC debt service reserve, which is the amount, as determined by IFC, equal to the aggregate principal and interest due on the next succeeding interest payment date. On January 17, 2017, the Company repaid the entire outstanding balance, and the associated interest, of the mortgage loan agreement with IFC (see Note 18).


131

Table of Contents


Loan Agreement with California Enterprise Development Authority ("CEDA")

In 2010, the Company borrowed the proceeds of the $30.0 million aggregate principal amount of CEDA's tax-exempt Recovery Zone Facility Revenue Bonds (SunPower Corporation - Headquarters Project) Series 2010 (the "Bonds") maturing April 1, 2031 under a loan agreement with CEDA. The Bonds mature on April 1, 2031, bear interest at a fixed rate of 8.50% through maturity, and include customary covenants and other restrictions on the Company.

Revolving Credit Facility with Credit Agricole

In July 2013, the Company entered into a revolving credit facility with Credit Agricole, as administrative agent, and certain financial institutions, under which the Company may borrow up to $250.0 million. On August 26, 2014, the Company entered into an amendment to the revolving credit facility that, among other things, extends the maturity date of the facility from July 3, 2016 to August 26, 2019 (the "Maturity Date"). Amounts borrowed may be repaid and reborrowed until the Maturity Date. On February 17, 2016, the Company entered into an amendment to the credit agreement, expanding the available borrowings under the revolving credit facility to $300.0 million and adding a $200.0 million letter of credit subfacility, subject to the satisfaction of certain conditions. The revolving credit facility includes representations, covenants, and events of default customary for financing transactions of this type.

The revolving credit facility was entered into in conjunction with the delivery by Total S.A. of a guarantee of the Company's obligations under the related facility. On January 31, 2014, as contemplated by the facility, (i) the Company's obligations under the facility became secured by a pledge of certain accounts receivable and inventory; (ii) certain of the Company's subsidiaries entered into guarantees of the facility; and (iii) Total S.A.'s guarantee of the Company's obligations under the facility expired.

After January 31, 2014, the Company is required to pay interest on outstanding borrowings and fees of (a) with respect to any LIBOR rate loan, an amount ranging from 1.50% to 2.00% (depending on the Company's leverage ratio from time to time) plus the LIBOR rate divided by a percentage equal to one minus the stated maximum rate of all reserves required to be maintained against "Eurocurrency liabilities" as specified in Regulation D; (b) with respect to any alternate base rate loan, an amount ranging from 0.50% to 1.00% (depending on the Company's leverage ratio from time to time) plus the greater of (1) the prime rate, (2) the Federal Funds rate plus 0.50%, and (3) the one-month LIBOR rate plus 1%; and (c) a commitment fee ranging from 0.25% to 0.35% (depending on the Company's leverage ratio from time to time) per annum on funds available for borrowing and not borrowed. The Company will be required to pay interest on letters of credit under the agreement of (a) with respect to any performance letter of credit, an amount ranging from 0.90% to 1.20% (depending on the Company’s leverage ratio from time to time); and (b) with respect to any other letter of credit, an amount ranging from 1.50% to 2.00% (depending on the Company’s leverage ratio from time to time).

As of January 1, 2017, the Company had $4.7 million of outstanding borrowings under the revolving credit facility, all of which were related to letters of credit. The Company had no outstanding borrowings under the revolving credit facility as of January 3, 2016.

August 2016 Letter of Credit Facility Agreement

In August 2016, the Company entered into a letter of credit facility with Banco Santander, S.A. which provides for the issuance, upon request by the Company, of letters of credit to support obligations of the Company in an aggregate amount not to exceed $85 million. As of January 1, 2017 and January 3, 2016, there were no letters of credit issued and outstanding under the facility with Banco Santander, S.A.

2016 Letter of Credit Facility Agreements

In June 2016, the Company entered into a Continuing Agreement for Standby Letters of Credit and Demand Guarantees with Deutsche Bank AG New York Branch and Deutsche Bank Trust Company Americas (the “2016 Non-Guaranteed LC Facility”) which provides for the issuance, upon request by the Company, of letters of credit to support the Company’s obligations in an aggregate amount not to exceed $50.0 million. The 2016 Non-Guaranteed LC Facility will terminate on June 29, 2018. As of January 1, 2017 and January 3, 2016, letters of credit issued and outstanding under the 2016 Non-Guaranteed LC Facility totaled $45.8 million and zero, respectively.

In June 2016, the Company entered into bilateral letter of credit facility agreements (the “2016 Guaranteed LC Facilities”) with Bank of Tokyo-Mitsubishi UFJ ("BTMU"), Credit Agricole, and HSBC USA Bank, National Association ("HSBC"). Each letter of credit facility agreement provides for the issuance, upon the Company’s request, of letters of credit

132

Table of Contents


by the issuing bank thereunder in order to support certain of the Company’s obligations until December 31, 2018. Payment of obligations under the 2016 Guaranteed Letter of Credit Facilities is guaranteed by Total S.A. pursuant to the Credit Support Agreement. Aggregate letter of credit amounts may be increased upon the agreement of the respective parties but, otherwise, may not exceed $75.0 million with BTMU, $75.0 million with Credit Agricole and $175.0 million with HSBC. Each letter of credit issued under one of the letter of credit facilities generally must have an expiration date, subject to certain exceptions, no later than the earlier of (a) two years from completion of the applicable project and (b) March 31, 2020.

In June 2016, in connection with the 2016 Guaranteed LC Facilities, the Company entered into a transfer agreement to transfer to the 2016 Guaranteed LC Facilities all existing outstanding letters of credit issued under the Company’s letter of credit facility agreement with Deutsche Bank AG New York Branch and Deutsche Bank Trust Company Americas, as administrative agent, and certain financial institutions, entered into in August 2011 and amended from time to time. In connection with the transfer of the existing outstanding letters of credit, the aggregate commitment amount under the August 2011 letter of credit facility was permanently reduced to zero on June 29, 2016. As of January 1, 2017 and January 3, 2016, letters of credit issued and outstanding under the August 2011 letter of credit facility with Deutsche Bank AG New York Branch totaled zero and $294.5 million, respectively. As of January 1, 2017 and January 3, 2016, letters of credit issued and outstanding under the 2016 Guaranteed LC Facilities totaled $244.8 million and zero, respectively.

September 2011 Letter of Credit Facility with Deutsche Bank and Deutsche Bank Trust Company Americas (together, "Deutsche Bank Trust")

In September 2011, the Company entered into a letter of credit facility with Deutsche Bank Trust which provides for the issuance, upon request by the Company, of letters of credit to support obligations of the Company in an aggregate amount not to exceed $200.0 million. Each letter of credit issued under the facility is fully cash-collateralized and the Company has entered into a security agreement with Deutsche Bank Trust, granting them a security interest in a cash collateral account established for this purpose.

As of January 1, 2017 and January 3, 2016, letters of credit issued and outstanding under the Deutsche Bank Trust facility totaled $3.1 million and $8.6 million, respectively, which were fully collateralized with restricted cash on the Consolidated Balance Sheets.

Revolving Credit Facility with Mizuho and Goldman Sachs

On May 4, 2016, the Company entered into a revolving credit facility (the “Construction Revolver”) with Mizuho Bank Ltd., as administrative agent, and Goldman Sachs Bank USA, under which the Company may borrow up to $200 million.  The Construction Revolver also includes a $100 million accordion feature.  Amounts borrowed under the facility may be repaid and reborrowed in support of the Company’s commercial and small scale utility projects in the United States until the May 4, 2021 maturity date. The facility includes representations, covenants, and events of default customary for financing transactions of this type.

Borrowings under the Construction Revolver bear interest at the applicable LIBOR rate plus 1.50% for the first two years, with the final year at LIBOR plus 1.75%. All outstanding indebtedness under the facility may be voluntarily prepaid in whole or in part without premium or penalty (with certain limitations to partial repayments), other than customary breakage costs. The facility is secured by the assets of, and equity in, the various project companies to which the borrowings relate, but is otherwise non-recourse to the Company and its other affiliates.

As of January 1, 2017 and January 3, 2016, the aggregate carrying value of the Construction Revolver totaled $10.5 million and zero, respectively.

Non-recourse Financing and Other Debt

In order to facilitate the construction, sale or ongoing operation of certain solar projects, including the Company's residential leasing program, the Company regularly obtains project-level financing. These financings are secured either by the assets of the specific project being financed or by the Company's equity in the relevant project entity and the lenders do not have recourse to the general assets of the Company for repayment of such debt obligations, and hence the financings are referred to as non-recourse. Non-recourse financing is typically in the form of loans from third-party financial institutions, but also takes other forms, including "partnership flip" structures, sale-leaseback arrangements, or other forms commonly used in the solar or similar industries. The Company may seek non-recourse financing covering solely the construction period of the solar project or may also seek financing covering part or all of the operating life of the solar project. The Company classifies

133

Table of Contents


non-recourse financings in the Consolidated Balance Sheets in accordance with their terms; however, in certain circumstances, the Company may repay or refinance these financings prior to stated maturity dates in connection with the sale of the related project or similar such circumstances. In addition, in certain instances, the customer may assume the loans at the time that the project entity is sold to the customer. In these instances, subsequent debt assumption is reflected as a financing outflow and operating inflow in the Consolidated Statements of Cash Flows to reflect the substance of the assumption as a facilitation of customer financing from a third party.

The following presents a summary of the Company's non-recourse financing arrangements, including arrangements that are not classified as debt:
 
 
Aggregate Carrying Value
 
 
(In thousands)
 
January 1, 2017
 
January 3, 2016
 
Balance Sheet Classification
Residential Lease Program
 
 
 
 
 
 
Bridge loans
 
$
6,718

 
$

 
Short-term debt and Long-term debt
Long-term loans
 
283,852

 
171,752

 
Short-term debt and Long-term debt
Financing arrangements with third parties
 
29,370

 
36,784

 
Accrued liabilities and Other long-term liabilities
Tax equity partnership flip facilities
 
183,109

 
128,594

 
Redeemable non-controlling interests in subsidiaries and Non-controlling interests in subsidiaries
 
 
 
 
 
 
 
Power Plant and Commercial Projects
 
 
 
 
 
 
Henrietta credit facility
 

 
216,691

 
Short-term debt and Long-term debt
Boulder I credit facility
 
28,775

 

 
Short-term debt and Long-term debt
El Pelicano credit facility
 
90,474

 

 
Long-term debt
Hooper credit facility
 

 
37,269

 
Short-term debt and Long-term debt
Construction Revolver
 
10,469

 

 
Long-term debt
Arizona loan
 
7,649

 
8,113

 
Short-term debt and Long-term debt

For the Company’s residential lease program, non-recourse financing is typically accomplished by aggregating an agreed-upon volume of solar power systems and leases with residential customers into a specific project entity. The Company has entered into the following non-recourse financings with respect to its residential lease program:

In fiscal 2016, the Company entered into bridge loans to finance solar power systems and leases under its residential lease program. The loans are repaid over terms ranging from two to seven years. Some loans may be prepaid without penalties at the Company's option at any time, while other loans may be prepaid, subject to a prepayment fee, after one year. During fiscal 2016, the Company had net proceeds of $5.7 million in connection with these loans. As of January 1, 2017, the aggregate carrying amount of these loans, presented in "Long-term debt" on the Company's Consolidated Balance Sheets, was $6.7 million.

The Company enters into long-term loans to finance solar power systems and leases under its residential lease program. The loans are repaid over their terms of between 17 and 18 years, and may be prepaid without penalty at the Company’s option beginning seven years after the original issuance of the loan. During fiscal 2016 and 2015, the Company had net proceeds of $111.8 million and $90.6 million, respectively, in connection with these loans. As of January 1, 2017, and January 3, 2016, the aggregate carrying amount of these loans, presented in "Short-term debt" and "Long-term debt" on the Company's Consolidated Balance Sheets, was $283.9 million and $171.8 million, respectively.

The Company has entered into multiple arrangements under which solar power systems are financed by third-party investors or customers, including by a legal sale of the underlying asset that is accounted for as a borrowing under relevant accounting guidelines as the requirements to recognize the transfer of the asset were not met. Under the terms of these arrangements, the third parties make an upfront payment to the Company, which the Company recognizes as a liability that will be reduced over the term of the arrangement as lease receivables and government incentives are received by the third party. As the liability is reduced, the Company makes a corresponding reduction in receivables. We use this approach to account for both operating and sales-type leases with our residential lease customers in our consolidated financial statements. During fiscal 2016 and 2015, the Company had net proceeds (repayments) of $28.5 million and $(32.0) million, respectively, in connection with these facilities. As of January 1, 2017, and January 3, 2016, the aggregate carrying amount of these facilities, presented in

134

Table of Contents


"Accrued liabilities" and "Other long-term liabilities" on the Company's Consolidated Balance Sheets, was $29.4 million and $36.8 million, respectively (see Note 5).

The Company also enters into facilities with third-party tax equity investors under which the investors invest in a structure known as a partnership flip. The Company holds controlling interests in these less-than-wholly-owned entities and therefore fully consolidates these entities. The Company accounts for the portion of net assets in the consolidated entities attributable to the investors as noncontrolling interests in its consolidated financial statements. Noncontrolling interests in subsidiaries that are redeemable at the option of the noncontrolling interest holder are classified accordingly as redeemable, between liabilities and equity on the Company's Consolidated Balance Sheets. During fiscal 2016 and 2015, the Company had net contributions of $127.3 million and $170.6 million, respectively, under these facilities and attributed losses of $74.9 million and $111.5 million, respectively, to the non-controlling interests corresponding principally to certain assets, including tax credits, which were allocated to the non-controlling interests during the periods. As of January 1, 2017 and January 3, 2016, the aggregate carrying amount of these facilities, presented in “Redeemable non-controlling interests in subsidiaries” and “Non-controlling interests in subsidiaries” on the Company’s Consolidated Balance Sheets, was $183.1 million and $128.6 million, respectively.

For the Company’s power plant and commercial solar projects, non-recourse financing is typically accomplished using an individual solar power system or a series of solar power systems with a common end customer, in each case owned by a specific project entity. The Company has entered into the following non-recourse financings with respect to its power plant and commercial projects:

In fiscal 2016, the Company entered into the Construction Revolver credit facility to support the construction of the Company’s commercial and small scale utility projects in the United States. During fiscal 2016, we had net proceeds of $9.9 million in connection with the facility. As of January 1, 2017, the aggregate carrying amount of the Construction Revolver, presented in "Short-term debt" and "Long-term debt" on the Company's Consolidated Balance Sheets, was $10.5 million.

In fiscal 2016, the Company entered into a long-term credit facility to finance the 125 MW utility-scale Boulder power plant project in Nevada. During fiscal 2016, the Company had net proceeds of $21.9 million in connection with the facility. As of January 1, 2017, the aggregate carrying amount of this facility, presented in "Short-term debt" and "Long-term debt" on the Company's Consolidated Balance Sheets, was $28.8 million.

In fiscal 2016, the Company entered into a short-term credit facility to finance the utility-scale Rio Bravo power plant projects in California, with an aggregate size of approximately 50 MW. During fiscal 2016, in connection with the sale of the project, the Company repaid the full amount outstanding, and as a result, the Company had net proceeds of $114.8 million and net repayments of $117.6 million in connection with the facility. As of January 1, 2017, the aggregate carrying amount of this facility, presented in "Short-term debt" on the Company's Consolidated Balance Sheets, was zero.

In fiscal 2016, the Company entered into a short-term credit facility to finance the 20 MW utility-scale Wildwood power plant project in California. During fiscal 2016, in connection with the sale of the project, the Company repaid the full amount outstanding, and as a result, the Company had net proceeds of $44.5 million and net repayments of $45.6 million in connection with the facility. As of January 1, 2017, the aggregate carrying amount of this facility, presented in "Short-term debt" on the Company's Consolidated Balance Sheets, was zero.

In fiscal 2016, the Company entered into a long-term credit facility to finance several related utility-scale power plant projects in California, including the Stanford and Turlock projects, with an aggregate size of approximately 350 MW. During fiscal 2016, in connection with the sale of the project, the Company repaid the full amount outstanding, and as a result, the Company had net proceeds of $192.2 million and net repayments of $201.6 million in connection with the facility. As of January 1, 2017, the aggregate carrying amount of this facility, presented in "Short-term debt" and "Long-term debt" on the Company's Consolidated Balance Sheets, was zero.

In fiscal 2016, the Company entered into a long-term credit facility to finance the 111 MW utility-scale El Pelicano power plant project in Chile. During fiscal 2016, the Company had net proceeds of $84.6 million in connection with the facility. As of January 1, 2017, the aggregate carrying amount of this facility, presented in "Long-term debt" on the Company's Consolidated Balance Sheets, was $90.5 million.

In fiscal 2015, the Company entered into a long-term credit facility to finance the 128 MW utility-scale Henrietta power plant in California. During fiscal 2016, in connection with the sale of the project, the Company repaid the full amount outstanding, and as a result, the Company had net repayments of $216.7 million in connection with the facility. As of

135

Table of Contents


January 1, 2017 and January 3, 2016, the aggregate carrying amount of this loan, presented in "Short-term debt" and "Long-term debt" on the Company's Consolidated Balance Sheets, was zero and $216.7 million, respectively.

In fiscal 2015, the Company entered into a long-term credit facility to finance the 60 MW Hooper utility-scale power plant in Colorado. In the first quarter of fiscal 2016, the Company repaid the full amount outstanding. During fiscal 2016, the Company had net repayments of $37.3 million, in connection with the facility. As of January 1, 2017 and January 3, 2016, the carrying amount of this facility, presented in "Long-term debt" on the Company's Consolidated Balance Sheets, was zero and $37.3 million, respectively.

In fiscal 2013, the Company entered into a long-term loan agreement to finance a 5.4 MW utility and power plant operating in Arizona. As of January 1, 2017 and January 3, 2016, the aggregate carrying amount under this loan, presented in "Short-term debt" and "Long-term debt" on the Company's Consolidated Balance Sheets, was $7.6 million, and $8.1 million, respectively.

Other debt is further composed of non-recourse project loans in EMEA, which are scheduled to mature through 2028.

See Note 6 for discussion of the Company’s sale-leaseback arrangements accounted for under the financing method.

Note 12. DERIVATIVE FINANCIAL INSTRUMENTS

The following tables present information about the Company's hedge instruments measured at fair value on a recurring basis as of January 1, 2017 and January 3, 2016, all of which utilize Level 2 inputs under the fair value hierarchy:

(In thousands)
 
Balance Sheet Classification
 
January 1, 2017
 
January 3, 2016
Assets:
 
 
 
 
 
 
Derivatives designated as hedging instruments:
 
 
 
 
 
 
Foreign currency option contracts
 
 Prepaid expenses and other current assets
 
$
1,711

 
$

 
 
 
 
$
1,711

 
$

Derivatives not designated as hedging instruments:
 
 
 
 
 
 
Foreign currency option contracts
 
 Prepaid expenses and other current assets
 
$
1,076

 
$

Foreign currency forward exchange contracts
 
 Prepaid expenses and other current assets
 
2,015

 
8,734

Interest rate contracts
 
Other long-term assets
 
$
11,429

 
$

 
 
 
 
$
14,520

 
$
8,734

 
 
 
 
 
 
 
Liabilities:
 
 
 
 
 
 
Derivatives designated as hedging instruments:
 
 
 
 
 
 
Foreign currency option contracts
 
Accrued liabilities
 
$
71

 
$

Foreign currency forward exchange contracts
 
Accrued liabilities
 

 
141

Interest rate contracts
 
Other long-term liabilities
 
448

 
583

 
 
 
 
$
519

 
$
724

 
 
 
 
 
 
 
Derivatives not designated as hedging instruments:
 
 
 
 
 
 
Foreign currency option contracts
 
Accrued liabilities
 
$
15

 
$

Foreign currency forward exchange contracts
 
Accrued liabilities
 
1,937

 
2,175

Interest rate contracts
 
Other long-term liabilities
 

 
450

 
 
 
 
$
1,952

 
$
2,625



136

Table of Contents


 
 
January 1, 2017
 
 
 
 
 
 
 
 
Gross Amounts Not Offset in the Consolidated Balance Sheets, but Have Rights to Offset
 
 
(In thousands)
 
Gross Amounts Recognized
 
Gross Amounts Offset
 
Net Amounts Presented
 
Financial Instruments
 
Cash Collateral
 
Net Amounts
Derivative assets
 
$
16,231

 
$

 
$
16,231

 
$
1,694

 
$

 
$
14,537

Derivative liabilities
 
$
2,471

 
$

 
$
2,471

 
$
1,694

 
$

 
$
777


 
 
January 3, 2016
 
 
 
 
 
 
 
 
Gross Amounts Not Offset in the Consolidated Balance Sheets, but Have Rights to Offset
 
 
(In thousands)
 
Gross Amounts Recognized
 
Gross Amounts Offset
 
Net Amounts Presented
 
Financial Instruments
 
Cash Collateral
 
Net Amounts
Derivative assets
 
$
8,734

 
$

 
$
8,734

 
$
2,316

 
$

 
$
6,418

Derivative liabilities
 
$
3,349

 
$

 
$
3,349

 
$
2,316

 
$

 
$
1,033


The following table summarizes the pre-tax amount of unrealized gain or loss recognized in "Accumulated other comprehensive income" ("OCI") in "Stockholders' equity" in the Consolidated Balance Sheets:
 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Derivatives designated as cash flow hedges:
 
 
 
 
 
 
Gain (loss) in OCI at the beginning of the period
 
$
5,942

 
$
(1,443
)
 
$
(805
)
Unrealized gain (loss) recognized in OCI (effective portion)
 
2,626

 
12,129

 
(255
)
Less: Loss (gain) reclassified from OCI to revenue (effective portion)
 
(7,365
)
 
(4,744
)
 
(383
)
Net gain (loss) on derivatives
 
$
(4,739
)
 
$
7,385

 
$
(638
)
Gain (loss) in OCI at the end of the period
 
$
1,203

 
$
5,942

 
$
(1,443
)

The following table summarizes the amount of gain or loss recognized in "Other, net" in the Consolidated Statements of Operations in the years ended January 1, 2017, January 3, 2016 and December 28, 2014:
 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Derivatives designated as cash flow hedges:
 
 
 
 
 
 
Gain (loss) recognized in "Other, net" on derivatives (ineffective portion and amount excluded from effectiveness testing)
 
$
(1,069
)
 
$
(1,925
)
 
$
704

Derivatives not designated as hedging instruments:
 
 
 
 
 
 
Gain (loss) recognized in "Other, net"
 
$
(6,964
)
 
$
4,146

 
$
6,463


Foreign Currency Exchange Risk

Designated Derivatives Hedging Cash Flow Exposure

The Company's cash flow exposure primarily relates to anticipated third-party foreign currency revenues and expenses and interest rate fluctuations. To protect financial performance, the Company enters into foreign currency forward and option

137

Table of Contents


contracts designated as cash flow hedges to hedge certain forecasted revenue transactions denominated in currencies other than their functional currencies.
 
As of January 1, 2017, the Company had designated outstanding cash flow hedge option contracts with an aggregate notional value of $17.3 million. As of January 3, 2016, the Company had designated outstanding cash flow hedge forward contracts with an aggregate notional value of $23.6 million. The Company designates either gross external or intercompany revenue up to its net economic exposure. These derivatives have a maturity of 12 months or less and consist of foreign currency option and forward contracts. The effective portion of these cash flow hedges is reclassified into revenue when third-party revenue is recognized in the Consolidated Statements of Operations.

Non-Designated Derivatives Hedging Transaction Exposure

Derivatives not designated as hedging instruments consist of forward and option contracts used to hedge re-measurement of foreign currency denominated monetary assets and liabilities primarily for intercompany transactions, receivables from customers, and payables to third parties. Changes in exchange rates between the Company's subsidiaries' functional currencies and the currencies in which these assets and liabilities are denominated can create fluctuations in the Company's reported consolidated financial position, results of operations and cash flows. As of January 1, 2017, to hedge balance sheet exposure, the Company held options contracts and forward contracts with an aggregate notional value of $11.0 million and $42.9 million, respectively. The maturity dates of these contracts range from January 2017 to June 2017. As of January 3, 2016, to hedge balance sheet exposure, the Company held forward contracts with an aggregate notional value of $12.1 million. The maturity dates of these contracts ranged from December 2015 to April 2016.

Interest Rate Risk

The Company also enters into interest rate swap agreements to reduce the impact of changes in interest rates on its project specific non-recourse floating rate debt. As of January 1, 2017 and January 3, 2016, the Company had interest rate swap agreements designated as cash flow hedges with an aggregate notional value of $7.6 million and $8.1 million, respectively, and interest rate swap agreements not designated as cash flow hedges with an aggregate notional value of $170.3 million and zero, respectively. These swap agreements allow the Company to effectively convert floating-rate payments into fixed rate payments periodically over the life of the agreements. These derivatives have a maturity of more than 12 months. The effective portion of these swap agreements designated as cash flow hedges is reclassified into interest expense when the hedged transactions are recognized in the Consolidated Statements of Operations. The Company analyzes its designated interest rate swaps quarterly to determine if the hedge transaction remains effective or ineffective. The Company may discontinue hedge accounting for interest rate swaps prospectively if certain criteria are no longer met, the interest rate swap is terminated or exercised, or if the Company elects to remove the cash flow hedge designation. If hedge accounting is discontinued, and the forecasted hedged transaction is considered possible to occur, the previously recognized gain or loss on the interest rate swaps will remain in accumulated other comprehensive loss and will be reclassified into earnings during the same period the forecasted hedged transaction affects earnings or is otherwise deemed improbable to occur. All changes in the fair value of non-designated interest rate swap agreements are recognized immediately in current period earnings.

Credit Risk

The Company's option and forward contracts do not contain any credit-risk-related contingent features. The Company is exposed to credit losses in the event of nonperformance by the counterparties to these option and forward contracts. The Company enters into derivative contracts with high-quality financial institutions and limits the amount of credit exposure to any single counterparty. In addition, the Company continuously evaluates the credit standing of its counterparties.
 
Note 13. INCOME TAXES

The geographic distribution of income (loss) from continuing operations before income taxes and equity earnings of unconsolidated investees and the components of provision for income taxes are summarized below:

138

Table of Contents


 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Geographic distribution of income (loss) from continuing operations before income taxes and equity in earnings of unconsolidated investees:
 
 
 
 
 
 
U.S. income (loss)
 
$
(696,232
)
 
$
(222,688
)
 
$
183,412

Non-U.S. income (loss)
 
131,637

 
(19,623
)
 
1,202

Income (loss) before income taxes and equity in earnings (loss) of unconsolidated investees
 
$
(564,595
)
 
$
(242,311
)
 
$
184,614

Provision for income taxes:
 
 
 
 
 
 
Current tax benefit (expense)
 
 
 
 
 
 
Federal
 
$
(6,843
)
 
$
(43,676
)
 
$
141

State
 
9,254

 
(22,143
)
 
3,554

Foreign
 
(19,073
)
 
(2,009
)
 
(16,571
)
Total current tax expense
 
$
(16,662
)
 
$
(67,828
)
 
$
(12,876
)
Deferred tax benefit (expense)
 
 
 
 
 
 
Federal
 
$
3,286

 
$
1,278

 
$
2,797

State
 
6,819

 

 
10

Foreign
 
(762
)
 
(144
)
 
1,309

Total deferred tax benefit (expense)
 
9,343

 
1,134

 
4,116

Provision for income taxes
 
$
(7,319
)
 
$
(66,694
)
 
$
(8,760
)

The provision for income taxes differs from the amounts obtained by applying the statutory U.S. federal tax rate to income before taxes as shown below:

 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Statutory rate
 
35
%
 
35
%
 
35
%
Tax benefit (expense) at U.S. statutory rate
 
$
197,608

 
$
84,809

 
$
(64,614
)
Foreign rate differential
 
24,932

 
(9,676
)
 
(15,387
)
State income taxes, net of benefit
 
(329
)
 
(21,547
)
 
2,180

Return to provision adjustments
 
10,784

 

 

Deemed foreign dividend
 

 
(16,618
)
 
(4,625
)
Tax credits (investment tax credit and other)
 
6,396

 
19,723

 
9,262

Change in valuation allowance
 
(189,245
)
 
(164,236
)
 
47,768

Unrecognized tax benefits
 
(42,697
)
 
(20,634
)
 
1,948

Non-controlling interest income
 
17,183

 
14,353

 
11,052

Goodwill impairment
 
(20,236
)
 

 

Domestic production activity
 

 
10,262

 

Transfer Pricing Adjustment
 

 
(6,304
)
 

Intercompany profit deferral
 
(4,933
)
 
49,705

 
4,721

Other, net
 
(6,782
)
 
(6,531
)
 
(1,065
)
Total
 
$
(7,319
)
 
$
(66,694
)
 
$
(8,760
)


139

Table of Contents


 
 
As of
(In thousands)
 
January 1, 2017
 
January 3, 2016
Deferred tax assets:
 
 
 
 
Net operating loss carryforwards
 
$
209,431

 
$
61,021

Tax credit carryforwards
 
6,898

 
595

Reserves and accruals
 
187,250

 
196,926

Stock-based compensation stock deductions
 
24,357

 
19,293

Outside basis difference on investment in 8point3
 
108,941

 
136,269

Basis difference on third-party project sales
 
148,636

 

Other
 
(331
)
 
846

Total deferred tax asset
 
685,182

 
414,950

Valuation allowance
 
(497,236
)
 
(268,671
)
Total deferred tax asset, net of valuation allowance
 
187,946

 
146,279

Deferred tax liabilities:
 
 
 
 
Foreign currency derivatives unrealized gains
 
(574
)
 
(747
)
Other intangible assets and accruals
 
(13,908
)
 
(23,950
)
Fixed asset basis difference
 
(149,380
)
 
(116,089
)
Other
 
(10,866
)
 

Total deferred tax liabilities
 
(174,728
)
 
(140,786
)
Net deferred tax asset
 
$
13,218

 
$
5,493


As of January 1, 2017, the Company had federal net operating loss carryforwards of $480 million for tax purposes. These federal net operating loss carryforwards will expire at various dates from 2028 to 2036. As of January 1, 2017, the Company had California state net operating loss carryforwards of approximately $438.5 million for tax purposes, of which $40.4 million relate to stock deductions and $39.7 million relate to debt issuance, both of which will benefit equity when realized.  These California net operating loss carryforwards will expire at various dates from 2029 to 2036. The Company also had credit carryforwards of approximately $54.3 million for federal tax purposes, of which $24.0 million relate to stock deductions and $23.6 million relate to debt issuance, both of which will benefit equity when realized. The Company had California credit carryforwards of $7.5 million for state tax purposes, of which $3.4 million relate to stock deductions and $3.3 million relate to debt issuance, both of which will benefit equity when realized. These federal credit carryforwards will expire at various dates from 2018 to 2036, and the California credit carryforwards do not expire. The Company’s ability to utilize a portion of the net operating loss and credit carryforwards is dependent upon the Company being able to generate taxable income in future periods or being able to carryback net operating losses to prior year tax returns. The Company's ability to utilize net operating losses may be limited due to restrictions imposed on utilization of net operating loss and credit carryforwards under federal and state laws upon a change in ownership, such as the transaction with Cypress.

The Company is subject to tax holidays in the Philippines where it manufactures its solar power products. The Company's current income tax holidays were granted as manufacturing lines were placed in service and thereafter expire within this fiscal year, and we are in the process of or have applied for extensions and renewals upon expiration. Tax holidays in the Philippines reduce the Company's tax rate to 0% from 30%. Tax savings associated with the Philippines tax holidays were approximately $10.0 million, $21.2 million, and $8.3 million in fiscal 2016, 2015, and 2014, respectively, which provided a diluted net income (loss) per share benefit of $0.07, $0.16, and $0.05, respectively.

The Company qualifies for the auxiliary company status in Switzerland where it sells its solar power products. The auxiliary company status entitles the Company to a reduced tax rate of 11.5% in Switzerland from approximately 24.2%. Tax savings associated with this ruling were approximately $1.9 million, $1.6 million, and $3.5 million in fiscal 2016, 2015, and 2014, respectively, which provided a diluted net income (loss) per share benefit of $0.01, $0.01, and $0.02 in fiscal 2016, 2015, and 2014, respectively.

The Company is subject to tax holidays in Malaysia where it manufactures its solar power products. The Company's current tax holidays in Malaysia were granted to its former joint venture AUOSP (now a wholly-owned subsidiary). Tax holidays in Malaysia reduce the Company’s tax rate to 0% from 25%. Tax savings associated with the Malaysia tax holiday

140

Table of Contents


were approximately $2.0 million in fiscal 2016, which provided a diluted net income (loss) per share benefit of $0.01 in fiscal 2016.

As of January 1, 2017, the Company’s foreign subsidiaries have accumulated undistributed earnings of approximately $269.2 million that are intended to be indefinitely reinvested outside the United States and, accordingly, no provision for U.S. federal and state tax has been made for the distribution of these earnings. At January 1, 2017, the amount of the unrecognized deferred tax liability on the indefinitely reinvested earnings was $50.0 million.

Valuation Allowance

The Company’s valuation allowance is related to deferred tax assets in the United States, France, and Spain and was determined by assessing both positive and negative evidence. When determining whether it is more likely than not that deferred assets are recoverable, with such assessment being required on a jurisdiction by jurisdiction basis, management believes that sufficient uncertainty exists with regard to the realizability of these assets such that a valuation allowance is necessary. Factors considered in providing a valuation allowance include the lack of a significant history of consistent profits, the lack of consistent profitability in the solar industry, the limited capacity of carrybacks to realize these assets, and other factors. Based on the absence of sufficient positive objective evidence, management is unable to assert that it is more likely than not that the Company will generate sufficient taxable income to realize net deferred tax assets aside from the U.S. net operating losses that can be carried back to prior year tax returns. Should the Company achieve a certain level of profitability in the future, it may be in a position to reverse the valuation allowance which would result in a non-cash income statement benefit. The change in valuation allowance for fiscal 2016, 2015, and 2014 was $228.6 million, $149.9 million, and $28.2 million, respectively.

Unrecognized Tax Benefits

Current accounting guidance contains a two-step approach to recognizing and measuring uncertain tax positions. The first step is to evaluate the tax position for recognition by determining if the weight of available evidence indicates that it is more likely than not that the position will be sustained on audit, including resolution of related appeals or litigation processes, if any. The second step is to measure the tax benefit as the largest amount that is more than 50% likely of being realized upon ultimate settlement.

A reconciliation of the beginning and ending amounts of unrecognized tax benefits during fiscal 2016, 2015, and 2014 is as follows:
 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Balance, beginning of year
 
$
41,058

 
$
44,287

 
$
29,618

Additions for tax positions related to the current year
 
35,768

 
10,478

 
5,579

Additions (reductions) for tax positions from prior years
 
7,322

 
(12,545
)
 
14,408

Reductions for tax positions from prior years/statute of limitations expirations
 
(2,063
)
 
(944
)
 
(3,391
)
Foreign exchange (gain) loss
 
168

 
(218
)
 
(1,927
)
Balance at the end of the period
 
$
82,253

 
$
41,058

 
$
44,287


Included in the unrecognized tax benefits at fiscal 2016 and 2015 is $44.3 million and $41.7 million, respectively that, if recognized, would result in a reduction of the Company's effective tax rate. The amounts differ from the long term liability recorded of $47.2 million and $43.3 million as of fiscal 2016 and 2015 due to accrued interest and penalties. Certain components of the unrecognized tax benefits are recorded against deferred tax asset balances.

Management believes that events that could occur in the next 12 months and cause a change in unrecognized tax benefits include, but are not limited to, the following:

commencement, continuation or completion of examinations of the Company’s tax returns by the U.S. or foreign taxing authorities; and

expiration of statutes of limitation on the Company’s tax returns.


141

Table of Contents


The calculation of unrecognized tax benefits involves dealing with uncertainties in the application of complex global tax regulations. Uncertainties include, but are not limited to, the impact of legislative, regulatory and judicial developments, transfer pricing and the application of withholding taxes. Management regularly assesses the Company’s tax positions in light of legislative, bilateral tax treaty, regulatory and judicial developments in the countries in which the Company does business. Management determined that an estimate of the range of reasonably possible change in the amounts of unrecognized tax benefits within the next 12 months cannot be made.

Classification of Interests and Penalties

The Company accrues interest and penalties on tax contingencies which are classified as "Provision for income taxes" in the Consolidated Statements of Operations. Accrued interest as of January 1, 2017 and January 3, 2016 was approximately $2.8 million and $1.7 million, respectively. Accrued penalties were not material for any of the periods presented.

Tax Years and Examination

The Company files tax returns in each jurisdiction in which it is registered to do business. In the United States and many of the state jurisdictions, and in many foreign countries in which the Company files tax returns, a statute of limitations period exists. After a statute of limitations period expires, the respective tax authorities may no longer assess additional income tax for the expired period. Similarly, the Company is no longer eligible to file claims for refund for any tax that it may have overpaid. The following table summarizes the Company’s major tax jurisdictions and the tax years that remain subject to examination by these jurisdictions as of January 1, 2017:

Tax Jurisdictions
Tax Years
United States
2010 and onward
California
2011 and onward
Switzerland
2007 and onward
Philippines
2012 and onward
France
2012 and onward
Italy
2011 and onward

Additionally, certain pre-2010 U.S. corporate tax return and pre-2011 California tax returns are not open for assessment but the tax authorities can adjust net operating loss and credit carryovers that were generated.

The Company is under tax examinations in various jurisdictions. The Company does not expect the examinations to result in a material assessment outside of existing reserves. If a material assessment in excess of current reserves results, the amount that the assessment exceeds current reserves will be a current period charge to earnings.

Note 14. COMMON STOCK

Common Stock

Voting Rights - Common Stock

All common stock holders are entitled to one vote per share on all matters submitted to be voted on by the Company's stockholders, subject to the preferences applicable to any preferred stock outstanding.

Dividends - Common Stock

All common stock holders are entitled to receive equal per share dividends when and if declared by the Board of Directors, subject to the preferences applicable to any preferred stock outstanding. Certain of the Company's debt agreements place restrictions on the Company and its subsidiaries’ ability to pay cash dividends.

Shares Reserved for Future Issuance
 
The Company had shares of common stock reserved for future issuance as follows:

142

Table of Contents


(In thousands)
 
January 1, 2017
 
January 3, 2016
Equity compensation plans
 
7,018

 
7,174


Note 15. NET INCOME (LOSS) PER SHARE
 
The Company calculates net income (loss) per share by dividing earnings allocated to common stockholders by the weighted average number of common shares outstanding for the period.

Diluted weighted average shares is computed using basic weighted average shares plus any potentially dilutive securities outstanding during the period using the treasury-stock-type method and the if-converted method, except when their effect is anti-dilutive. Potentially dilutive securities include stock options, restricted stock units, the Upfront Warrants held by Total, warrants associated with the CSO2015, and the outstanding senior convertible debentures.

The following table presents the calculation of basic and diluted net income (loss) per share:
 
 
Fiscal Year
(In thousands, except per share amounts)
 
2016
 
2015
 
2014
Basic net income (loss) per share:
 
 
 
 
 
 
Numerator
 
 
 
 
 
 
Net income (loss) attributable to stockholders
 
$
(471,064
)
 
$
(187,019
)
 
$
245,894

Denominator
 
 
 
 
 
 
Basic weighted-average common shares
 
137,985

 
134,884

 
128,635

 
 
 
 
 
 
 
Basic net income (loss) per share
 
$
(3.41
)
 
$
(1.39
)
 
$
1.91

 
 
 
 
 
 
 
Diluted net income (loss) per share:
 
 
 
 
 
 
Numerator
 
 
 
 
 
 
Net income (loss) attributable to stockholders
 
$
(471,064
)
 
$
(187,019
)
 
$
245,894

Add: Interest expense incurred on the 0.75% debentures due 2018, net of tax
 

 

 
2,103

Add: Interest expense incurred on the 0.875% debentures due 2021, net of tax
 

 

 
1,897

Add: Interest expense incurred on the 4.75% debentures due 2014, net of tax
 

 

 
2,630

Net income (loss) available to common stockholders
 
$
(471,064
)
 
$
(187,019
)
 
$
252,524

Denominator
 
 
 
 
 
 
Basic weighted-average common shares
 
137,985

 
134,884

 
128,635

Effect of dilutive securities:
 
 
 
 
 
 
Stock options
 

 

 
84

Restricted stock units
 

 

 
4,522

Upfront Warrants (held by Total)
 

 

 
7,236

Warrants (under the CSO2015)
 
n/a

 

 
2,945

Warrants (under the CSO2014)
 
n/a

 

 
262

0.75% debentures due 2018
 

 

 
12,026

0.875% debentures due 2021
 

 

 
4,530

4.75% debentures due 2014
 

 

 
2,511

Dilutive weighted-average common shares
 
137,985

 
134,884

 
162,751

 
 
 
 
 
 
 
Diluted net income (loss) per share
 
$
(3.41
)
 
$
(1.39
)
 
$
1.55


The Upfront Warrants allow Total to acquire up to 9,531,677 shares of the Company's common stock at an exercise price of $7.8685. The warrants under the CSO2015, when such warrants were still outstanding, entitled holders to acquire up to 11.1

143

Table of Contents


million shares of the Company's common stock at an exercise price of $24.00. During the second quarter of fiscal 2015, the Company entered into unwind agreements pursuant to which the Company issued common stock to settle all of the outstanding warrants relating to the CSO2015 (refer to "Note 12. Debt and Credit Sources" in our Annual Report on Form 10-K for the fiscal year ended January 3, 2016).

Holders of the Company's 4.00% debentures due 2023, 0.875% debentures due 2021, and 0.75% debentures due 2018 can convert the debentures into shares of the Company's common stock, at the applicable conversion rate, at any time on or before maturity. These debentures are included in the calculation of diluted net income per share if they were outstanding during the period presented and if their inclusion is dilutive under the if-converted method.

Holders of the Company's 4.50% debentures due 2015 could, under certain circumstances at their option and before maturity, convert the debentures into cash, and not into shares of the Company's common stock (or any other securities). Therefore, the 4.50% debentures due 2015 are excluded from the net income per share calculation. In March 2015, the 4.50% debentures due 2015 matured and were settled in cash.

The following is a summary of outstanding anti-dilutive potential common stock that was excluded from income (loss) per diluted share in the following periods:
 
 
Fiscal Year
(In thousands)
 
20161
 
20151
 
2014
Stock options
 
141

 
151

 
142

Restricted stock units
 
4,997

 
3,152

 
374

Upfront Warrants (held by Total)
 
3,721

 
6,801

 

Warrants (under the CSO2015)
 
n/a

 
913

 

4.00% debentures due 2023
 
13,922

 
682

 
n/a

0.75% debentures due 2018
 
12,026

 
12,026

 

0.875% debentures due 2021
 
8,203

 
8,203

 


1 
As a result of the net loss per share for fiscal 2016 and 2015, the inclusion of all potentially dilutive stock options, restricted stock units, and common shares under noted warrants and convertible debt would be anti-dilutive. Therefore, those stock options, restricted stock units and shares were excluded from the computation of the weighted-average shares for diluted net loss per share for such periods.

Note 16. STOCK-BASED COMPENSATION

The following table summarizes the consolidated stock-based compensation expense by line item in the Consolidated Statements of Operations:
 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Cost of Residential revenue
 
$
5,464

 
$
4,764

 
$
3,959

Cost of Commercial revenue
 
4,235

 
2,676

 
1,954

Cost of Power Plant revenue
 
10,878

 
5,904

 
8,408

Research and development
 
11,075

 
9,938

 
7,714

Sales, general and administrative
 
29,847

 
35,678

 
33,557

Total stock-based compensation expense
 
$
61,499

 
$
58,960

 
$
55,592


The following table summarizes the consolidated stock-based compensation expense by type of award:
 
 
Fiscal Year
(In thousands)
 
2016
 
2015
 
2014
Restricted stock units
 
$
58,562

 
$
61,818

 
$
55,591

Change in stock-based compensation capitalized in inventory
 
2,937

 
(2,858
)
 
1

Total stock-based compensation expense
 
$
61,499

 
$
58,960

 
$
55,592


144

Table of Contents



As of January 1, 2017, the total unrecognized stock-based compensation related to outstanding restricted stock units was $88.6 million, which the Company expects to recognize over a weighted-average period of 2.72 years.

Equity Incentive Programs

Stock-based Incentive Plans
 
The Company has four stock incentive plans: (i) the 1996 Stock Plan ("1996 Plan"); (ii) the Third Amended and Restated 2005 SunPower Corporation Stock Incentive Plan ("2005 Plan"); (iii) the PowerLight Corporation Common Stock Option and Common Stock Purchase Plan ("PowerLight Plan"); and (iv) the SunPower Corporation 2015 Omnibus Incentive Plan ("2015 Plan"). The PowerLight Plan, which was adopted by PowerLight’s Board of Directors in October 2000, was assumed by the Company by way of the acquisition of PowerLight in fiscal 2007. Under the terms of all plans, the Company may issue incentive or non-statutory stock options or stock purchase rights to directors, employees and consultants to purchase common stock. The 2005 Plan, which replaced the 1996 Plan, was adopted by the Company’s Board of Directors in August 2005, and was approved by shareholders in November 2005. The 2015 Plan, which subsequently replaced the 2005 Plan, was adopted by the Company’s Board of Directors in February 2015, and was approved by shareholders in June 2015. The 2015 Plan allows for the grant of options, as well as grant of stock appreciation rights, restricted stock grants, restricted stock units and other equity rights.  The 2015 Plan also allows for tax withholding obligations related to stock option exercises or restricted stock awards to be satisfied through the retention of shares otherwise released upon vesting.

The 2015 Plan includes an automatic annual increase mechanism equal to the lower of three percent of the outstanding shares of all classes of the Company’s common stock measured on the last day of the immediately preceding fiscal year, 6.0 million shares, or such other number of shares as determined by the Company’s Board of Directors. In fiscal 2015, the Company’s Board of Directors voted to reduce the stock incentive plan’s automatic increase from 3% to 2% for 2016. Subsequent to the adoption of the 2015 Plan, no new awards are being granted under the 2005 Plan, the 1996 Plan, or the PowerLight Plan. Outstanding awards granted under these plans continue to be governed by their respective terms. As of January 1, 2017, approximately 7.0 million shares were available for grant under the 2015 Plan.

Incentive stock options, nonstatutory stock options, and stock appreciation rights may be granted at no less than the fair value of the common stock on the date of grant. The options and rights become exercisable when and as determined by the Company’s Board of Directors, although these terms generally do not exceed ten years for stock options. Under the 1996 and 2005 Plans, the options typically vest over five years with a one-year cliff and monthly vesting thereafter. Under the PowerLight Plan, the options typically vest over five years with yearly cliff vesting. The Company has not granted stock options since fiscal 2008, and accordingly all outstanding options are fully vested. Under the 2005 and 2015 plans, the restricted stock grants and restricted stock units typically vest in equal installments annually over three or four years.

The majority of shares issued are net of the minimum statutory withholding requirements that the Company pays on behalf of its employees. During fiscal 2016, 2015, and 2014, the Company withheld 1.0 million, 1.4 million and 1.7 million shares, respectively, to satisfy the employees' tax obligations. The Company pays such withholding requirements in cash to the appropriate taxing authorities. Shares withheld are treated as common stock repurchases for accounting and disclosure purposes and reduce the number of shares outstanding upon vesting.

Restricted Stock and Stock Options

The following table summarizes the Company’s non-vested restricted stock activities:

145

Table of Contents


 
 
Restricted Stock Units
 
 
Shares
(in thousands)
 
Weighted-Average
Grant Date Fair
Value Per Share1
Outstanding as of December 29, 2013
 
9,592

 
12.26

Granted
 
2,187

 
31.80

Vested2
 
(4,432
)
 
11.61

Forfeited
 
(792
)
 
15.00

Outstanding as of December 28, 2014
 
6,555

 
18.88

Granted
 
2,695

 
29.77

Vested2
 
(3,560
)
 
15.31

Forfeited
 
(627
)
 
22.99

Outstanding as of January 3, 2016
 
5,063

 
26.68

Granted
 
4,978

 
18.81

Vested2
 
(2,837
)
 
23.47

Forfeited
 
(1,057
)
 
26.30

Outstanding as of January 1, 2017
 
6,147

 
21.85

1 
The Company estimates the fair value of its restricted stock awards and units at its stock price on the grant date.

2 
Restricted stock awards and units vested include shares withheld on behalf of employees to satisfy the minimum statutory tax withholding requirements.

The following table summarizes the Company’s outstanding options as of January 1, 2017:
 
 
Outstanding Stock Options
 
 
Shares
(in thousands)
 
Weighted-Average
Exercise Price
Per Share
 
Weighted-Average
Remaining Contractual
Term (in years)
 
Aggregate
Intrinsic Value
(in thousands)
Outstanding and exercisable as of January 1, 2017
 
134

 
$
56.21

 
1.41
 
$
2


There were no options exercised in fiscal 2016. The intrinsic value of options exercised in fiscal 2016, 2015, and 2014 were zero, $1.0 million, and $2.4 million, respectively. There were no stock options granted in fiscal 2016, 2015, and 2014.

The aggregate intrinsic value in the preceding table represents the total pre-tax intrinsic value, based on the Company’s closing stock price of $6.61 at January 1, 2017 which would have been received by the option holders had all option holders exercised their options as of that date. The total number of in-the-money options exercisable was not material as of January 1, 2017.


Note 17. SEGMENT AND GEOGRAPHICAL INFORMATION

The Company's President and Chief Executive Officer, as the CODM, has organized the Company, manages resource allocations and measures performance of the Company's activities among three end-customer segments: (i) Residential Segment, (ii) Commercial Segment and (iii) Power Plant Segment (see Note 1). The Residential and Commercial Segments combined are referred to as Distributed Generation.

The CODM assesses the performance of the three end-customer segments using information about their revenue, gross margin, and adjusted earnings before interest, taxes, depreciation and amortization ("Adjusted EBITDA") after certain adjustments, described below in further detail. Additionally, for purposes of calculating Adjusted EBITDA, the calculation includes equity in earnings of unconsolidated investees and net loss attributable to noncontrolling interests and redeemable noncontrolling interests and excludes cash interest expense, net of interest income, and depreciation. The CODM does not review asset information by segment.

Adjustments Made for Segment Purposes

8point3 Energy Partners

The Company includes adjustments related to the sales of projects contributed to 8point3 based on the difference between the fair market value of the consideration received and the net carrying value of the projects contributed, of which, a portion is deferred in proportion to the Company’s retained equity interest in 8point3. Under U.S. GAAP (“GAAP”), these sales are recognized under either real estate, lease, or consolidation accounting guidance depending upon the nature of the individual asset contributed, with outcomes ranging from no, partial, or full profit recognition.

Utility and power plant projects

The Company includes adjustments related to the revenue recognition of certain utility and power plant projects based on percentage-of-completion accounting and, when relevant, the allocation of segment revenue and margin to the Company’s project development efforts at the time of initial project sale. Under GAAP, such projects are accounted for under real estate accounting guidance, under which no separate allocation to the Company’s project development efforts occurs and the amount of revenue and margin that is recognized may be limited in circumstances where the Company has certain forms of continuing involvement in the project. Over the life of each project, cumulative revenue and gross margin will eventually be equivalent under both the GAAP and segment treatments; however, revenue and gross margin will generally be recognized earlier under the Company’s segment treatment. Within each project, the relationship between the adjustments to revenue and gross margins is generally consistent. However, as the Company may have multiple utility and power plant projects in differing stages of progress at any given time, the relationship in the aggregate will occasionally appear otherwise.

Sale of operating lease assets

The Company includes adjustments related to the revenue recognition on the sale of certain solar assets subject to an operating lease (or of solar assets that are leased by or intended to be leased by the third-party purchaser to another party) based on the net proceeds received from the purchaser. Under GAAP, these sales are accounted for as borrowing transactions in accordance with lease accounting guidance. Under such guidance, revenue and profit recognition is based on rental payments made by the end lessee, and the net proceeds from the purchaser are recorded as a non-recourse borrowing liability, with imputed interest expense recorded on the liability. This treatment continues until the Company has transferred the substantial risks of ownership, as defined by lease accounting guidance, to the purchaser, at which point the sale is recognized.

Sale-leaseback transactions

The Company includes adjustments related to the revenue recognition on certain sale-leaseback transactions based on the net proceeds received from the buyer-lessor. Under GAAP, these transactions are accounted for under the financing method in accordance with real estate accounting guidance. Under such guidance, no revenue or profit is recognized at the inception of the transaction, and the net proceeds from the buyer-lessor are recorded as a financing liability. Imputed interest is recorded on the liability equal to the Company’s incremental borrowing rate adjusted solely to prevent negative amortization.

Stock-based compensation

The Company incurs stock-based compensation expense related primarily to the Company’s equity incentive awards. The Company excludes this expense from its segment results.

Amortization of intangible assets

The Company incurs amortization expense on intangible assets as a result of acquisitions, which includes patents, project assets, purchased technology, in-process research and development and trade names. The Company excludes this expense from its segment results.

Non-cash interest expense

The Company incurs non-cash interest expense related to the amortization of items such as original issuance discounts on certain of its convertible debt. The Company excludes this expense from its segment results.

Restructuring expense

The Company incurs restructuring expense related to reorganization plans aimed towards realigning resources consistent with the Company's global strategy and improving its overall operating efficiency and cost structure. The Company excludes this expense from its segment results.

Goodwill Impairment

In the third quarter of fiscal 2016, the Company performed an interim goodwill impairment evaluation due to market circumstances at the time, including a decline in the Company's stock price which resulted in the market capitalization of the Company being below its book value. The Company's preliminary calculation determined that the implied fair value of goodwill for all reporting units was zero and therefore recorded a goodwill impairment loss of $147.4 million, which includes $89.6 million of goodwill recognized in the third quarter of 2016 in connection with the Company's acquisition of the remaining 50% of AUOSP (see Notes 3 and 4). The Company excludes from its segment results the impairment of goodwill arising from business combinations prior to the acquisition of AUOSP. No adjustment was made for the impairment of the goodwill arising from the acquisition of AUOSP.

Arbitration ruling

On January 28, 2015, an arbitral tribunal of the International Court of Arbitration of the International Chamber of Commerce declared a binding partial award in the matter of an arbitration between First Philippine Electric Corporation (“FPEC”) and First Philippine Solar Corporation (“FPSC”) against SunPower Philippines Manufacturing, Ltd. (“SPML”), the Company’s wholly-owned subsidiary. The tribunal found SPML in breach of its obligations under its supply agreement with FPSC, and in breach of its joint venture agreement with FPEC. The second partial and final awards dated July 14, 2015 and September 30, 2015, respectively, reduced the estimated amounts to be paid to FPEC, and on July 22, 2016, SPML entered into a settlement with FPEC and FPSC and paid a total of $50.5 million in settlement of all claims between the parties. As a result, the Company recorded its best estimate of probable loss related to this case at the time of the initial ruling and updated the estimate as circumstances warranted. The Company excludes these amounts from its segment results.

IPO-related costs

The Company incurred costs related to the IPO of 8point3 related to legal, accounting, advisory, valuation, and other expenses, as well as modifications to or terminations of certain existing financing structures in preparation for the sale to 8point3. The Company excludes these costs from its segment results.

Other

The Company combines amounts previously disclosed under separate captions into “Other” when amounts do not have a significant impact on the presented fiscal periods.

Segment and Geographical Information

The following tables present information by end-customer segment including revenue, gross margin, and adjusted EBITDA, each as reviewed by the CODM, as well as information about significant customers and revenue by geography, based on the destination of the shipments.



146

Table of Contents



A reconciliation of the Company's segment revenue and gross margin to its consolidated financial statements for the fiscal years ended January 1, 2017, January 3, 2016, and December 28, 2014 is as follows:
 
 
Fiscal 2016
 
 
Revenue
 
Gross margin
Revenue and Gross margin by segment (in thousands, except percentages):
 
Residential
 
Commercial
 
Power Plant
 
Residential
 
Commercial
 
Power Plant
As reviewed by CODM
 
$
708,687

 
$
520,818

 
$
1,473,355

 
$
120,484

 
17.0
%
 
$
19,876

 
3.8
 %
 
$
103,161

 
7.0
%
8point3 Energy Partners
 
5,248

 
(5,370
)
 
(61,596
)
 
1,657

 
 
 
(3,751
)
 
 
 
(8,418
)
 
 
Utility and power plant projects
 

 

 
(9,443
)
 

 
 
 

 
 
 
(10,274
)
 
 
Sale of operating lease assets
 
6,396

 

 

 
1,942

 
 
 

 
 
 

 
 
Sale-leaseback transactions
 

 
(78,533
)
 

 

 
 
 
(11,351
)
 
 
 

 
 
Stock-based compensation
 

 

 

 
(5,464
)
 
 
 
(4,234
)
 
 
 
(10,879
)
 
 
Amortization of intangible assets
 

 

 

 
(2,965
)
 
 
 
(3,059
)
 
 
 
(1,655
)
 
 
Non-cash interest expense
 

 

 

 
(227
)
 
 
 
(199
)
 
 
 
(530
)
 
 
Arbitration ruling
 

 

 

 
1,345

 
 
 
922

 
 
 
3,585

 
 
GAAP
 
$
720,331

 
$
436,915

 
$
1,402,316

 
$
116,772

 
16.2
%
 
$
(1,796
)
 
(0.4
)%
 
$
74,990

 
5.3
%



 
 
Fiscal 2015
 
 
Revenue
 
Gross margin
Revenue and Gross margin by segment (in thousands, except percentages):
 
Residential
 
Commercial
 
Power Plant
 
Residential
 
Commercial
 
Power Plant
As reviewed by CODM
 
$
647,213

 
$
392,866

 
$
1,572,571

 
$
140,010

 
21.6
%
 
$
52,070

 
13.3
%
 
$
432,921

 
27.5
%
8point3 Energy Partners
 
2,754

 
(115,723
)
 
(898,765
)
 
1,148

 
 
 
(32,734
)
 
 
 
(338,371
)
 
 
Utility and power plant projects
 

 

 
(17,996
)
 

 
 
 

 
 
 
3,016

 
 
Sale of operating lease assets
 
(6,447
)
 

 

 
(2,000
)
 
 
 

 
 
 

 
 
Stock-based compensation
 

 

 

 
(4,764
)
 
 
 
(2,676
)
 
 
 
(5,903
)
 
 
Amortization of intangible assets
 

 

 

 
(728
)
 
 
 
(451
)
 
 
 
(1,155
)
 
 
Non-cash interest expense
 

 

 

 
(638
)
 
 
 
(330
)
 
 
 
(1,069
)
 
 
Arbitration ruling
 

 

 

 
2,084

 
 
 
1,697

 
 
 
2,678

 
 
Other
 

 

 

 
(41
)
 
 
 
(33
)
 
 
 
(85
)
 
 
GAAP
 
$
643,520

 
$
277,143

 
$
655,810

 
$
135,071

 
21.0
%
 
$
17,543

 
6.3
%
 
$
92,032

 
14.0
%


 
 
Fiscal 2014
 
 
Revenue
 
Gross margin
Revenue and Gross margin by segment (in thousands, except percentages):
 
Residential
 
Commercial
 
Power Plant
 
Residential
 
Commercial
 
Power Plant
As reviewed by CODM
 
$
655,936

 
$
361,828

 
$
1,600,885

 
$
137,532

 
21.0
%
 
$
47,497

 
13.1
%
 
$
328,516

 
20.5
%
Utility and power plant projects
 

 

 
408,616

 

 
 
 

 
 
 
190,712

 
 
Stock-based compensation
 

 

 

 
(3,959
)
 
 
 
(1,954
)
 
 
 
(8,408
)
 
 
Non-cash interest expense
 

 

 

 
(765
)
 
 
 
(379
)
 
 
 
(1,615
)
 
 
Arbitration ruling
 


 


 


 
(18,684
)
 
 
 
(9,660
)
 
 
 
(28,462
)
 
 
Other
 

 

 

 

 
 
 

 
 
 
(5,244
)
 
 
GAAP
 
$
655,936

 
$
361,828

 
$
2,009,501

 
$
114,124

 
17.4
%
 
$
35,504

 
9.8
%
 
$
475,499

 
23.7
%






147

Table of Contents


 
 
Fiscal Year
(In thousands):
 
2016
 
2015
 
2014
Adjusted EBITDA as reviewed by CODM
 
 
 
 
 
 
Distributed Generation
 
 
 
 
 
 
   Residential
 
$
134,157

 
$
194,906

 
$
153,456

   Commercial
 
2,268

 
18,743

 
29,293

Power Plant
 
78,800

 
396,379

 
329,787

Total Segment Adjusted EBITDA as reviewed by CODM
 
$
215,225

 
$
610,028

 
$
512,536

Reconciliation to Consolidated Statements of Income (Loss)
 
 
 
 
 
 
8point3 Energy Partners
 
(54,379
)
 
(408,780
)
 

Utility and power plant projects
 
(10,274
)
 
3,016

 
190,712

Sale of operating lease assets
 
1,889

 
(2,000
)
 

Sale-leaseback transactions
 
(11,700
)
 

 

Stock-based compensation
 
(61,498
)
 
(58,960
)
 
(55,592
)
Amortization of intangible assets
 
(17,369
)
 
(4,717
)
 
(614
)
Non-cash interest expense
 
(1,057
)
 
(6,519
)
 
(21,585
)
Restructuring expense
 
(207,189
)
 
(6,056
)
 
(12,684
)
Goodwill impairment
 
(57,765
)
 

 

Arbitration ruling
 
5,852

 
6,459

 
(56,806
)
IPO-related costs
 
304

 
(28,033
)
 

Other
 
31

 
(162
)
 
(6,930
)
Equity in earnings of unconsolidated investees
 
(28,070
)
 
(9,569
)
 
(7,241
)
Net loss attributable to noncontrolling interests and redeemable noncontrolling interests
 
(72,780
)
 
(112,417
)
 
(62,799
)
Cash interest expense, net of interest income
 
(57,734
)
 
(37,643
)
 
(48,364
)
Depreciation
 
(156,464
)
 
(133,456
)
 
(107,406
)
Corporate and unallocated items
 
(51,617
)
 
(53,502
)
 
(138,613
)
Loss before taxes and equity in earnings of unconsolidated investees
 
$
(564,595
)
 
$
(242,311
)
 
$
184,614


 
 
Fiscal Year
(As a percentage of total revenue):
 
2016
 
2015
 
2014
Significant Customers:
Business Segment
 
 
 
 
 
 
8point3 Energy Partners
Power Plant
 
10
%
 
n/a

 
n/a

Southern Renewable Partnerships, LLC
Power Plant
 
15
%
 
n/a

 
n/a

MidAmerican Energy Holdings Company
Power Plant
 
*

 
14
%
 
49
%
*denotes less than 10% during the period

 
 
Fiscal Year
 
 
(As a percentage of total revenue):
 
2016
 
2015
 
2014
Revenue by geography:
 
 
 
 
 
 
United States
 
85
%
 
69
%
 
72
%
Japan
 
6
%
 
12
%
 
12
%
Rest of World
 
9
%
 
19
%
 
16
%
 
 
100
%
 
100
%
 
100
%



148

Table of Contents


Note 18. SUBSEQUENT EVENTS

In May 2010, the Company entered into a mortgage loan agreement with IFC to borrow $75.0 million (see Note 11). As of January 1, 2017, the Company had $17.5 million outstanding under the mortgage loan agreement. On January 17, 2017, the Company made an $18.0 million payment to IFC to repay the outstanding balance, and the associated interest, of the mortgage loan agreement.



149

Table of Contents


SELECTED UNAUDITED QUARTERLY FINANCIAL DATA

Consolidated Statements of Operations:

 
 
Three Months Ended
(In thousands, except per share data)
 
January 1, 2017
 
October 2, 2016
 
July 3, 2016
 
April 3, 2016
 
January 3, 2016
 
September 27, 2015
 
June 28, 2015
 
March 29, 2015
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
Revenue
 
$
1,024,889

 
$
729,346

 
$
420,452

 
$
384,875

 
$
374,364

 
$
380,218

 
$
381,020

 
$
440,871

Gross margin
 
$
(32,073
)
 
$
129,208

 
$
41,294

 
$
51,537

 
$
20,303

 
$
62,644

 
$
70,881

 
$
90,818

Net income (loss)
 
$
(294,339
)
 
$
(55,907
)
 
$
(92,181
)
 
$
(101,417
)
 
$
(159,635
)
 
$
(87,285
)
 
$
(23,466
)
 
$
(29,050
)
Net income (loss) attributable to stockholders
 
$
(275,118
)
 
$
(40,545
)
 
$
(69,992
)
 
$
(85,409
)
 
$
(127,621
)
 
$
(56,326
)
 
$
6,509

 
$
(9,581
)
Net income (loss) per share attributable to stockholders:
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
Basic
 
$
(1.99
)
 
$
(0.29
)
 
$
(0.51
)
 
$
(0.62
)
 
$
(0.93
)
 
$
(0.41
)
 
$
0.05

 
$
(0.07
)
Diluted
 
$
(1.99
)
 
$
(0.29
)
 
$
(0.51
)
 
$
(0.62
)
 
$
(0.93
)
 
$
(0.41
)
 
$
0.04

 
$
(0.07
)


150

Table of Contents


ITEM 9: CHANGES IN AND DISAGREEMENTS WITH ACCOUNTANTS ON ACCOUNTING AND FINANCIAL DISCLOSURES

None.


151

Table of Contents


ITEM 9A: CONTROLS AND PROCEDURES

Evaluation of Disclosure Controls and Procedures

We maintain "disclosure controls and procedures," as defined in Rule 13a-15(e) and 15d-15(e) under the Exchange Act, that are designed to provide reasonable assurance that information required to be disclosed in reports that we file or submit under the Exchange Act is recorded, processed, summarized and reported within the time periods specified in SEC rules and forms, and that such information is accumulated and communicated to our management, including our Chief Executive Officer and Chief Financial Officer, as appropriate to allow timely decisions regarding required disclosure. In designing and evaluating our disclosure controls and procedures, management recognizes that disclosure controls and procedures, no matter how well conceived and operated, can provide only reasonable, not absolute, assurance that the objectives of the disclosure controls and procedures are met. Additionally, in designing disclosure controls and procedures, our management is required to apply its judgment in evaluating the cost-benefit relationship of possible disclosure controls and procedures. The design of any disclosure control and procedure also is based in part upon certain assumptions about the likelihood of future events, and there can be no assurance that any design will succeed in achieving its stated goals under all potential future conditions.

Based on their evaluation as of the end of the period covered by this Annual Report on Form 10-K, our Chief Executive Officer and Chief Financial Officer have concluded that our disclosure controls and procedures were effective as of January 1, 2017 at a reasonable assurance level.

Management's Report on Internal Control over Financial Reporting

Management is responsible for establishing and maintaining adequate internal control over financial reporting, as defined in Exchange Act Rule 13a-15(f). Management conducted an evaluation of the effectiveness of our internal control over financial reporting using the criteria described in Internal Control-Integrated Framework issued by the Committee of Sponsoring Organizations of the Treadway Commission (2013 framework) ("COSO"). Based on this evaluation, management concluded that our internal control over financial reporting was effective as of January 1, 2017 based on the criteria described in Internal Control-Integrated Framework issued by COSO. Management reviewed the results of its assessment with our Audit Committee.

The effectiveness of the Company's internal control over financial reporting as of January 1, 2017 has been audited by Ernst & Young LLP, an independent registered public accounting firm, as stated in their report which is included in Item 8 of this Annual Report on Form 10-K.

The Company's evaluation of the effectiveness of its internal control over financial reporting as of January 1, 2017 excluded the internal controls of our former joint venture AUOSP because AUOSP was acquired by the Company in a business combination during fiscal 2016. Our former joint venture AUOSP (now our wholly-owned subsidiary, SunPower Malaysia Manufacturing Sdn. Bhd.) is a subsidiary whose total assets represent approximately 7% of the Company's consolidated total assets as of the year ended January 1, 2017. In accordance with guidance issued by the SEC, companies may exclude acquisitions from their assessment of internal control over financial reporting during the first year subsequent to the acquisition while integrating the acquired operations.

Changes in Internal Control over Financial Reporting

We regularly review our system of internal control over financial reporting and make changes to our processes and systems to improve controls and increase efficiency, while ensuring that we maintain an effective internal control environment. Changes may include such activities as implementing new, more efficient systems, consolidating activities, and migrating processes.

There were no changes in our internal control over financial reporting that occurred during our most recent fiscal quarter that materially affected, or are reasonably likely to materially affect, our internal control over financial reporting.

ITEM 9B: OTHER INFORMATION

None.

152

Table of Contents


PART III

ITEM 10. DIRECTORS, EXECUTIVE OFFICERS AND CORPORATE GOVERNANCE

Information appearing under this Item is incorporated herein by reference to our proxy statement for the 2017 annual meeting of stockholders.

We have adopted a code of ethics, entitled Code of Business Conduct and Ethics, that applies to all of our directors, officers and employees, including our principal executive officer, principal financial officer, and principal accounting officer. We have made it available, free of charge, on our website at www.sunpower.com, and if we amend it or grant any waiver under it that applies to our principal executive officer, principal financial officer, or principal accounting officer, we will promptly post that amendment or waiver on our website as well.

ITEM 11: EXECUTIVE COMPENSATION

Information appearing under this Item is incorporated herein by reference to our proxy statement for the 2017 annual meeting of stockholders.

ITEM 12: SECURITY OWNERSHIP OF CERTAIN BENEFICIAL OWNERS AND MANAGEMENT AND RELATED STOCKHOLDER MATTERS

Information appearing under this Item is incorporated herein by reference to our proxy statement for the 2017 annual meeting of stockholders.

ITEM 13: CERTAIN RELATIONSHIPS AND RELATED TRANSACTIONS, AND DIRECTOR INDEPENDENCE

Information appearing under this Item is incorporated herein by reference to our proxy statement for the 2017 annual meeting of stockholders.

ITEM 14: PRINCIPAL ACCOUNTANT FEES AND SERVICES

Information appearing under this Item is incorporated herein by reference to our proxy statement for the 2017 annual meeting of stockholders.


153

Table of Contents


PART IV

ITEM 15: EXHIBITS AND FINANCIAL STATEMENT SCHEDULES

The following documents are filed as a part of this Annual Report on Form 10-K:

1. Financial Statements:
 
Page
 Reports of Ernst & Young LLP, Independent Registered Public Accounting Firm
 Consolidated Balance Sheets
 Consolidated Statements of Operations
 Consolidated Statements of Comprehensive Income (Loss)
 Consolidated Statements of Stockholders’ Equity
 Consolidated Statements of Cash Flows
 Notes to Consolidated Financial Statements

2. Financial Statement Schedule:

All financial statement schedules are omitted as the required information is inapplicable or the information is presented in the Consolidated Financial Statements or Notes to Consolidated Financial Statements under Item 8 of this Annual Report on Form 10-K.

3. Exhibits:

EXHIBIT INDEX
Exhibit Number
 
Description
3.1
 
Restated Certificate of Incorporation of SunPower Corporation (incorporated by reference to Exhibit 3.1 to the Registrant’s Current Report on Form 8-K filed with the Securities and Exchange Commission on November 16, 2011).
3.2
 
Amended and Restated By-Laws of SunPower Corporation (incorporated by reference to Exhibit 3.1 to the Registrant’s Current Report on Form 8-K filed with the Securities and Exchange Commission on March 7, 2012).
4.1
 
Specimen Common Stock Certificate (incorporated by reference to Exhibit 4.1 to the Registrant's Annual Report on Form 10-K filed with the Securities and Exchange Commission on February 29, 2012).
4.2
 
Amended and Restated Rights Agreement, dated November 16, 2011, by and between SunPower Corporation and Computershare Trust Company, N.A., as Rights Agent, including the form of Certificate of Designation of Series A Junior Participating Preferred Stock, the forms of Right Certificates, and the Summary of Rights attached thereto as Exhibits A, B, and C, respectively (incorporated by reference to Exhibit 4.1 to the Registrant's Registration Statement on Form 8-A filed with the Securities and Exchange Commission on November 16, 2011).
4.3
 
Certificate of Designation of Series A Junior Participating Preferred Stock of SunPower Corporation (incorporated by reference to Exhibit 4.6 to the Registrant's Current Report on Form 8-K filed with the Securities and Exchange Commission on November 16, 2011).
4.4
 
Amendment No. 1, dated May 10, 2012, to the Amended and Restated Rights Agreement, dated as of November 16, 2011, by and between the SunPower Corporation and Computershare Trust Company, N.A., as rights agent (incorporated by reference to Exhibit 4.1 to the Registrant's Current Report on Form 8-K filed with the Securities and Exchange Commission on May 10, 2012).
4.5
 
Indenture, dated as of May 29, 2013, by and between SunPower Corporation and Wells Fargo Bank, National Association, as Trustee (incorporated by reference to Exhibit 4.1 to the Registrant’s Current Report on Form 8-K filed with the Securities and Exchange Commission on May 29, 2013).
4.6
 
Indenture, dated as of December 15, 2015 by and between SunPower Corporation and Wells Fargo Bank, National Association, as Trustee (incorporated by reference to Exhibit 4.1 to the Registrant’s Current Report on Form 8-K filed with the Securities and Exchange Commission on December 16, 2015).
4.7
 
Indenture, dated as of June 11, 2014 by and between SunPower Corporation and Wells Fargo Bank, National Association, as Trustee (incorporated by reference to Exhibit 10.1 to the Registrant's Current Report on Form 8-K filed with the Securities and Exchange Commission on June 11, 2014).

154

Table of Contents


10.1
 
Credit Support Agreement, dated April 28, 2011, between SunPower Corporation and Total S.A. (incorporated by reference to Exhibit 99.5 to the Registrant’s Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on May 12, 2011).
10.2
 
Amended and Restated Credit Support Agreement, dated June 29, 2016, between SunPower Corporation and Total S.A. (incorporated by reference to Exhibit 10.62 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on August 9, 2016).

10.3
 
Continuing Agreement for Standby Letters of Credit and Demand Guarantees, dated June 29, 2016 by and among the Company, Deutsche Bank AG New York Branch, and Deutsche Bank Trust Company Americas (incorporated by reference to Exhibit 10.63 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on August 9, 2016).
10.4
 
Letter of Credit Facility Agreement, dated June 29, 2016, by and among SunPower Corporation, SunPower Corporation, Systems, Total S.A., the Subsidiary Applicants party thereto, and The Bank of Tokyo-Mitsubishi UFJ, Ltd. (incorporated by reference to Exhibit 10.64 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on August 9, 2016).
10.5
 
Letter of Credit Facility Agreement, dated June 29, 2016, by and among SunPower Corporation, SunPower Corporation, Systems, Total S.A., the Subsidiary Applicants party thereto, and Credit Agricole Corporate and Investment Bank (incorporated by reference to Exhibit 10.65 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on August 9, 2016).
10.6
 
Letter of Credit Facility Agreement, dated June 29, 2016, by and among SunPower Corporation, SunPower Corporation, Systems, Total S.A., the Subsidiary Applicants party thereto, and HSBC Bank USA, National Association (incorporated by reference to Exhibit 10.66 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on August 9, 2016).
10.7
 
Transfer Agreement, dated June 29, 2016, by and among SunPower Corporation, SunPower Corporation, Systems, Total S.A., Deutsche Bank AG New York Branch as administrative agent, and the Banks party thereto (incorporated by reference to Exhibit 10.67 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on August 9, 2016).
10.8
 
Amendment to Credit Support Agreement, dated June 7, 2011, between SunPower Corporation and Total S.A. (incorporated by reference to Exhibit 10.1 of Registrant's Current Report on Form 8-K filed with the Securities and Exchange Commission on June 7, 2011).
10.9
 
Second Amendment to Credit Support Agreement, dated December 12, 2011, by and between Total S.A. and SunPower Corporation (incorporated by reference to Exhibit 10.3 of Registrant's Current Report on Form 8-K filed with the Securities and Exchange Commission on December 23, 2011).
10.10
 
Third Amendment to Credit Support Agreement, dated December 14, 2012, by and between SunPower Corporation and Total S.A. (incorporated by reference to Exhibit 10.34 to the Registrant’s Annual Report on Form 10-K filed with the Securities and Exchange Commission on February 25, 2013)
10.11
 
Affiliation Agreement, dated April 28, 2011, between SunPower Corporation and Total Gas & Power USA, SAS (incorporated by reference to Exhibit 99.6 to the Registrant’s Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on May 12, 2011).
10.12
 
Amendment to Affiliation Agreement, dated June 7, 2011, between SunPower Corporation and Total Gas & Power USA, SAS (incorporated by reference to Exhibit 10.2 of Registrant's Current Report on Form 8-K filed with the Securities and Exchange Commission on June 7, 2011).
10.13
 
Second Amendment to Affiliation Agreement, dated December 23, 2011, by and between Total G&P and SunPower Corporation (incorporated by reference to Exhibit 10.4 of Registrant's Current Report on Form 8-K filed with the Securities and Exchange Commission on December 23, 2011).
10.14
 
Amendment No. 3 to Affiliation Agreement, dated February 28, 2012, by and between SunPower Corporation and Total Gas & Power USA, SAS (incorporated by reference to Exhibit 10.91 to the Registrant's Annual Report on Form 10-K filed with the Securities and Exchange Commission on February 29, 2012).
10.15
 
Amendment No. 4 to Affiliation Agreement, dated August 10, 2012, by and between SunPower Corporation and Total Gas & Power USA, SAS (incorporated by reference to Exhibit 10.2 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on November 2, 2012).
10.16
 
Affiliation Agreement Guaranty, dated April 28, 2011, between SunPower Corporation and Total S.A. (incorporated by reference to Exhibit 99.7 to the Registrant’s Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on May 12, 2011).
10.17
 
Research & Collaboration Agreement, dated April 28, 2011, between SunPower Corporation and Total Gas & Power USA, SAS (incorporated by reference to Exhibit 99.8 to the Registrant’s Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on May 12, 2011).
10.18
 
Amendment to Research & Collaboration Agreement, dated June 7, 2011, between SunPower Corporation and Total Gas & Power USA, SAS (incorporated by reference to Exhibit 10.3 of Registrant's Current Report on Form 8-K filed with the Securities and Exchange Commission on June 7, 2011).

155

Table of Contents


10.19
 
Registration Rights Agreement, dated April 28, 2011, between SunPower Corporation and Total Gas & Power USA, SAS (incorporated by reference to Exhibit 99.9 to the Registrant’s Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on May 12, 2011).
10.20^
 
SunPower Corporation 2005 Stock Unit Plan (incorporated by reference to Exhibit 10.28 to the Registrant’s Registration Statement on Form S-1/A filed with the Securities and Exchange Commission on October 31, 2005).
10.21^
 
Third Amended and Restated SunPower Corporation 2005 Stock Incentive Plan and forms of agreements there-under (incorporated by reference to Exhibit 4.1 to the Registrant’s Registration Statement on Form S-8 filed with the Securities and Exchange Commission on November 17, 2011).
10.22^
 
SunPower Corporation 2015 Omnibus Incentive Plan (incorporated by reference to Exhibit 10.1 to the Registrant’s Registration Statement on Form S-8 (File No. 333-205207), filed with the Securities and Exchange Commission on June 25, 2015).
10.23^
 
Forms of agreements under SunPower Corporation 2015 Omnibus Incentive Plan (incorporated by reference to Exhibit 10.60 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on May 6, 2016).
10.24^
 
PowerLight Corporation Common Stock Option and Common Stock Purchase Plan (incorporated by reference to Exhibit 4.3 to the Registrant’s Registration Statement on Form S-8 filed with the Securities and Exchange Commission on January 25, 2007).
10.25^
 
Form of PowerLight Corporation Incentive/Non-Qualified Stock Option, Market Standoff and Stock Restriction Agreement (Employees) (incorporated by reference to Exhibit 4.4 to the Registrant’s Registration Statement on Form S-8 filed with the Securities and Exchange Commission on January 25, 2007).
10.26^
 
Outside Director Compensation Policy, as amended on July 22, 2015 (incorporated by reference to Exhibit 10.1 to the Registrant’s Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on October 29, 2015).
10.27^
 
Form of Employment Agreement for Executive Officers (incorporated by reference to Exhibit 10.47 to the Registrant’s Annual Report on Form 10-K filed with the Securities and Exchange Commission on February 18, 2014).
10.28^
 
SunPower Corporation Annual Executive Bonus Plan (incorporated by reference to Exhibit 10.1 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on April 30, 2014).
10.29^
 
SunPower Corporation Executive Semi-Annual Bonus Plan (incorporated by reference to Exhibit 10.2 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on April 30, 2014).
10.30^
 
Form of Indemnification Agreement for Directors and Officers (incorporated by reference to Exhibit 10.24 to the Registrant's Annual Report on Form 10-K filed with the Securities and Exchange Commission on February 19, 2016).
10.31^
 
2016 Management Career Transition Plan, dated August 10, 2015 (incorporated by reference to Exhibit 10.2 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on October 29, 2015).
10.32†
 
Mortgage Loan Agreement, dated May 6, 2010, by and among SunPower Philippines Manufacturing Ltd., SPML Land, Inc. and International Finance Corporation (incorporated by reference to Exhibit 10.13 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on August 13, 2010).
10.33
 
Guarantee Agreement, dated May 6, 2010, by and between SunPower Corporation and International Finance Corporation (incorporated by reference to Exhibit 10.14 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on August 13, 2010).
10.34
 
Amendment No. 1 to Loan Agreement, dated November 2, 2010, by and between SunPower Philippines Manufacturing Ltd. and International Finance Corporation (incorporated by reference to Exhibit 10.42 to the Registrant's Annual Report on Form 10-K filed with the Securities and Exchange Commission on February 28, 2011).
10.35
 
Mortgage Supplement No. 1, dated November 3, 2010, by and between SunPower Philippines Manufacturing Ltd., SPML Land, Inc. and International Finance Corporation (incorporated by reference to Exhibit 10.63 to the Registrant’s Annual Report on Form 10-K filed with the Securities and Exchange Commission on February 25, 2013).
10.36
 
Mortgage Supplement No. 2, dated October 9, 2012, by and between SunPower Philippines Manufacturing Ltd., SPML Land, Inc. and International Finance Corporation (incorporated by reference to Exhibit 10.64 to the Registrant’s Annual Report on Form 10-K filed with the Securities and Exchange Commission on February 25, 2013).

156

Table of Contents


10.37
 
Mortgage Supplement No. 3, dated February 7, 2013, by and between SunPower Philippines Manufacturing Ltd., SPML Land, Inc. and International Finance Corporation (incorporated by reference to Exhibit 10.1 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on May 7, 2013).
10.38
 
Loan Agreement, dated December 1, 2010, by and among California Enterprise Development Authority and SunPower Corporation, relating to $30,000,000 California Enterprise Development Authority Tax Exempt Recovery Zone Facility Revenue Bonds (SunPower Corporation - Headquarters Project) Series 2010 (incorporated by reference to Exhibit 10.50 to the Registrant's Annual Report on Form 10-K filed with the Securities and Exchange Commission on February 28, 2011).
10.39
 
First Supplement to Loan Agreement, dated June 1, 2011, by and between California Enterprise Development Authority and SunPower Corporation, relating to $30,000,000 California Enterprise Development Authority Tax Exempt Recovery Zone Facility Revenue Bonds (SunPower Corporation - Headquarters Project) Series 2010 (incorporated by reference to Exhibit 10.16 to the Registrant’s Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on August 9, 2011).
10.40†
 
Letter of Credit Facility Agreement, dated August 9, 2011, by and among SunPower Corporation, Total S.A., the Subsidiary Applicants party thereto, the Banks party thereto, and Deutsche Bank AG New York Branch (incorporated by reference to Exhibit 10.3 to the Registrant’s Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on November 10, 2011).
10.41†
 
First Amendment to Letter of Credit Facility Agreement, dated December 20, 2011, by and among SunPower Corporation, Total S.A., the Subsidiary Applicants party thereto, the Banks party thereto, and Deutsche Bank AG New York Branch (incorporated by reference to Exhibit 10.65 to the Registrant's Annual Report on Form 10-K filed with the Securities and Exchange Commission on February 29, 2012).
10.42
 
Second Amendment to Letter of Credit Facility Agreement, dated December 19, 2012, by and among SunPower Corporation, Total S.A., the Subsidiary Applicants party thereto, the Banks party thereto, and Deutsche Bank AG New York Branch (incorporated by reference to Exhibit 10.69 to the Registrant’s Annual Report on Form 10-K filed with the Securities and Exchange Commission on February 25, 2013).
10.43
 
Third Amendment to Letter of Credit Facility Agreement, dated December 20, 2013, by and among SunPower Corporation, SunPower Corporation, Systems, Total S.A., Deutsche Bank AG New York Branch (incorporated by reference to Exhibit 10.61 to the Registrant’s Annual Report on Form 10-K filed with the Securities and Exchange Commission on February 18, 2014).
10.44
 
Fourth Amendment to Letter of Credit Facility Agreement, dated December 23, 2014, by and among SunPower Corporation, SunPower Corporation, Systems, Total S.A., Deutsche Bank AG New York Branch (incorporated by reference to Exhibit 10.66 to the Registrant’s Annual Report on Form 10-K filed with the Securities and Exchange Commission on February 24, 2015).
10.45
 
Fifth Amendment to Letter of Credit Facility Agreement, dated October 7, 2015, by and among SunPower Corporation, SunPower Corporation, Systems, Total S.A., Deutsche Bank AG New York Branch (incorporated by reference to Exhibit 10.3 to the Registrant’s Annual Report on Form 10-Q filed with the Securities and Exchange Commission on October 29, 2015).
10.46
 
Continuing Agreement for Standby Letters of Credit and Demand Guarantees, dated September 27, 2011, by and among SunPower Corporation, Deutsche Bank Trust Company Americas, and Deutsche Bank AG New York Branch (incorporated by reference to Exhibit 10.10 to the Registrant’s Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on November 10, 2011).
10.47
 
Security Agreement, dated September 27, 2011, by and among SunPower Corporation, Deutsche Bank Trust Company Americas, and Deutsche Bank AG New York Branch (incorporated by reference to Exhibit 10.11 to the Registrant’s Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on November 10, 2011).

10.48
 
Revolving Credit Agreement, dated July 3, 2013, by and among SunPower Corporation and Credit Agricole Corporate and Investment Bank, and the financial institutions party thereto (incorporated by reference to Exhibit 10.1 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on October 31, 2013).
10.49
 
First Amendment to Revolving Credit Agreement, dated August 26, 2014, by and among SunPower Corporation, its subsidiaries, SunPower Corporation, Systems; SunPower North America LLC; and SunPower Capital, LLC, and Credit Agricole Corporate and Investment Bank and the other lenders party thereto (incorporated by reference to Exhibit 10.1 to the Registrant's Current Report on Form 8-K filed with the Securities and Exchange Commission on August 28, 2014).
10.50
 
Second Amendment to Revolving Credit Agreement, dated February 17, 2016, by and among SunPower Corporation, its subsidiaries, SunPower Corporation, Systems; SunPower North America LLC; and SunPower Capital, LLC, and Credit Agricole Corporate and Investment Bank and the other lenders party thereto (incorporated by reference to Exhibit 10.57 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on May 6, 2016).

157

Table of Contents


10.51
 
Third Amendment to Revolving Credit Agreement, dated March 18, 2016, by and among SunPower Corporation, its subsidiaries, SunPower Corporation, Systems; SunPower North America LLC; and SunPower Capital, LLC, and Credit Agricole Corporate and Investment Bank and the other lenders party thereto (incorporated by reference to Exhibit 10.58 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on May 6, 2016).
10.52†
 
Security Agreement, dated January 31, 2014, by and among SunPower Corporation, SunPower Corporation, Systems, SunPower North America, LLC, SunPower Capital, LLC, and Credit Agricole Corporate and Investment Bank (incorporated by reference to Exhibit 10.91 to the Registrant’s Annual Report on Form 10-K filed with the Securities and Exchange Commission on February 18, 2014).

10.53
 
First Amendment to Security Agreement, dated February 17, 2016, by and among SunPower Corporation, SunPower Corporation, Systems, SunPower North America, LLC, SunPower Capital, LLC, and Crédit Agricole Corporate and Investment Bank (incorporated by reference to Exhibit 10.59 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on May 6, 2016).
10.54
 
Joint Venture Agreement, dated May 27, 2010, by and among SunPower Technology, Ltd., AU Optronics Singapore Pte. Ltd., AU Optronics Corporation and AUO SunPower Sdn. Bhd. (formerly known as SunPower Malaysia Manufacturing Sdn. Bhd.) (incorporated by reference to Exhibit 10.15 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on August 13, 2010).
10.55
 
Amendment No. 1 to Joint Venture Agreement, dated June 29, 2010, by and among SunPower Technology, Ltd., AU Optronics Singapore Pte. Ltd., AU Optronics Corporation and AUO SunPower Sdn. Bhd. (formerly known as SunPower Malaysia Manufacturing Sdn. Bhd.) (incorporated by reference to Exhibit 10.1 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on November 12, 2010).
10.56
 
Amendment No. 2 to Joint Venture Agreement, dated July 5, 2010, by and among SunPower Technology, Ltd., AU Optronics Singapore Pte. Ltd., AU Optronics Corporation and AUO SunPower Sdn. Bhd. (formerly known as SunPower Malaysia Manufacturing Sdn. Bhd.) (incorporated by reference to Exhibit 10.2 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on November 12, 2010).
10.57
 
Amendment No. 3 to Joint Venture Agreement, dated March 3, 2014, by and among SunPower Technology, Ltd., AU Optronics Singapore Pte. Ltd., AU Optronics Corporation and AUO SunPower Sdn. Bhd. (formerly known as SunPower Malaysia Manufacturing Sdn. Bhd.) (incorporated by reference to Exhibit 10.3 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on April 30, 2014).
10.58†
 
Supply Agreement, dated July 5, 2010, by and among AUO SunPower Sdn. Bhd. (formerly known as SunPower Malaysia Manufacturing Sdn. Bhd.), SunPower Systems, Sarl and AU Optronics Singapore Pte. Ltd. (incorporated by reference to Exhibit 10.3 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on November 12, 2010).
10.59
 
License and Technology Agreement, dated July 5, 2010, by and among SunPower Technology, Ltd., AU Optronics Singapore Pte. Ltd. and AUO SunPower Sdn. Bhd. (formerly known as SunPower Malaysia Manufacturing Sdn. Bhd.) (incorporated by reference to Exhibit 10.4 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on November 12, 2010).
10.60
 
Compensation and Funding Agreement, dated February 28, 2012, by and between SunPower Corporation and Total S.A. (incorporated by reference to Exhibit 10.90 to the Registrant's Annual Report on Form 10-K filed with the Securities and Exchange Commission on February 29, 2012).
10.61
 
Amendment No. 1 to Compensation and Funding Agreement, dated August 10, 2012, by and between SunPower Corporation and Total S.A. (incorporated by reference to Exhibit 10.1 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on November 2, 2012).
10.62
 
Warrant to Purchase Common Stock, dated February 28, 2012, issued to Total Gas & Power USA, SAS (incorporated by reference to Exhibit 10.92 to the Registrant's Annual Report on Form 10-K filed with the Securities and Exchange Commission on February 29, 2012).
10.63†

 
Amended and Restated Limited Liability Company Agreement of 8point3 Holding Company, LLC, dated as of June 24, 2015, by and between SunPower YC Holdings, LLC and First Solar 8point3 Holdings, LLC (incorporated by reference to Exhibit 10.2 to the Registrant’s Annual Report on Form 10-Q filed with the Securities and Exchange Commission on July 29, 2015).
10.64
 
Amended and Restated Limited Liability Company Agreement of 8point3 Operating Company, LLC, dated as of June 24, 2015, by and between 8point3 Energy Partners LP, SunPower YC Holdings, LLC, First Solar 8point3 Holdings, LLC, Maryland Solar Holdings, Inc. and 8point3 Holdings, LL (incorporated by reference to Exhibit 10.3 to the Registrant’s Annual Report on Form 10-Q filed with the Securities and Exchange Commission on July 29, 2015).

10.65
 
Master Formation Agreement, dated as of March 10, 2015, by and between First Solar, Inc. and SunPower Corporation (incorporated by reference to Exhibit 2.1 to the Registrant’s Current Report on Form 8-K filed with the Securities and Exchange Commission on March 11, 2015).

158

Table of Contents


10.66
 
Credit Agreement, dated May 4, 2016, by and among SunPower Revolver HoldCo I, LLC, Mizuho Bank, Ltd., Mizuho Bank (USA), Mizuho Bank, Ltd., Goldman Sachs Bank USA, and the Lenders party thereto (incorporated by reference to Exhibit 10.61 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on August 9, 2016).
10.67
 
First Amendment to Credit Agreement, dated June 30, 2016, by and among SunPower Revolver HoldCo I, LLC, Mizuho Bank, Ltd., Mizuho Bank (USA), Mizuho Bank, Ltd., Goldman Sachs Bank USA, and the Lenders party thereto (incorporated by reference to Exhibit 10.68 to the Registrant's Quarterly Report on Form 10-Q filed with the Securities and Exchange Commission on August 9, 2016).
21.1*
 
List of Subsidiaries.
23.1*
 
Consent of Ernst & Young LLP, Independent Registered Public Accounting Firm.
24.1*
 
Power of Attorney.
31.1*
 
Certification by Chief Executive Officer Pursuant to Rule 13a-14(a)/15d-14(a).
31.2*
 
Certification by Chief Financial Officer Pursuant to Rule 13a-14(a)/15d-14(a).
32.1**
 
Certification Furnished Pursuant to 18 U.S.C. Section 1350 as Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.
101.INS*+
 
XBRL Instance Document.
101.SCH*+
 
XBRL Taxonomy Schema Document.
101.CAL*+
 
XBRL Taxonomy Calculation Linkbase Document.
101.LAB*+
 
XBRL Taxonomy Label Linkbase Document.
101.PRE*+
 
XBRL Taxonomy Presentation Linkbase Document.
101.DEF*+
 
XBRL Taxonomy Definition Linkbase Document.

Exhibits marked with a carrot (^) are director and officer compensatory arrangements.

Exhibits marked with an asterisk (*) are filed herewith.

Exhibits marked with two asterisks (**) are furnished and not filed herewith.

Exhibits marked with an extended cross (†) are subject to a request for confidential treatment filed with the Securities and Exchange Commission.

Exhibits marked with a cross (+) are XBRL (Extensible Business Reporting Language) information furnished and not filed herewith, are not a part of a registration statement or Prospectus for purposes of sections 11 or 12 of the Securities Act of 1933, are deemed not filed for purposes of section 18 of the Securities Exchange Act of 1934, and otherwise are not subject to liability under these sections.



159

Table of Contents


SIGNATURES

Pursuant to the requirements of Section 13 or 15(d) of the Securities Exchange Act of 1934, the registrant has duly caused this report to be signed on its behalf by the undersigned, thereto duly authorized.

 
SUNPOWER CORPORATION
 
 
 
Dated: February 17, 2017
By:  
/s/  CHARLES D. BOYNTON
 
 
 
 
 
Charles D. Boynton
 
 
Executive Vice President and
 
 
Chief Financial Officer

Pursuant to the requirements of the Securities Exchange Act of 1934, this Report has been signed below by the following persons on behalf of the registrant and in the capacities and on the dates indicated.
Signature
 
Title
 
Date
 
 
 
 
 
/S/ THOMAS H. WERNER 
 
President, Chief Executive Officer and Director
 
February 17, 2017
Thomas H. Werner
 
(Principal Executive Officer)
 
 
 
 
 
 
 
/S/ CHARLES D. BOYNTON
 
Executive Vice President and
Chief Financial Officer
 
February 17, 2017
Charles D. Boynton
 
(Principal Financial Officer and Principal Accounting Officer)
 
 
 
 
 
 
 
*
 
Director
 
February 17, 2017
Helle Kristoffersen

 
 
 
 
 
 
 
 
 
*
 
Director
 
February 17, 2017
Daniel Laure

 
 
 
 
 
 
 
 
 
*
 
Director
 
February 17, 2017
Catherine A. Lesjak

 
 
 
 
 
 
 
 
 
*
 
Director
 
February 17, 2017
Thomas R. McDaniel

 
 
 
 
 
 
 
 
 
*

 
Director
 
February 17, 2017
Ladislas Paszkiewicz

 
 
 
 
 
 
 
 
 
*

 
Director
 
February 17, 2017
Julien Pouget

 
 
 
 
 
 
 
 
 
*

 
Director
 
February 17, 2017
Laurent Wolffsheim
 
 
 
 
 
 
 
 
 
*

 
Director
 
February 17, 2017
Patrick Wood III
 
 
 
 

* By:  /S/ CHARLES D. BOYNTON
Charles D. Boynton
Power of Attorney




160

Table of Contents


Index to Exhibits
Exhibit Number
 
Description
21.1*
 
List of Subsidiaries.
23.1*
 
Consent of Ernst & Young LLP, Independent Registered Public Accounting Firm.
24.1*
 
Power of Attorney.
31.1*
 
Certification by Chief Executive Officer Pursuant to Rule 13a-14(a)/15d-14(a).
31.2*
 
Certification by Chief Financial Officer Pursuant to Rule 13a-14(a)/15d-14(a).
32.1**
 
Certification Furnished Pursuant to 18 U.S.C. Section 1350 as Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.
101.INS*+
 
XBRL Instance Document.
101.SCH*+
 
XBRL Taxonomy Schema Document.
101.CAL*+
 
XBRL Taxonomy Calculation Linkbase Document.
101.LAB*+
 
XBRL Taxonomy Label Linkbase Document.
101.PRE*+
 
XBRL Taxonomy Presentation Linkbase Document.
101.DEF*+
 
XBRL Taxonomy Definition Linkbase Document.

Exhibits marked with an asterisk (*) are filed herewith.

Exhibits marked with two asterisks (**) are furnished and not filed herewith.

Exhibits marked with a cross (+) are XBRL (Extensible Business Reporting Language) information furnished and not filed herewith, are not a part of a registration statement or Prospectus for purposes of sections 11 or 12 of the Securities Act of 1933, are deemed not filed for purposes of section 18 of the Securities Exchange Act of 1934, and otherwise are not subject to liability under these sections.


161